13152-CONTRACT (PHASE II).PDF

CONSTRUCTION MANAGEMENT AT RISK
MARICOPA COUNTY, ARIZONA
FOR PROFESSIONAL SERVICES
PHASE H
CONSTRUCTION SERVICES
FACILITIES MANAGEMENT DEPARTMENT
By and Through the OFFICE of PROCUREMENT SERVICES
OET Zone 2 Refresh Downtown CMR
Contract # 13152-CMR
Serial # 13152-CMR
C-91-
Project # FM131172
GET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. #1

CONSTRUCTION MANAGEMENT AT RISK
PROFESSIONAL SERVICES AGREEMENT
PHASE II
CONSTRUCTION SERVICES
BETWEEN MARICOPA COUNTY, ARIZONA, OWNER, AND
DPR Construction, PROFESSIONAL CMR
FOR CONSTRUCTION SERVICES FOR
OET Zone 2 Refresh Downtown CMR in Phoenix, Arizona
Whereas, Maricopa County (hereinafter the "County" "OWNER") desires to construct OET Zone 2
Refresh Downtown CMR in Phoenix, Arizona, and
Whereas, it is in the best interests of the County to obtain professional construction management services
in order to insure quality, timely and valued construction from a pre-approved professional Construction
Manager at Risk (CMR), and
Whereas, the COUNTY has competitively selected the Construction Manager at Risk in accordance in
following the procedures in Section 34-603, Arizona Revised Statutes, and the Maricopa County
Procurement Code from several firms, and
Whereas the selected firm will provide professional CMR and construction management services for the
OET Zone 2 Refresh Downtown CMR Project as directed by the County.
Whereas the Facilities Management Department is a part of the Maricopa County Regional Development
Services constellation, the Assistant County Manager will, from time to time, participate or assist in the
timely execution of various aspects of the design, construction, and completion management on behalf of
the Maricopa County Manager.
This agreement made this day of ,2014 by and between Maricopa County
(hereinafter called the "OWNER") and DPR Construction, hereinafter called the "CMR" as Construction
Manager at Risk for Phase II Construction Services.
Witnesseth, that the OWNER and the CMR, for the considerations herein set forth, agrees as follows:
Construction Agreement
Construction Management at Risk Phase II
The Scope of this Project is defined as follows:
The construction of OET Zone 2 Refresh Downtown CMR, and as further outlined in Exhibit A,
attached hereto and incorporated herein by reference as though fully set forth herein.
GET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. # 2

Table of Contents
ARTICLE 1- SCOPE OF WORK 5
ARTICLE 2- DEFINITIONS 5
ARTICLE 3- CMR'S SERVICES AND RESPONSIBILITIES 8
ARTICLE 4- PRIORITY OF PROVISIONS ..... 13
ARTICLE 5- DESIGN PROFESSIONAL'S AUTHORITY 14
ARTICLE 6- TIME FOR PERFORMANCE 15
ARTICLE 8- PAYMENTS AND COST OF THE WORK 21
ARTICLE 9- CONTINGENCY 26
ARTICLE 10- DISCOUNTS, REBATES AND REFUNDS 26
ARTICLE 11 - SUBCONTRACTS AND PURCHASE ORDERS 26
ARTICLE 12- INSURANCE 27
ARTICLE 13 - INDEMNIFICATION AND INSURANCE 30
ARTICLE 14- PERFORMANCE AND PAYMENT BOND AND QUALIFICATIONS OF
SURETY 30
ARTICLE 15 - INDEPENDENT CMR 32
ARTICLE 16- ACCESS TO AND RETENTION OF PROJECT RECORDS FOR THE
PURPOSE OF AUDIT AND/OR OTHER REVIEW 32
ARTICLE 17 - AS BUILT RECORDS 33
ARTICLE 18- CMR'S RESPONSIBILITY FOR THE WORK 33
ARTICLE 19- OCCUPATIONAL HEALTH AND SAFETY 33
ARTICLE 20- PERMITS, LICENSES AND IMPACT FEES ..... . ........... 35
ARTICLE 21 - PERSONNEL 35
ARTICLE 22- CMR'S WARRANTIES 36
ARTICLE 23- DEFECTIVE WORK 36
ARTICLE 24- CONSTRUCTION SIGNAGE 37
ARTICLE 25- OWNERSHIP OF CONTRACT DOCUMENTS 37
ARTICLE 26- CMR'S REPRESENTATIVE 38
ARTICLE 27 - OWNER'S RIGHT TO TERMINATE CONTRACT 38
ARTICLE 28- RESOLUTION OF DISPUTES 39
ARTICLE 29- NOTICES 39
ARTICLE 30- REQUIREMENTS FOR CONTRACTS WITH SBE GOALS 40
ARTICLE 31- OTHER TERMS & CONDITIONS 40
EXHIBIT A - CONSTRUCTION DOCUMENTS 47
OET Zone 2 Refresh Downtown CMR Serial 14 I3152-CMR
Contract between Maricopa County and DPR Construction Pg. # 3

EXHIBIT B - GMP PROPOSAL 48
EXHIBIT C - INSURANCE CERTIFICATE(S) 49
EXHIBIT D - PAYMENT BOND 50
EXHIBIT E - PERFORMANCE BOND 51
EXHIBIT F - MARICOPA COUNTY SMALL BUSINESS ENTERPRISE PROGRAM 52
EXHIBIT G - ALTERNATIVE DISPUTE RESOLUTION 54
EXHIBIT H - SUBCONTRACTOR MANAGEMENT PLAN 59
EXHIBIT I - LEGAL WORKER CERTIFICATION 60
OET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. # 4

ARTICLE 1- SCOPE OF WORK
The CMR shall furnish professional Construction Management at Risk Services for the Project described
in Exhibits A and B attached hereto and incorporated herein by this reference upon issuance of CMR's
Notice-to-Proceed by the OWNER or OWNER's representative.
The CMR shall furnish the following Services as specifically authorized by "CMR's Notice to Proceed"
issued by the Facilities Management Department,
1.1 The contract price elements are as follows:
CONTRACT PRICE
WITH A GUARANTEED MAXIMUM PRICE (GMP)
a. Construction $1,740,972.00
b. General Conditions $452,045.00
c. Construction (OWNER) Contingency $68,149.00
d. CMR's Fee $98,271.00
e. CMR's Overhead (included with Line B)
f. Bonds $43,860.00
g. Builders Risk Insurance $6,711.00
h. General Liability Insurance $28,045.00
Taxes $131,533.00
TOTAL GMP (ALL INCLUSIVE) $2,569,586.00
1.2 CMR hereby agrees to furnish all of the labor, materials, equipment services and incidentals
necessary to perform all of the work or reasonably inferable from the Contract Documents
Including Drawings, Specifications and Addenda for the Project known as the OET Zone 2
Refresh Downtown CMR, prepared by Pearson Engineering Associates, Inc., the DESIGN
PROFESSIONAL.
ARTICLE 2- DEFINITIONS
2.1 AUTHORITY HAVING JURISDICTION: The Maricopa County Planning and Development
Department
2.2 BASELINE PROJECT SCHEDULE: The initial schedule attached hereto and incorporated into
Exhibit "C".
2.3 BOARD OF SUPERVISORS: The Maricopa County Board of Supervisors, its successors and
assigns.
2.4 COUNTY OR OWNER: Maricopa County, Arizona, a political subdivision of the State of
Arizona, which is the party hereto for which this Contract is to be performed. In all respects
hereunder, COUNTY performance is pursuant to the COUNTY's position as the OWNER of a
construction Project. In the event COUNTY exercises its regulatory authority as a governmental
body, the exercises of such authority and the enforcement of any rules, regulations, laws and
ordinances shall be deemed to have occurred pursuant to the COUNTY's authority as a
governmental body and shall not be attributable in any manner to COUNTY as a party to this
contract.
2.5 CHANGE ORDER: A written document ordering a change in the Contract Price or Contract
Time or a material change in the Work as determined by the PROJECT MANAGER.
OET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. #5

2.6 CONDITIONAL NOTICE TO PROCEED: Not applicable herein.
2.7 CONSTRUCTION CONTINGENCY: An established sum included in the Guaranteed Maximum
Price (GMP) for the purpose of defraying actual expenses that may arise due to unforeseen
circumstances of the Project for which the contingency is established. If contingency is provided
but not utilized, it will be returned to the OWNER at Final Completion. Any use of construction
contingency funds must first be approved in writing by the OWNER.
2.8 CONTRACT: This Construction Agreement.
2.9 CONTRACT DOCUMENTS: The Project Manual (including this Agreement and its Exhibits,
Attachments and Forms including the General Conditions and General Requirements), drawings
and specifications, the Request For Qualifications and/or proposals, as applicable and CMR's
response thereto titled "Guaranteed Maximum Price Proposal" dated Wednesday, January 29,
2014 and herein attached as Exhibit B (as negotiated and accepted by the OWNER), any Addenda
to the Project Manual, the record of the contract award by the Board of Supervisors, the Contract,
the Performance Bond and Payment Bond, the Notice of Award, the Notice(s) to Proceed, the
Purchase Order(s) and all agreed upon modifications issued after execution of the Contract are the
documents which are collectively referred to as the Contract Documents as referenced herein.
2.10 CONTRACT PRICE: The amount established in the Contract as the Guaranteed Maximum Price
(GMP), as may be amended, if so warranted, by a Change Order issued in conformity with the
Contract Documents.
2.11 CONTRACT TIME: The time between the Project initiation date specified in the Notice to
Proceed for this phase and final completion, including any milestone dates thereof, established in
the contract, as may be amended by any change order.
2.12 CMR: An individual, partnership, corporation, association, joint venture, or any combination
thereof, which has entered into the contract with the OWNER for construction of the Work. The
Construction Manager at Risk for this Project is DPR Construction.
2.13 DAY: A Day is defined as a 24-hour period beginning at 12:01 a.m. and ending at Midnight,
Arizona standard time.
2.14 DESIGN PROFESSIONAL: The individual, partnership, corporation, association, joint venture,
or any combination thereof, of properly registered professional architects and/or engineers, which
has entered into an agreement to provide professional services for this Project.
2.15 DIRECTOR OF FACILITIES MANAGEMENT DEPARTMENT: The Director of this
Department, of Maricopa County, Arizona, having the authority and responsibility for
management of the specific Projects authorized under this Agreement.
2.16 FIELD ORDER or SUPPLEMENTAL INSTRUCTION: A written order which directs minor
changes or interpretations of the Contract Documents in accordance with Article 7, but which
does not involve a change in the Contract Price or Contract Time.
2.17 FINAL COMPLETION: The date certified by the DESIGN PROFESSIONAL and PROJECT
MANAGER in the Final Certificate of Payment in which all conditions and requirements of any
permits and regulatory agencies have been satisfied; and the documents (if any) required to be
provided by CMR have been received by the PROJECT MANAGER; and to the best of DESIGN
PROFESSIONAL's and PROJECT MANAGER's information and belief the Project has been
fully completed in accordance with the terms and conditions of the Contract Documents.
GET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. # 6

2.18 GENERAL CONDITION ITEMS: Includes, but is not limited to the following types of costs for
the CMR during the construction phase: payroll costs for Project manager or construction
manager but not both for Work conducted at the site, payroll costs for the superintendent and full-
time general foremen, payroll costs for management personnel resident and working on the site,
workers not included as direct labor costs engaged in support (e.g. loading/unloading, clean-up,
etc.), administrative office personnel, costs of offices and temporary facilities including office
materials, office supplies, office equipment, minor expenses, utilities, fuel, sanitary facilities and
telephone services at the site, costs of liability insurance premiums not included in labor burdens
for direct labor costs, costs of bond premiums, costs of consultants not in the direct employ of the
CMR or Subcontractors, fees for permits and licenses. Certain limitations and exclusions are
described in the General Conditions.
2.19 GUARANTEED MAXIMUM PRICE CONSTRUCTION CONTRACT: The method of
construction contracting whereby the CMR provides design phase consulting services (pre-
construction services) and management responsibility for the Project (general conditions). The
fee is a dollar amount negotiated for profit, overhead and off-site general and administrative
costs. All subcontracts are generally awarded by the CMR based on competitive bids received in
response to invitations to bid issued by the CMR to those entities on an OWNER pre-approved,
pre-qualified list of subcontractors. The total price paid to the CMR is either the fee plus the
costs or the Guaranteed Maximum Price (GMP), whichever is less. This contract utilizes the
Guaranteed Maximum Price as the method of compensation.
2.20 INSPECTOR: An employee of the OWNER of Maricopa County, Arizona, assigned by the
Director to make observations of work performed by a CMR.
2.21 LOOK AHEAD SCHEDULE: A schedule for a period of 3 weeks ahead of the current date to be
delivered during regular Project meetings.
2.22 MATERIALS: Materials incorporated in this Project, or used or consumed in the performance of
the Work.
2.23 NOTICE-TO-PROCEED: One or more written notices to CMR authorizing the commencement
of Work.
2.24 THE OFFICE OF PROCUREMENT SERVICES: The Maricopa County Department with
authority for all procurement activity within Maricopa County.
2.25 PLANS AND/OR DRAWINGS: The official graphic representations of this construction Project
which are a part of the Contract Documents.
2.26 PRELIMINARY WORK: not applicable.
2.27 PRICING DOCUMENTS: The set of documents and specifications upon which the GMP
contract is negotiated is comprised of the following: (i) the OWNER approved Contract
Documents, (ii) the Estimated and Actual Selected Qualified Bids CMR's Direct Construction
Cost (including unit prices, quantities and explanatory notes), (iii) the CMR's General Condition
Items, (iv) schedules developed by the CMR and approved by the PROJECT MANAGER, and
any other documents or exhibits utilized to derive the GMP.
2.28 PROJECT: The construction, alteration or repair, and all services and incidents thereto, of a
Maricopa County facility as contemplated and budgeted by the OWNER as described in the
Contract Documents, including the work described therein.
OET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. #7

2.29 PROJECT INITIATION DATE: the date of actual deployment onto the site of Work for the
Project which may be equal to or after the date of Notice to Proceed.
2.30 PROJECT MANAGER: An employee of the OWNER assigned by the Director of the
Department of Facilities Management to monitor the work to be performed under this Agreement
and the construction of a Project as a direct representative of the OWNER and who is the
representative of the Director concerning the Contract Documents.
2.31 PROJECT MANUAL: The official documents setting forth information and requirements;
contract forms, bonds, and certificates; general and supplementary conditions of the Contract
Documents; the specifications; and the plans and drawings of the Project.
2.32 RESIDENT PROJECT REPRESENTATIVE: An authorized representative of the DESIGN
PROFESSIONAL on the Project.
2.33 SCHEDULE: The document setting for the timeline and milestones for this Project.
2.34 SCHEDULE OF VALUES: A schedule showing the portion of the Work to be used to make
payment of the allotted funds for the Project based upon the GMP and Project schedule.
2.35 SUBCONTRACTOR: A person, firm or corporation having a direct contract with CMR including
one who furnishes material worked to a special design according to the Project Manual for this
work, but does not include those who merely furnish material not so worked.
2.36 SUBMITTAL SCHEDULE: The schedule for initiation and completion of submittals.
2.37 SUBSTANTIAL COMPLETION; That date on which, as certified in writing by DESIGN
PROFESSIONAL, the Work, or a portion thereof designated by the PROJECT MANAGER in its
sole discretion, is at a level of completion in substantial compliance with the Contract Documents
such that all conditions of permits and regulatory agencies have been satisfied and the OWNER
or its designee can enjoy beneficial use or occupancy and can use or operate it in all respects for
its intended purpose(s).
2.38 SURETY: The surety company or individual which is bound by the performance bond and
payment bond with and for CMR who is primarily liable, and which surety company or individual
is responsible for CMR's acceptable and timely performance of the work under the contract and
for the payment of all debts pertaining thereto in accordance with Arizona Revised Statutes. All
surety companies or individuals shall be authorized to conduct suretyship business under Arizona
Law and have an Arizona Resident Agent.
2.39 WORK: The totality of the obligations, including construction and other services required by the
Contract Documents, whether completed or partially completed, including all labor, materials,
equipment and service provided or to be provided by CMR to fulfill CMR's obligations. The
work may constitute the whole or a part of the Project.
2.40 WRITTEN NOTICE: As set forth in Article 30 herein.
ARTICLE 3- CMR'S SERVICES AND RESPONSIBILITIES
3.1 INTENTION OF OWNER:
It is the intent of OWNER to describe in the Contract Documents a functionally complete Project
(or part thereof as applicable) to be constructed in accordance with the Contract Documents. Any
work, materials or equipment that may reasonably be inferred from the Contract Documents as
being required to produce the intended result shall be supplied by CMR. When words, which
have a well-known technical or trade meaning, are used to describe work, materials or equipment,
OET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. # 8

such words shall be interpreted in accordance with that meaning. Reference to standard
specifications, manuals, or codes of any technical society, organization or association, or to the
laws or regulations of any governmental authority, whether such reference be specific or by
implication, shall mean the latest standard specification, manual, code or laws or regulations in
effect at the time of permit issuance. OWNER shall have no duties other than those duties and
obligations set forth within the Contract Documents.
3.2 THE CMR:
Shall promptly order and expedite all materials and other parts of the Work to be readily available
as and when required or needed for or in connection with the construction, furnishing and
equipping of the improvements. No excess materials are to be purchased, and the OWNER shall
not be charged for any materials acquired but not used in the Project, and any materials remaining
at the end of the Project are to be removed at CMR's expense.
3.3 THE CMR:
Shall plan, record, and update, the construction schedule of the Project. The Schedule shall
indicate the dates for the commencement and completion of the various stages of construction and
shall be revised as required by the Contract Documents and the condition of the Work. The
Progress Schedule shall encompass all of the work of all trades necessary for the construction of
the Project and shall be sufficiently complete and comprehensive to enable progress to be
monitored on a weekly basis. This schedule is in addition to the look ahead schedule as discussed
in Article 2.21.
3.4 SUPERINTENDENCE AND SUPERVISION:
3.4.1 The orders of OWNER are to be given through the OWNER or OWNER's
Representative, which instructions are to be strictly and promptly followed in every case.
CMR shall keep on the Project site during its progress, a competent, full time, English
speaking SUPERINTENDENT or PROJECT MANAGER (hereinafter referred to as
SUPERINTENDENT) and any necessary assistants, all satisfactory to the OWNER and
DESIGN PROFESSIONAL. The SUPERINTENDENT shall not be changed except with
the written consent of OWNER, unless the SUPERINTENDENT proves to be
unsatisfactory to CMR and ceases to be in its employ. The SUPERINTENDENT shall
represent CMR and all direction given to the SUPERINTENDENT shall be as binding as
if given to CMR and will be confirmed in writing by PROJECT MANAGER. CMR shall
give efficient supervision to the work, using its best skill and attention.
3.4.2 Daily, CMR's SUPERINTENDENT shall record, at a minimum, the following
information in a bound log: the day; date; weather conditions and how any weather
conditions affected the progress of the work; time of commencement of work for the day;
the work being performed; materials, labor, personnel, equipment and subcontractors at
the Project site; visitors to the Project site including representatives of OWNER,
DESIGN PROFESSIONAL, and regulatory authorities; any special or unusual conditions
or occurrences encountered; and the time of termination of work for the day. All
information shall be recorded in the daily log. The daily log shall be kept on the Project
site and shall be available at all times for inspection and copying by the OWNER and
DESIGN PROFESSIONAL.
3.4.3 The CMR, DESIGN PROFESSIONAL and PROJECT MANAGER shall meet at least
every week or as otherwise determined by the OWNER and/or DESIGN
PROFESSIONAL during the course of the work to review and agree upon the work
performed to date and to establish the controlling items of work for the next three weeks.
GET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Marieopa County and DPR Construction Pg. # 9

The CMR shall publish, keep, and distribute minutes and any comments thereto of each
such meeting.
3.4.4 CMR shall supervise and direct the work competently and efficiently, devoting such
attention thereto and applying such skills and expertise as may be necessary to perform
the Work in accordance with the Contract Documents. CMR shall be solely responsible
for the means, methods, techniques, sequences and procedures of construction.
3.5 CMR TO CHECK DRAWINGS, SPECIFICATIONS AND DATA:
CMR shall use reasonable effort to verify all dimensions, quantities and details shown on the
drawings, specifications or other data received from DESIGN PROFESSIONAL, and shall notify
OWNER and DESIGN PROFESSIONAL of all errors, omissions and discrepancies found therein
within three (3) calendar days of discovery. CMR will not be allowed to take advantage of any
error, omission or discrepancy. CMR shall not be liable for damages resulting from errors,
omissions or discrepancies in the Contract Documents unless CMR recognized or should have
recognized such error, omission or discrepancy and failed to report it to DESIGN
PROFESSIONAL.
3.6 DIFFERING SITE CONDITIONS:
In the event that during the course of the work, CMR encounters an underground utility that was
not shown on the Contract Documents; or subsurface or concealed conditions at the Project site
which differ materially from those shown on the Contract Documents or from those ordinarily
encountered and generally recognized as inherent in work of the character called for in the
Contract Documents; or unknown physical conditions of the Project site, of an unusual nature,
which differ materially from that ordinarily encountered and generally recognized as inherent in
work of the character called for in the Contract Documents, CMR, without disturbing the
conditions and before performing any work affected by such conditions, shall, no later than 9:00
a.m. the next day after their discovery, notify the OWNER and DESIGN PROFESSIONAL in
writing of the existence of the aforesaid conditions. DESIGN PROFESSIONAL shall, within one
(1) business day after receipt of CMR's written notice, investigate the site conditions identified
by the CMR. If, in the opinion of OWNER and DESIGN PROFESSIONAL, the conditions do
materially so differ and cause an increase or decrease in CMR's cost of or the time required for,
the performance of any part of the work, whether or not charged as a result of the conditions,
DESIGN PROFESSIONAL shall recommend an equitable adjustment to the contract price, or the
Contract Time, or both, which is subject to written approval by the OWNER. If DESIGN
PROFESSIONAL, OWNER, and CMR cannot agree on an adjustment in the contract price or
Contract Time, the adjustment shall be determined by the OWNER in accordance with Article 28
below.
No request by CMR for an equitable adjustment or change to the contract price or Contract Time
under this provision shall be allowed unless the CMR has given written notice detailing the facts
for such request in a reasonable time (not exceeding thirty (30) days from when the CMR knew
or should have known of such conditions) in accordance with the provisions of this Section.
No request for an equitable adjustment or change to the contract price or Contract Time •for
different site conditions shall be allowed if made after the date certified by DESIGN
PROFESSIONAL as the date of Substantial Completion.
3.7 SUBMITTALS:
3.7.1 CMR shall submit submittals (including but not limited to shop drawings, product
samples, product data, warranties, closeout submittals, reports and photographs) as
required by the General Conditions (Section 00700), General Requirements, and
specifications. The submittals serve as the CMR's coordination documents and
OET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. #10

demonstrate the suitability, efficiency, technique of manufacture, installation
requirements, detailing and coordination of specified products, components, assemblies
and systems, and shall evidence compliance or noncompliance with the Contract
Documents. The CMR's submittals are not part of the Contract Documents but are
documents prepared and utilized by the CMR to coordinate the work.
3.7.2 Within ten (10) calendar days after the date of the Notice to Proceed, CMR shall submit
to DESIGN PROFESSIONAL and OWNER a list of all submittals to be required.
Within twenty (20) calendar days of the date of the Notice to Proceed, CMR shall submit
to DESIGN PROFESSIONAL (with a copy to the PROJECT MANAGER) a
comprehensive list of items for which submittals are to be submitted and shall identify
the critical items, stating the dates for submittals and approval of submittals. Approval of
this list (the Submittal Schedule) by DESIGN PROFESSIONAL shall in no way relieve
CMR from submitting complete and timely submittals as required by the Contract
Documents and providing services, products, materials, equipment, systems and
assemblies, fully in accordance with the Contract Documents.
3.7.3 After the approval of the submittal schedule, CMR shall promptly request submittals
from the various manufacturers, fabricators, and suppliers.
3.7.4 CMR shall thoroughly review and check the submittals and timely submit them to the
DESIGN PROFESSIONAL in accordance with the requirements for such submittals
specified in Division 1 of the specifications. Each submittal and required copy thereof
shall indicate the CMR's review of that submittal in the form required by the Contract
Documents.
3.7.5 The CMR shall maintain a Submittal Log which shall include, at a minimum, the date of
each submittal, the date of any resubmittal, the date of any approval or rejection, and the
reason for any approval or rejection.
3.7.6 If the submittals indicate deviations or departures from the requirements of the Contract
Documents, CMR shall make specific mention thereof in its letter of transmittal. Failure
to point out such deviations or departures shall not relieve CMR from its responsibility to
comply with the Contract Documents.
3.7.7 The DESIGN PROFESSIONAL shall have no duty to review partial or incomplete
submittals except as may be provided otherwise within the Contract Documents.
3.7.8 Provided such Submittals conform to the approved Submittal schedule, CMR shall allow
the DESIGN PROFESSIONAL up to fourteen (14) calendar days from the date received
by the DESIGN PROFESSIONAL for review and approval of the submittals, unless said
Submittals are rejected by DESIGN PROFESSIONAL for material reasons or the
Submittals are of substantial building systems which require more time for thorough
review. DESIGN PROFESSIONAL's approval of Submittals will be general and shall
not relieve CMR of responsibility for the accuracy of such drawings, nor for the proper
fitting and construction of the work, nor for the furnishing of materials or work required
by the Contract Documents. No work for which submittals are required shall be
performed until said Submittals have been approved by DESIGN PROFESSIONAL.
Approval shall not relieve CMR from responsibility for errors or omissions on the
Submittals or for compliance with the requirements of the Contract Documents.
3.7.9 No review or approval will be given to partial Submittals for items, which interconnect
and/or are interdependent where necessary to properly evaluate the Submittal. It is
CMR's responsibility to assemble the Submittals for all such interconnecting and/or
interdependent items, check them and then make one Submittal to DESIGN
OET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. #11

PROFESSIONAL along with its comments as to compliance, noncompliance, or features
requiring special attention.
3.7.10 Additional information provided by the CMR on any Submittal shall be typewritten or
lettered in ink.
3.7.11 CMR shall submit the number of copies required by the Contract Documents plus the
number required by jurisdictional authorities (when submittals are to be made to such
authorities). Resubmissions of Submittals shall be made in the same quantity until final
approval is obtained from DESIGN PROFESSIONAL.
3.7.12 CMR shall keep one set of DESIGN PROFESSIONAL approved Submittals at the
Project site at all times.
3.8 FIELD LAYOUT OF THE WORK AND RECORD DRAWINGS:
3.8.1 The entire responsibility for establishing and maintaining line and grade in the field lies
with CMR. CMR shall maintain an accurate and precise record of the location and
elevation of all pipe lines, conduits, structures, manholes, handholds, fittings and other
accessories/features and shall prepare a complete site survey sealed by an Arizona
registered Professional Surveyor which shall be submitted as a Project record document
at the time of requesting final payment. Final surveys shall be submitted in hardcopy and
as an electronic media submittal prepared in accordance with requirements for electronic
media submittals as specified elsewhere in the Project Manual. The cost of all such field
layout and recording work is included in the Contract Price for the Project.
3.8.2 CMR shall maintain in a safe place at the Project site, one record copy of all drawings,
plans, specifications, addenda, written amendments, change orders, field orders,
submittals and written interpretations and clarifications in good order and annotated to
show all changes made during construction. Each of these documents shall be clearly
marked by CMR as "Project Record Documents". These Project Record Documents
together with all approved samples and a counterpart of all approved Submittals shall be
available at all times to DESIGN PROFESSIONAL for reference. Upon final completion
of the Project and prior to Final Payment, these Project Record Documents, including
Submittals and other Project Record Documents required elsewhere in the Project
Manual and specifications shall be delivered to the PROJECT MANAGER in an
electrical media as required by the OWNER.
3.8.3 Prior to, and as a condition precedent to Final Payment, the CMR shall submit to
OWNER, CMR's record drawings or as-built drawings acceptable to DESIGN
PROFESSIONAL. Record drawings/as-builts will be delivered on electronic media, CD
preferred, in AutoCAD format with all external references bound and PDF format.
3.8.4 Prior to, and as a condition for substantial completion, the CMR shall deliver to DESIGN
PROFESSIONAL for delivery to the OWNER all equipment data, along with its
recommended spare parts list, maintenance manuals, manufacturer's warranties and
operations manuals as may be required within the Project Manual for the OWNER's
employees and agents to maintain and operate any equipment provided as part of the
work.
3.9 INSPECTION AND TESTING:
3.9.1 DESIGN PROFESSIONAL and PROJECT MANAGER shall have reasonable access to
the work, and CMR shall provide the DESIGN PROFESSIONAL and PROJECT
MANAGER with the facilities described in the specifications, drawings, and solicitation
for such access and for inspecting, measuring and testing.
OET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. # 12

3.9.1.1 Should the Contract Documents, DESIGN PROFESSIONAL's instructions,
any laws, ordinances, or public authority require any of the Work to be
specially tested or approved, CMR, shall update and provide weekly for the
OWNER and DESIGN PROFESSIONAL a three (3) week Look-Ahead
Schedule denoting all activities to be performed and highlighting those that
need testing and approval. If the testing or approval is to be made by an
authority other than OWNER, timely notice shall be given of the date fixed for
such testing. Testing shall be made promptly, and where practicable, at the
source of supply.
3.9.1.2 If any of the Work which requires approval is covered up without approval or
consent of Authority Having Jurisdiction, it must, if required by the Authority
Having Jurisdiction, be uncovered at CMR's cost for examination and properly
restored to the satisfaction of the DESIGN PROFESSIONAL and PROJECT
MANAGER.
3.9.1.3 Should reexamination of any of the Work be ordered by DESIGN
PROFESSIONAL or PROJECT MANAGER for any reason other than that
specified in 3.9.1.2, the Work must be uncovered by the CMR. If such work is
found to be in accordance with the Contract Documents, OWNER shall pay the
cost of reexamination and replacement by means of a Change Order. If such
work is not in accordance with the Contract Documents, CMR shall pay such
cost to be deducted from the CMR's fee at no additional cost to OWNER and
no extension of time will be granted.
3.9.2 No inspector, employee or agent of the OWNER shall have the authority to permit
deviations from, nor to modify any of the provisions of the Contract Documents nor to
delay the contract by failure to inspect the materials and work with reasonable
promptness without written permission and instruction by the PROJECT MANAGER.
3.9.3 The payment of any compensation, whatever may be its character or form, or the giving
of any gratuity or the granting of any favor by CMR to any inspector, directly or
indirectly, is strictly prohibited, and any such act on the part of the CMR will constitute a
breach of this contract.
3.10 TAXES
3.10.1 CMR shall pay all applicable sales, consumer, use and other taxes required by law. CMR
is responsible for reviewing the pertinent state statutes and regulations involving state
taxes and complying with all requirements.
ARTICLE 4- PRIORITY OF PROVISIONS
4.1 The Contract Documents shall be interpreted so as to eliminate inconsistencies or conflicts, but in
the event of any conflict, requirements for greater quantity and/or more expensive work indicated
shall govern such interpretation.
4.2 Anything shown on the drawings and not mentioned in the specifications or mentioned in the
specifications and not shown on the drawings shall have the same effect as if shown or mentioned
respectively in both. In the event of a conflict among the Contract Documents, the most stringent
requirements applicable to the CMR shall control.
OET Zone 2 Refresh Downtown CMR Serial #1.1152-CMR
Contract between Maricopa County and DPR Construction Pg. # 13

4.3 In case of conflicts between the provisions of this Contract, any ancillary documents executed
contemporaneously herewith or prior hereto, or any other of the Contract Documents, the
provisions of this Contract (including all Exhibits) shall prevail in the order of preference stated
in the General Conditions (See § 1.1.7).
4.4 The organization of the Specifications into divisions and sections and the arrangement of
drawings shall not control CMR in dividing the Work among subcontractors or in establishing the
extent of the work to be performed by any trade. The organization of the Specifications and the
arrangement of the Drawings is for the convenience of the CMR and is not intended to relieve the
CMR from its obligation to conduct a complete study of the Drawings, Specifications and
Addenda for the purpose of directing and coordinating the various subcontractors and suppliers as
to their respective responsibilities.
ARTICLE 5- DESIGN PROFESSIONAL'S AUTHORITY
5.1 DESIGN PROFESSIONAL will provide overall technical and management services to assist the
OWNER in maintaining schedules, establishing budgets, controlling costs, and achieving quality.
5.2 If at any time the DESIGN PROFESSIONAL observes or becomes aware of any fault or defect in
the Work or of any nonconformance with the Contract Documents, DESIGN PROFESSIONAL
will promptly notify the OWNER and CMR in writing and will recommend reasonable steps be
taken to correct such fault, defect or nonconformance. The OWNER shall have the authority to
reject work that does not, in its opinion, conform to the Contract Documents.
5.3 DESIGN PROFESSIONAL shall monitor and report to the OWNER the overall quality and
progress of the Work.
5.4 DESIGN PROFESSIONAL shall not have control over construction means, method, techniques,
sequences and procedures employed by CMR in the performance of the work, but shall be
responsible for using its best efforts to review and, if unacceptable, disapprove such and shall
recommend a course of action to the OWNER if requirements of the Contract Documents are not
being met by CMR.
5.5 The OWNER will be assisted by DESIGN PROFESSIONAL in the areas of on-site review of
work in progress, review of pay requests submitted by the CMR, assisting in the interpretation of
the intent of the Contract Documents for the proper execution of the work, and such other
assistance as the OWNER may request.
5.6 The DESIGN PROFESSIONAL shall have no authority to order or approve any deviation from
the Contract Documents, if such deviation affects the Cost of the Work, or the date of Substantial
Completion. In the event any such deviation is sought by DESIGN PROFESSIONAL or CMR,
prior written approval from the PROJECT MANAGER must be obtained.
5.7 Any responsibility not specifically delegated to the DESIGN PROFESSIONAL in the contract
between the OWNER and the DESIGN PROFESSIONAL and not identified as responsibility of
the OWNER in the Contract shall be deemed a question of means and methods and shall be the
responsibility of the CMR.
OET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. # 14

ARTICLE 6- TIME FOR PERFORMANCE
6.1 CONTRACT TIME:
6.1.1 CMR shall be instructed to commence the work by written Notice-to-Proceed issued by
the OWNER. The Notice to Proceed will not be issued until CMR's submission to
OWNER of all required documents and after execution of the CONTRACT by both
parties. Preliminary work, including submission of a Baseline Project Schedule,
Schedule of Values, Submittal Schedule, completed security clearance documents for all
personnel and a subcontractor list, performance of work that does not require permits,
shall be submitted within ten (10) calendar days after the date of the Notice to Proceed.
Receipt of all permits, the Guaranteed Maximum Price, insurance documents, payment
bond and performance bond documents and the signed contract are all conditions
precedent to the issuance of a Notice to Proceed for all other Work. The Work to be
performed pursuant to the Notice to Proceed shall commence within ten (10) calendar
days of the Project Initiation Date specified in the Notice to Proceed.
6.1.2 Time is of the essence throughout this contract. The Project shall be substantially
completed within 92 calendar days from the date of the Notice to Proceed. The total
Project shall be completed and ready for final payment in accordance with Article 8
within 16 calendar days from the date certified by DESIGN PROFESSIONAL as the
date of Substantial Completion, or by June 30, 2014, whichever comes first.
6.1.3 Upon failure of CMR to substantially complete the Project within the specified period of
time, plus approved time extensions, CMR shall pay to OWNER the sum of One
Thousand, One Hundred Forty -Eight Dollars, and Eighty -Eight Cents, ($1,148.88)
for each calendar day after the time specified in Article 6.1.2, plus any approved
extensions for Substantial Completion. After Substantial Completion, should CMR fail
to complete the remaining work within the time specified in Article 6.1.2 above, plus
approved time extensions thereof, for completion and readiness for Final Completion,
CMR shall pay to OWNER the sum of One Thousand, One Hundred Forty-Eight
Dollars, and Eighty-Eight Cents ($1,148.88.) for each calendar day after the time
specified in Article 6.1.2 above, plus any approved extensions, for completion and
readiness for final payment. These amounts are not penalties but are liquidated damages
to OWNER for its inability to obtain full beneficial occupancy of the Project.
Upon failure of CMR to finally complete the Project within the specified period of time,
plus approved time extensions, CMR shall pay to OWNER the sum of One Thousand,
One Hundred Forty Eight Dollars, and Eighty -Eight Cents ($1,148.88.) for each
calendar day after the time specified in Article 6.1.2, plus any approved extensions for
Final Completion. After Final Completion, should CMR fail to complete the remaining
work within the time specified in Article 6.1.2 above, plus approved time extensions
thereof, for completion and readiness for Final Completion, CMR shall pay to OWNER
the sum of One Thousand, One Hundred Forty -Eight Dollars, and Eighty -Eight
Cents ($1,148.88.) for each calendar day after the time specified in Article 6.1.2 above,
plus any approved extensions, for completion and readiness for final payment. These
amounts are not penalties but are liquidated damages to OWNER for its inability to
obtain full beneficial occupancy of the Project.
Liquidated damages are hereby fixed and agreed upon between the parties, recognizing
the impossibility or difficulty of precisely ascertaining the amount of damages that will
be sustained by OWNER as a consequence of such delay, and both parties desiring to
obviate any questions of dispute concerning the amount of said damages and the cost and
effect of the failure of CMR to complete the Contract on time. The above-stated
OET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. #15

liquidated damages shall apply separately to Substantial Completion and Final
Completion.
6.1.4 PROJECT MANAGER is authorized to deduct liquidated damages from monies due to
CMR for the work under this contract or as much thereof as PROJECT MANAGER may,
at its option, deem just and reasonable.
6.1.5 CMR shall be responsible for reimbursing OWNER, in addition to liquidated damages,
for all costs incurred by DESIGN PROFESSIONAL in administering the construction of
the Project beyond the completion dates specified above or beyond an approved
extension of time granted to CMR, whichever date is later. Such costs shall be deducted
from the monies due CMR for performance of work under this contract by means of
unilateral deductive change orders by OWNER.
6.1.6 Extensions to the Contract Time for delays caused by the effects of adverse weather shall
be submitted as a request for change in Contract Time pursuant to Article 6.3. If adverse
weather conditions are the basis for a Claim for additional time, such Claim shall be
documented by data substantiating that weather conditions were abnormal for the period
of time and could not have been reasonably anticipated, and that weather conditions had
an adverse effect on the scheduled construction.
6.2 SUBSTANTIAL COMPLETION DATE:
6.2.1 When CMR considers that the Work, or portion thereof designated by PROJECT
MANAGER pursuant to Article 6.4 hereof, has reached Substantial Completion, CMR
shall so notify PROJECT MANAGER and DESIGN PROFESSIONAL in writing.
DESIGN PROFESSIONAL and PROJECT MANAGER shall then promptly inspect the
work.
6.2.2 When OWNER, on the basis of such an inspection, determines that the work or
designated portion thereof is substantially complete, DESIGN PROFESSIONAL will
then prepare a Certificate of Substantial Completion by utilizing form No. AIA G704 or a
comparable form, which shall establish the Date of Substantial Completion; shall state
the responsibilities of OWNER and CMR for security, operation, safety, maintenance,
utilities, damage to the work, insurance, and warranties; shall list all work yet to be
completed (Punch List) to satisfy the requirements of the Contract Documents for final
completion. The failure to include any items of corrective work on such list does not
alter the responsibility of CMR to complete all of the work in accordance with the
Contract Documents. The Certificate of Substantial Completion shall be submitted to the
PROJECT MANAGER, after execution by CMR, and DESIGN PROFESSIONAL,
indicating their written acceptance of such certificate.
6.3 NOTIFICATION OF CHANGE OF CONTRACT TIME OR CONTRACT PRICE:
6.3.1 Any claim for a change in the Contract Time or Contract Price shall be made by written
notice and delivered by CMR to the PROJECT MANAGER within five (5) calendar days
of the commencement of the event giving rise to the claim and stating the general nature
of the claim. Notice of the nature and elements of the claim shall be delivered within
twenty (20) calendar days after the date of such written notice. Thereafter, within ten
(10) calendar days of the termination of the event giving rise to the claim, notice of the
extent of the claim with supporting data shall be delivered unless DESIGN
PROFESSIONAL allows an additional period of time to ascertain more accurate data in
support of the claim and shall be accompanied by CMR's written statement and
explanation how the adjustment claimed is justified as a result of the occurrence of said
OET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. # 16

event. All claims for adjustment in the Contract Time or contract price shall be
determined by OWNER in accordance with Article 28 hereof, if OWNER and CMR
cannot otherwise agree. NO CLAIM FOR AN ADJUSTMENT IN THE CONTRACT
TIME OR CONTRACT PRICE WILL BE VALID IF NOT SUBMITTED IN STRICT
ACCORDANCE WITH THE REQUIREMENTS OF THIS SECTION AND ARTICLE
28 HEREOF.
6.3.2 The Contract Time will be extended in an amount equal to time lost due to delays beyond
the control of and through no fault or negligence of CMR if a claim is made therefore as
provided in Articles 6.3.1 and 7.7. Such delays shall include, but not be limited to, acts
or neglect by any separate independent contractors employed by OWNER, fires, floods,
labor disputes, epidemics, abnormal weather conditions or acts of God.
6.3.3 All approved Change Orders will be considered full and final and inclusive of all claims
related thereto, both as to time and costs.
6.4 USE OF COMPLETED PORTIONS:
6.4.1 OWNER shall have the right, at its sole option, to take possession of and use of any
completed or partially completed portions of the Project. Such possession and use shall
not be deemed an acceptance of any of the Work not completed in accordance with the
Contract Documents. If such possession and use increases the cost of or delays of the
work, CMR shall be entitled to reasonable extra compensation, or reasonable extension of
time or both, by appropriate adjustment pursuant to Articles 7.4 and 7.6 hereof.
6.4.2 In the event OWNER takes possession of any completed or partially completed portions
of the Project, the following shall occur:
6.4.2.1 OWNER shall give notice to CMR in writing at least fifteen (15) calendar
days prior to OWNER's intended occupancy of a designated area.
6.4.2.2 CMR shall complete to the point of Substantial Completion the designated
area. Additionally, CMR shall submit a request for an inspection and issuance
of a Certificate of Substantial Completion (AIA - Form G704 or equivalent)
for the designated area. The CMR's open punch list for that area shall be
attached to the request for Substantial Completion.
6.4.2.2.1 Upon DESIGN PROFESSIONAL's issuance of a Certificate of
Substantial Completion, OWNER will assume full responsibility
for maintenance, utilities, subsequent damages of the area by the
OWNER and the public, adjustment of insurance coverage and
start of warranty for the occupied area.
6.4.2.3 If the OWNER finds it necessary to occupy or use a portion or portions of the
Work prior to Substantial Completion thereof, such occupancy or use shall not
commence prior to a time mutually agreed upon by OWNER and CMR and to
which the insurance company or companies providing the property insurance
have consented by endorsement to the policy or policies. Insurance on the
unoccupied or unused portion or portions shall not be canceled or lapsed on
account of such partial occupancy or use. Consent of CMR and of the
insurance company or companies to such occupancy or use shall not be
unreasonably withheld.
OET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. #17

ARTICLE 7- CHANGES IN THE WORK OR TERMS OF CONTRACT DOCUMENTS
7.1 CHANGE ORDER - AMENDMENTS:
Any changes to the terms of the Contract Documents must be contained in a written document,
executed by the parties hereto, with the same formality and of equal dignity prior to the initiation
of any work reflecting such change. This section shall not prohibit the issuance of Change Orders
executed only by OWNER as hereinafter provided.
All amendments to this Contract shall be in writing and approved/signed by both parties.
7.2 EXTRA WORK:
Without invalidating the Contract and without notice to the surety, OWNER reserves and shall
have the right, from time to time, to make such increases, decreases or other changes in the
character, timing, or quantity of the work as may be considered necessary or desirable to
complete fully and acceptably the proposed construction in a satisfactory manner. Any extra or
additional work within the scope of this Project must be accomplished by means of an appropriate
Change Order in accordance with the requirements of the Contract Documents.
7.3 EXPEDITING THE WORK:
The PROJECT MANAGER may direct the CMR to expedite the work by whatever means the
CMR may choose, including, without limitation, increasing staffing or working overtime to bring
the work back within the progress schedule. If the expediting of Work is required due to reasons
outside the control or responsibility of the CMR, then the additional costs incurred shall be the
subject of an appropriate adjustment issued pursuant to Articles 7.4 and Article 7.6, below, as
applicable.
7.4 CHANGE ORDER PROCEDURES:
7.4.1 Changes in the quantity or character of the work within the scope of the Project including
ones which are the subject of Field Orders or Supplemental Instructions, and including all
changes resulting in changes in the contract price, or the Contract Time, shall be
authorized only by written change orders approved and issued in advance of the work and
in accordance with the provisions of the Contract Documents and Article 5 of the
Maricopa County Procurement Code which is deemed to be incorporated by reference
herein as though set forth in full.
7.4.2 The CMR's fee on such changes which exceeds GMP shall be determined as follows:
7.4.2.1 A mutually acceptable fixed fee; or, if none can be agreed upon,
7.4.2.2 A fee based upon a percentage of the net change to the Cost of the Work
resulting from the Change Order, in accordance with Article 8.3, hereof, not to
exceed five percent (5%).
Subcontractor's percentage markup on change orders for overhead and profit shall be
reasonable, but in no event shall the aggregate of the subcontractor's overhead and profit
markups exceed fifteen percent (15%). In the event subcontractor is affiliated with the
CMR by common OWNERship or management, or is effectively controlled by the CMR,
no fee will be allowed on the subcontractor costs. In the event there is more than one
level of subcontractor, such as second and third tier subcontractors, the sum of all of the
OET Zone 2 Refresh Downtown GMR Serial # I3152-CMR
Contract between Maricopa County and DPR Construction Pg. # 18

subcontractor's percentage markups for overhead and profit shall not in the aggregate
exceed twenty percent (20%).
7.4.3 CMR shall not start work on any changes requiring an increase in the contract price or the
Contract Time until a Change Order setting forth adjustments is approved and issued by
the OWNER. If the CMR commences work pertaining to a Change Order prior to
receiving written authorization through the Project Manager it does so at its own risk and
assumes all associated responsibility and costs. Upon receipt of a Change Order, CMR
shall promptly proceed with the work set forth within the document.
7.4.4 In the event satisfactory adjustment cannot be reached for any item requiring a change in
the Contract Price or Contract Time, and a Change Order has not been issued, OWNER
reserves the right at its sole option to either terminate the Contract as it applies to the
items in question and make such arrangements as may be deemed necessary to complete
the disputed work; or submit the matter in dispute to ADR as set forth in the attached
Exhibit, incorporated herein. During the pendency of the dispute, and upon receipt of a
Change Order, CMR shall promptly proceed with the change in the work involved and
advise the PROJECT MANAGER in writing within seven (7) calendar days of CMR's
agreement or disagreement with the method, if any, provided in the Change Order for
determining the proposed adjustment in the Contract Price or Contract Time.
7.4.5 On approval of any Contract change increasing the contract price, CMR shall ensure that
the Performance Bond and Payment Bond are increased so that each reflects the total
contract price as increased.
7.4.6 To avoid delays to the Project and to mitigate damages to the parties, Change Orders may
be issued unilaterally by OWNER in accordance Article 5 of the Maricopa County
Procurement Code and the Article 5 Procedures Manual.
7.4.7 All approved Change Orders will be deemed final and inclusive of all claims related
thereto, including costs and time.
7.5 Field ORDERS AND SUPPLEMENTAL INSTRUCTIONS:
7.5.1 The DESIGN PROFESSIONAL shall have the right to approve and issue changes setting
forth written interpretations of the intent of the Contract Documents and ordering minor
changes in work execution, providing the Field Order involves no change in the Contract
Price or Contract Time.
7.5.2 DESIGN PROFESSIONAL shall have the right to approve and issue Supplemental
Instructions setting forth written orders, instruction, or interpretations concerning the
Contract Documents, provided such supplemental instructions involve no change in the
contract price or Contract Time.
7.6 NO DAMAGES FOR DELAY:
No claim for damages or any claim other than for an extension of time, shall be made or asserted
against OWNER by reason of any delays. CMR shall not be entitled to an increase in the
Contract Price or payment or compensation of any kind from OWNER for direct, indirect,
consequential, impact or other costs, expenses or damages, including, but not limited to, costs of
acceleration or inefficiency, arising because of delay, disruption, Eichleay Formula Costs,
interference or hindrance from any cause whatsoever, whether such delay, disruption, interference
or hindrance be reasonable or unreasonable, foreseeable or unforeseeable, or avoidable or
unavoidable; provided, however, that this provision shall not preclude recovery of damages by
0E1 Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. # 19

CMR for hindrance or delays due solely to fraud, bad faith or active interference on the part of
OWNER or its agents. Otherwise, CMR shall be entitled only to extensions of the Contract Time
as the sole and exclusive remedy for such resulting delay, in accordance with and to the extent
specifically provided above.
7.7 EXCUSABLE DELAY: COMPENSABLE & NON-COMPENSABLE:
7.7.1 Excusable Delay: Delay which extends the completion of the work which is caused by
circumstances beyond the control of CMR or its subcontractors, materials persons,
suppliers, or vendors is Excusable Delay. CMR is entitled to a time extension of the
Contract Time for each day the work is delayed due to excusable delay. CMR shall
document its claim for any time extensions as provided in Article 6.3 hereof.
Failure of CMR to timely comply with Article 6.3 hereof as to any particular event of
delay shall be deemed conclusively to constitute a waiver, abandonment or
relinquishment of any and all claims resulting from that particular event of delay.
7.7.2 Excusable Delay may be compensable or non-compensable.
7.7.2.1 Compensable Excusable Delay. Excusable Delay is only compensable when: (i)
the delay extends the Contract Time, and (ii) is due solely to fraud, bad faith or
active interference on the part of OWNER or its DESIGN PROFESSIONAL. In
no event shall CMR be compensated for interim or non-critical delays, which do
not extend the Contract Time. CMR shall be entitled to direct and indirect costs
for Compensable Excusable Delay. Direct costs recoverable by CMR shall be
limited to the actual additional costs allowed pursuant to Article 8.3 hereof.
OWNER and CMR recognize and agree that the amount of CMR's precise actual
indirect costs for delay in the performance and completion of the work is
impossible to determine as one of the date of execution of the Contract
Documents, and that proof of the precise amount will be difficult. Therefore,
indirect costs recoverable by the CMR shall be liquidated on a daily basis for
each day the Contract Time is delayed due to a Compensable Excusable Delay.
These liquidated indirect costs shall be paid to compensate CMR or for all
indirect costs caused by a Compensable Excusable Delay and shall include, but
not be limited to, all profit on indirect costs, home office overhead, acceleration,
loss of earnings, loss of productivity, loss of bonding OWNER, loss of
opportunity
and all other indirect costs recoverable shall be One Thousand, One Hundred
Forty-Eight Dollars, and Eighty-Eight Cents ($1,148.88.) per day for each day
the Contract is delayed due to a Compensable Excusable Delay.
7.7.2.2 Non-Compensable Excusable Delay. When Excusable Delay is (i) caused by
circumstances beyond the control of CMR, its subcontractors, material persons,
suppliers and vendors, or is also caused by circumstances beyond the control of
the OWNER or (ii) is caused jointly or concurrently by CMR or its
subcontractors, materials persons, suppliers or vendors and by the OWNER or
DESIGN PROFESSIONAL, then CMR shall be entitled only to a time extension
and no further compensation for the delay.
OET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. # 20

ARTICLE 8- PAYMENTS AND COST OF THE WORK
8.1 In full consideration of the full and complete performance of the Work and all other obligations
of the CMR hereunder, the OWNER shall pay to the CMR a sum of money not to exceed the
contract price which is defined to be the total of: (i) the CMR's Direct Construction Cost, (ii) so
much of the CMR's General Conditions as may have been expended, (iii) so much of the
approved amount of the Construction Contingency as may have been expended, and (iv) the
CMR's construction management fee. The contract price shall not exceed the sum shown in
Article 1.0 as the Guaranteed Maximum Price, adjusted to take into account any approved
Change Orders, and shall mean those costs necessarily incurred and paid by the CMR in
connection with the performance of all the work.
8.2 After completion and acceptance of the work, in the event that the Cost of the Work plus the
CMR's fee are less than the Guaranteed Maximum Price after giving effect to adjustments to the
GMP made in accordance with this Contract then the difference between the Cost of the Work
plus the CMR's fee on the one hand and the GMP on the other hand is the "savings". The
savings shall accrue to the OWNER as stated in Article 8.11. The OWNER reserves the right to
issue a deductive Change Order at any point during the Project, reducing the Construction
(OWNER) Contingency. The OWNER also reserves the right to issue a deductive Change Order
at any point during the Project, as agreed to by the CMR, deducting calculated savings from the
Guaranteed Maximum Price. In the event that the CMR's total approved expenditures for the
Project shall exceed the Guaranteed Maximum Price, the CMR shall pay such excess from its
own funds, and the OWNER shall not be required to pay any amount that exceeds the GMP; and
the CMR shall have no claim against the OWNER on account thereof.
8.3 The term "Cost of the Work" shall mean the sum of all direct costs necessarily and reasonably
incurred and paid by the CMR in the performance of the Work. Such costs shall be at rates not
higher than those customarily paid in the locality of the Project except with the prior written
consent of OWNER. The Cost of the Work shall include only those items set forth in this Article
8.3 and shall not include any items listed in Article 8.4. Cost of the Work shall be determined as
follows:
8.3.1 SUBCONTRACTOR COSTS:
8.3.1.1 The CMR's Direct Construction Cost, for the work as generally described in
Exhibit A, attached hereto, to be performed by the General CMR or performed
by subcontractor selected in accordance with Article 11, below. Where the work
is covered by unit prices contained in the Contract Documents or an applicable
subcontract, the Cost of the Work shall be determined by application of unit
prices to the quantities of items involved.
8.3.1.2 Whenever a change in subcontractor work is to be based on mutual acceptance of
a lump sum, whether the amount is an addition, credit or no change-in-cost, CMR
shall submit an initial cost estimate obtained from the subcontractor and
acceptable to OWNER subject to the Limitations set forth in Article 7.4. The
breakdown shall list the quantities and earlier agreed unit prices for materials,
labor, equipment and other items of cost. Whenever a change involves more than
one subcontractor and the change is an increase in the GMP, overhead and profit
percentage of each subcontractor and CMR, if applicable, shall be itemized
separately.
8.3.1.3 If the subcontract provides that the subcontractor is to be paid on the basis of
Cost of the Work plus a fee, the subcontractor's Cost of the Work shall be
OET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. #21

determined in the same manner as CMR's Cost of the Work, subject to the
limitation on subcontractor's fees set forth in Article 7.4.
8.3.1.4 If changes to subcontracted work affected the GMP, such changes shall be
accomplished in accordance with Article 7.4, Change Orders. The amount of
decrease in the GMP for any change that results in a net decrease in cost, will be
the amount of the actual net decrease. When both additions and decreases are
involved in any one change, the combined effect shall be figured on the basis of
the net change in the GMP, if any.
8.3.2 CMR'S LABOR COSTS:
Costs for employees in the direct employ of CMR in the performance of the work
described in the Contract Documents. In lieu of wages and a labor burden, it is agreed
that wages shall be reimbursed in accordance with Attachment A — Billable Rate
Schedule, which shall be mutually agreed upon for the duration of the Project by
OWNER and CMR. Costs for employees not employed full time on the work covered by
the Contract shall be apportioned on the basis of the time the employees spent on the
work. In lieu of wages and a labor burden, it is agreed that wages shall be reimbursed in
accordance with Attachment "A" - Billable Rate Schedule. Rates included in Attachment
A — Billable Rate Schedule shall include salaries, social security contributions,
unemployment, excise and payroll taxes, working compensation, health insurance, sick
leave, pensions or 401k programs, vacation and holiday pay. A detailed accounting of
time spent on the Project must be provided at the request of the County within seven (7)
business days of the receipt by the CMR of written request therefor.
8.3.3 MATERIALS AND EQUIPMENT:
Cost of all materials and equipment furnished and incorporated in the work, including
costs of transportation and storage thereof, and manufacturers' field services required in
connection therewith, adjusted in accordance with Article 10, pertaining to Discounts,
Rebates and Refunds; rentals of all construction equipment and machinery and the parts
thereof whether rented from CMR of others in accordance with rental agreements and the
costs of transportation, loading, unloading, installation, dismantling and removal thereof,
all in accordance with the terms of said agreements. The rental of any such equipment,
machinery or parts shall cease when the use thereof is no longer necessary for the work.
8.3.4 MISCELLANEOUS COSTS:
8.3.4.1 The cost, as documented by the CMR's detailed receipts, of telephone, telegrams,
postage, photographs, blueprints, office supplies, first aid supplies and related
miscellaneous costs reasonably incurred in direct support of the work at the
Project location.
8.3.4.2 Premiums on bonds and insurance, including subcontractor bonds, if any that the
CMR secures and maintains under the terms of the CONTRACT DOCUMENTS
and such other insurance and bonds as may be required, All insurance and bonds
shall be provided by companies acceptable to the OWNER 's Risk Manager.
Self-insurance by the CMR or insurance through any affiliates of CMR shall not
be permitted without the OWNER' s prior written approval. OWNER's approval
shall not be required on a subcontractor bond, and premiums thereof shall be
considered a Cost of the Work.
OET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. # 22

8.3.4.3 The cost of obtaining and using any utility services required for the Work that are
not paid directly by OWNER, including fuel and sanitary services at the Project
site.
8.3.4.4 The cost of removal of debris from the site. The Project site, lay-down locations,
and staging sites will be kept clear of all debris on a daily basis. All subcontracts
shall require subcontractors to remove all debris daily created by their activities,
and the CMR shall exercise its best efforts to enforce such requirements or effect
the removal of the debris of the subcontractors who fail in this regard. Provided,
however, the CMR shall not be required to remove debris created by the
OWNER's separate CMRs except pursuant to Change Order procedures set forth
herein.
8.3.4.5 The cost and expenses, actually sustained by the CMR in connection with the
work, of protecting and repairing adjoining property, if required, except to the
extent that any such cost or expense is:
8.3.4.5.1 the responsibility of the CMR under Article 13, reimbursable by
insurance or otherwise;
8.3.4.5.2 Due to the failure of the CMR to comply with the requirements of the
Contract Documents with respect to insurance; or
8.3.4.5.3 Due to the failure of any officer of the CMR or any of its representatives
having supervision or direction of the Work to exercise good faith or the
standard of care normally exercised in the conduct of the business CMR
experienced in the performance of work of the magnitude, complexity
and type encompassed by the Contract Documents, in any of which
events any such expenses shall not be included in CMR's costs.
8.3.4.6 Federal, state, municipal, sales, use and other taxes required by law, as applicable
to the Project, all with respect to service performed or materials furnished for the
work, it being understood that none of the foregoing includes, federal, state or
local income or franchise taxes.
8.3.4.7 All reasonable costs and expenditures necessary for the operation of the Project
job site office(s), including cost of field computer equipment and software.
8.3.4.8 The proportion of necessary transportation, travel and subsistence expenses of
CMR's employees, excluding travel time, incurred in discharge of duties
connected with the work except for local travel to and from the site of the Work.
Out of state travel must be approved in advance in writing by the OWNER.
8.3.4.9 Cost, including transportation and maintenance, of all materials, supplies,
equipment, machinery, appliances, office and temporary facilities at the site and
hand tools not owned by the workers, which are consumed in the performance of
the work, and cost less market value of such items used but not consumed which
remain the property of CMR.
8.3.4.10 Deposits lost for causes other than CMR's negligence, royalty payments and fees
for permits and licenses.
8.3.4.11 Cost of premiums for additional bonds and insurance required because of
changes in the Work.
OET Zone 2 Refresh Downtown CMR Serial #13152-CMR
Contract between Maricopa County and DPR Construction Pg. # 23

8.3.4.12 Cost of special DESIGN PROFESSIONALS, including, but not limited to,
engineers, architects, testing laboratories, surveyors employed for services
specifically related to the Work except for those required for deferred submittals.
8.3.4.13 Any other expenses or changes incurred, with the prior written approval of he
OWNER, in the performance of the Work.
8.4 EXCLUSIONS TO COST OF THE WORK:
Overhead is defined as any and all other costs, not referenced in Article 8.3, of the CMR and its
operation which are not in direct support of the Project. The CMR agrees to furnish and perform,
as a part of the CMR's Fee and without reimbursement, said overhead items. The term "Cost of
the Work" shall not include any of the following:
8.4.1 Payroll costs and other compensation of CMR's officers, executives, principals (of
partnership and sole proprietorship), general managers, estimators, purchasing and
contracting agents, clerks and other personnel employed by CMR whether or not
approved by the OWNER whether at the site or in its principal or a branch office for
general administration that are not specifically included in the General Conditions are to
be considered administrative costs covered by CMR's fee.
8.4.2 Other than those expenses authorized on Exhibit B, expenses of CMR's principal and
branch offices.
8.4.3 Any part of CMR's capital expenses, including interest on CMR's capital employed for
the Work and charges against CMR for delinquent payments.
8.4.4 Other overhead, general expense costs or charges of any kind and the cost of any item not
specifically and expressly included in Article 8.3.
8.4.5 Costs in excess of the Guaranteed Maximum Price.
8.4.6 Entertainment and meal expenses, car allowances and charges of a personal nature.
8.4.7 Bonuses, pensions, profit sharing or other special labor charges not included in Article
8.3.2, above.
8.4.8 Any outside legal or accounting fees incurred without prior written approval from the
OWNER, which approval is at the sole discretion of the OWNER.
8.5 PROGRESS PAYMENTS:
8.5.1 CMR may make Application for Payment for Work completed during the Project
utilizing AIA form 702/703 or equivalent at intervals of not more than once a month.
CMR's application shall show a complete breakdown of the Project components, the
percentages completed and the fees and General Conditions amounts due in proportion to
the percentages of the Work completed. Each application shall be accompanied by such
supporting evidence as may be reasonably required by OWNER, however each
application shall, at a minimum be accompanied by statements/invoices from each
subcontractor and/or materials provider for the application period along with conditional
lien waivers, and in addition thereto, unconditional lien waivers/releases from all
subcontractors and materials providers from the preceding application for payment.
CMR shall submit with each Application for Payment, an updated progress schedule
acceptable to OWNER. Each Application for Payment shall be accompanied by a
completed SBE Program Participation Reporting form in the form attached hereto as an
Exhibit. OWNER shall make payment to CMR, as required by A.R.S. § 34-609 and the
Prompt Payment Act.
OET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. # 24

8.5.2 Ten percent (10%) of all monies earned by CMR shall be retained by OWNER until Final
Completion and acceptance by OWNER in accordance with Article 8.5.4 hereof.
8.5.3 After fifty percent (50%) of the Work has been completed, the PROJECT MANAGER
may reduce the retainage to five percent (5%) of all monies previously earned and all
monies earned thereafter. Any reduction in retainage shall be in the sole discretion of the
PROJECT MANAGER, and CMR shall have no entitlement to a reduction. Any interest
earned on retainage shall accrue solely to the benefit of OWNER.
8.5.4 The CMR shall have the right, pursuant to Arizona Revised Statues, to submit securities
in lieu of retention. The CMR is required to request this option at least ten (10) business
days prior to submission of first Application for Payment to allow time for preparation of
forms.
8.5.5 OWNER may withhold, in whole or in part, any progress payment to CMR to such extent
as may be sufficient to pay the Expenses the OWNER reasonably expects to incur to
correct an deficiency in the Work set forth in specific written findings by DESIGN
PROFESSIONAL or PROJECT MANAGER prepared for those items in the pay
application of the estimate of the Work that are not approved for payment in that pay
application under Contract. If PROJECT MANAGER in its good faith judgment,
determines that the portion of the GMP then remaining unpaid will not be sufficient to
complete the Work in accordance with Contract Documents as set forth in written detail
and provided to CMR pursuant to A.R.S. § 34-609, no additional payments will be due to
CMR hereunder unless and until CMR, at its sole cost, performs a sufficient portion of
the Work so that such portion of the GMP then remaining unpaid is determined by
PROJECT MANAGER to be sufficient to so complete the Work. It is the intention of
this Article 8.5 to provide OWNER with the maximum protection afforded an OWNER
under the Prompt Pay Provisions of A.R.S. § 34-609.
8.5.6 The Schedule of Values, prepared in accordance with Exhibit B, shall reflect the CSI
Divisions including the cost of materials, the cost of labor, the cost of equipment and the
cost of subcontractor Work. Each monthly Application for Payment shall be for a sum
equal to (i) that portion of the CMR's Direct Construction Cost equal to the percentage of
the Work completed; plus (ii) an appropriate amount of the CMR 's General Conditions
Costs and Fees as related to the percentage of the Work completed. The calculation of
the percentage of the Work completed shall be in accordance with the approved Progress
Schedule; provided, however, prior to the date of the Final Request, and unless subject to
reduction under Article 8.5.2, the aggregate of the CMR's Fee payments shall not exceed
Ninety (90%) percent of the CMR's Fee as stated in Article 8.3.
8.5.7 The CMR's Direct Construction Cost shall be segregated and detailed in a manner
satisfactory to the PROJECT MANAGER to evaluate the charges. The Request for
Payment shall indicate the percentage of completion of each portion of the Work, and the
total Work, as of the end of the period covered by the Application for Payment. The
Schedule of Values shall be used as one basis for reviewing the Request for Payment
when such amounts are approved.
8.6 The DESIGN PROFESSIONAL and PROJECT MANAGER shall review each such Request for
Payment and may make such exceptions, as the DESIGN PROFESSIONAL and the PROJECT
MANAGER reasonably deem necessary or appropriate under the state of circumstances then
existing. Final determination resides with the Project Manager. In no event shall the OWNER be
required to make payment for items of the CMR's Cost to which the PROJECT MANAGER
reasonably take(s) exception.
OET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. # 25

8.7 CMR shall remain solely liable for subcontractor's Work and for any unpaid laborers, material
suppliers or subcontractors in the event it is later discovered that said Work is deficient or that
any of said laborers, material suppliers or subcontractors did not receive payments due them on
the Project.
8.8 Within 15 Calendar Days after Final Completion of the Work and acceptance thereof by the
OWNER, the CMR shall submit a Final Request for Payment (Final Request) which shall set
forth all amounts due and remaining unpaid to the CMR (including the unpaid portion of the
CMR's Fee).
8.9 Except for the CMR's Fee, the CMR shall use the sums paid to it pursuant to this Article 8 solely
for the purpose of performance of the Work and the construction, furnishing and equipping of the
Work in accordance with the Contract Documents and payments of bills incurred by the CMR in
performance of the Work.
8.10 The CMR shall promptly pay all bills for labor and material performed and furnished by its
subcontractors, suppliers and materials providers, in connection with the construction, furnishing
and equipping of the Work and the performance of the Work.
8.11 PROJECT CLOSEOUT:
Prior to the Notice of Final Completion being issued, any remaining monies in the Guaranteed
Maximum Price shall be returned to the OWNER through a final deductive Change Order,
reducing the Guaranteed Maximum Price. Final Payment shall only be made after full execution
of the final deductive Change Order.
ARTICLE 9- CONTINGENCY
9.0 THE CONSTRUCTION CONTINGENCY (OWNER):
The GMP may include an OWNER'S construction contingency. Costs may be applied against
the contingency if first approved by the OWNER in writing. The CMR shall furnish all
documentation evidencing the expenditures charged to this Contingency prior to release of funds
by the OWNER. At Final Completion of the Project, any remaining monies in the Construction
Contingency shall vest in the OWNER. The Guaranteed Maximum Price shall be reduced in the
amount of the Construction Contingency remaining monies, if any. Any use of construction
contingency funds must first be approved in writing by the OWNER.
ARTICLE 10- DISCOUNTS, REBATES AND REFUNDS
10.1 All cash discounts obtained on payments made by the CMR shall accrue to the OWNER
irrespective of whether or not the CMR actually advanced its own funds, prior to receipt of funds
from OWNER, to make the payment giving rise to the discount.
ARTICLE 11- SUBCONTRACTS AND PURCHASE ORDERS
11.1 All work, including work to be specifically performed by the CMR must be obtained via
competitive pricing and subcontract, in compliance with the requirements of this Article 11 and
A.R.S. Titles 34 and 41, for the balance of the CMR's Direct Construction Cost required under
this Contract. All subcontracts and purchase orders shall be awarded according to the following
procedure:
OET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. # 26

11.2 The CMR shall prepare for DESIGN PROFESSIONAL's and PROJECT MANAGER's review
and approval a list of pre-qualified subcontractors and suppliers for each bid who meet the
CMR's schedule of minimum requirements. The CMR shall obtain bids from a minimum of
three (3) such subcontractors for each subcontract, when available. If the CMR is unable to do so
for any subcontract, it must request and obtain the approval of the PROJECT MANAGER. After
receiving such bids, the CMR shall analyze them and make recommendations to the OWNER and
DESIGN PROFESSIONAL for awards in compliance with A.R.S. Title 34. Unless the DESIGN
PROFESSIONAL and PROJECT MANAGER determine any such subcontract to be
unacceptable, the CMR shall contract solely in its own name and behalf, and not in the name or
behalf of the OWNER, with the specified subcontractor or supplier. The CMR's subcontract form
shall provide: that the subcontractor shall perform its portion of the Work in accordance with all
applicable provisions of this Contract and the other Contract Documents; that subcontractor is
bound to the CMR to the same extent that the CMR is bound to the OWNER; that the CMR and
OWNER shall be named as additional insureds on subcontractor's comprehensive general
liability insurance policy and provide an insurance certificate evidencing the same; for
termination of the subcontract by the CMR in the same manner and method as provided in Article
27 of this Contract, or as otherwise provided in such subcontract, whichever is more protective of
the OWNER's interest; subcontractor shall comply with A.R.S. § 41-4401; and shall further
provide that, in the event this Contract is terminated for any reason, that the subcontract shall, at
the OWNER's option, be assigned to OWNER and subcontractor shall perform its subcontract for
the OWNER, or for a CMR designated by the OWNER, without additional or increased cost,
provided the subcontractor is paid in accordance with its subcontract. The CMR shall sign, and
shall cause each subcontractor to sign, an Assignment of Rights under Construction Subcontract.
Nothing contained herein shall impose on the OWNER an obligation to assume any subcontract
or to make any payments to any subcontractor to perform and nothing contained herein shall
create any contractual relationship between the OWNER and any subcontractor. The
subcontractor selection and management plan submitted by CMR is incorporated herein by this
reference as Exhibit H.
ARTICLE 12 - INSURANCE
12.1 The CMR, at the CMR'S own expense, shall purchase and maintain the herein stipulated
minimum insurance from a company or companies duly licensed by the State of Arizona and
possessing a current A.M. Best, Inc. rating of B++. In lieu of State of Arizona licensing, the
stipulated insurance may be purchased from a company or companies, which are authorized to do
business in the State of Arizona, provided that said insurance companies meet the approval of
COUNTY. The form of any insurance policies and forms must be acceptable to COUNTY.
12.1.1 All insurance required herein shall be maintained in full force and effect until all work or
service required to be performed under the terms of the Contract is satisfactorily
completed and formally accepted. Failure to do so may, at the sole discretion of
COUNTY, constitute a material breach of this Contract.
12.1.2 CMR'S insurance shall be primary insurance as respects COUNTY, and any insurance or
self-insurance maintained by COUNTY shall not contribute to it.
12.1.3 Any failure to comply with the claim reporting provisions of the insurance policies or any
breach of an insurance policy warranty shall not affect the COUNTY'S right to coverage
afforded under the insurance policies.
12.1.4 The insurance policies may provide coverage that contains deductibles or self-insured
retentions. Such deductible and/or self-insured retentions shall not be applicable with
respect to the coverage provided to COUNTY under such policies. CMR shall be solely
responsible for the deductible and/or self-insured retention and COUNTY, at its option,
OET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. # 27

may require the CMR to secure payment of such deductibles or self-insured retentions by
a surety bond or an irrevocable and unconditional letter of credit.
12.1.5 COUNTY reserves the right to request and to receive, within ten (10) working days,
certified copies of any or all of the herein required insurance policies and/or
endorsements and any amendments thereto. COUNTY shall not be obligated, however,
to review such policies and/or endorsements or to advise the CMR of any deficiencies in
such policies and endorsements, and such receipt shall not relieve the CMR from, or be
deemed a waiver of Maricopa COUNTY'S right to insist on strict fulfillment of the
CMR'S obligations under this Contract.
12.1.6 The insurance policies required by this Contract, except Workers' Compensation, shall
name COUNTY, its agents, representatives, officers, directors, officials, and employees
as Additional Insured's.
12.1.7 The policies required hereunder, except Workers' Compensation, shall contain a waiver
of transfer of rights of recovery (subrogation) against COUNTY, Maricopa County, City
its agents, representatives, officers, directors, officials, and employees for any claims
arising out of the CMR'S work or service.
12.1.8 CMR is required to procure and maintain the following coverage's:
12.1.8.1 Commercial General Liability. Commercial General Liability insurance and,
when necessary, Commercial Umbrella insurance with a limit of not less than
$2,000,000 for each occurrence, 52,000,000 Personal/Advertising Injury,
$4,000,000 Products/Completed Operations Aggregate, and $4,000,000
General Aggregate Limit. The policy shall include coverage for bodily
injury, broad form property damage, and blanket contractual coverage, and
shall not contain any provision that would serve to limit third party action
over claims. There shall be no endorsement or modification of the CGL
limiting the scope of coverage for liability arising from explosion, collapse,
or underground property damage.
12.1.8.2 Automobile Liability. Commercial/Business Automobile Liability insurance
and, if necessary, Commercial Umbrella insurance with a combined single
limit for bodily injury and property damage of not less than $2,000,000 each
occurrence with respect to any of the CMR'S owned, hired, and non-owned
vehicles assigned to or used in performance of the CMR's work or services
under this Contract.
12.1.8.3 Workers' Compensation. Workers' Compensation insurance to cover
obligations imposed by federal and state statutes having jurisdiction of the
CMR's employees engaged in the performance of the work or services under
this Contract; and Employer's Liability insurance of not less than $1,000,000
for each accident, $1,000,000 disease for each employee, and $1,000,000
disease policy limit.
CMR waives all rights against COUNTY and its agents, officers, directors
and employees for recovery of damages to the extent these damages are
covered by the Workers' Compensation and Employer's Liability or
commercial umbrella liability insurance obtained by CMR pursuant to this
agreement.
GET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. # 28

12.1.8.4 Builder's Risk (Property) Insurance. CMR shall purchase and maintain, on a
replacement cost basis, Builders' Risk insurance and, if necessary,
Commercial Umbrella insurance in the amount of the initial Contract amount
as well as subsequent modifications thereto for the entire work at the site.
Such Builders' Risk insurance shall be maintained until final payment has
been made or until no person or entity other than COUNTY has an insurable
interest in the property required to be covered, whichever is earlier. This
insurance shall include interests of COUNTY, CMR, and all subcontractors
and sub-subcontractors in the work during the life of the Contract and course
of construction, and shall continue until the work is completed and accepted
by COUNTY. For new construction Projects, CMR agrees to assume full
responsibility for loss or damage to the work being performed and to the
structures under construction. For renovation construction Projects, CMR
agrees to assume responsibility for loss or damage to the work being
performed at least up to the full Contract amount, unless otherwise required
by the Contract documents or amendments thereto.
Builders' Risk insurance shall be on a special form and shall also cover false
work and temporary buildings and shall insure against risk of direct physical
loss or damage from external causes including debris removal, demolition
occasioned by enforcement of any applicable legal requirements, and shall
cover reasonable compensation for architect's service and expenses required
as a result of such insured loss and other "soft costs" as required by the
Contract.
Builders' Risk insurance must provide coverage from the time any covered
property comes under CMR'S control and/or responsibility, and continue
without interruption during construction, renovation, or installation,
including any time during which the covered property is being transported to
the construction installation site, and while on the construction or installation
site awaiting installation. The policy will provide coverage while the covered
premises or any part thereof are occupied. Builders' Risk insurance shall be
primary and any insurance or self-insurance maintained by the County is not
contributory.
If the Contract requires testing of equipment or other similar operations, at
the option of COUNTY, CMR will be responsible for providing property
insurance for these exposures under a Boiler Machinery insurance policy or
the Builders' Risk Insurance policy.
l 2 .1 .8.5 COVERAGES
Commercial General
Liability $2,000,000 Each Occurrence
$2,000,000 Personal & Advertising Injury
$4,000,000 General Aggregate
$4,000,000 Products/Completed Operations
Automotive Liability $2,000,000 Each Occurrence
Workers' Compensation $1,000,000 Each Accident
$1,000,000 Disease for Each Employee
$1,000,000 Disease Policy Limit
Builders' Risk Replacement Cost
OET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. # 29

12.2 CERTIFICATES OF INSURANCE:
Prior to commencing work or services under this Contract, the CMR shall furnish County
with Certificates of Insurance in a form acceptable to COUNTY, or formal endorsements
as required by the Contract in the form provided by the County, issued by the CMR's
insurer(s), as evidence that policies providing the required coverage's, conditions, and
limits required by this Contract are in full force and effect. Such certificates shall
identify this contract number and contract title. Subguard insurance will not be accepted
by the COUNTY.
12.2.1 In the event any insurance policy(ies) required by this contract is(are) written on a
"claims made" basis, coverage shall extend for two (2) years past completion and
acceptance of the CMR's work or services and as evidenced by annual Certificates of
Insurance.
12.2.2 If a policy does expire during the life of the Contract, a renewal certificate must be sent to
COUNTY not later than fifteen (15) days prior to the expiration date.
12.3 CANCELLATION AND EXPIRATION NOTICE:
12.3.1 Insurance required herein shall not expire, be canceled, or materially changed without
thirty (30) days prior written notice to COUNTY.
ARTICLE 13 - INDEMNIFICATION AND INSURANCE
13.1 CMR's Duty to Indemnify and Defend. To the fullest extent permitted by law, the CMR shall
defend, indemnify and hold harmless the OWNER, its agents, representatives, officers, directors,
officials, and employees from and against all claims, damages losses, and expenses, including but
not limited to attorney fees, court costs, expert witness fees, and the cost of appellate proceedings,
relating to, arising out of, or alleged to have resulted from the negligent, reckless, or intentionally
wrongful acts, errors, omissions or mistakes of the CMR, its agents, representatives, employees,
or subcontractors relating to the performance of this Contract. CMR's duty to defend, indemnify
and hold harmless the OWNER, its agents, representatives, officers, directors, officials, and
employees shall arise in connection with any claim, damage loss or expense that is attributable to
bodily injury, sickness, disease, death or injury to, impairment, or destruction of property,
including loss of use resulting therefrom, caused by the referenced acts, errors, omissions or
mistakes in the performance of this Contract, including those made by any person for whose acts,
errors, omissions or mistakes, the CMR may be legally liable.
The amount and type of insurance coverage requirements set forth herein will in no way be
construed as limiting the scope of the indemnity in this paragraph.
ARTICLE 14 - PERFORMANCE AND PAYMENT BOND AND QUALIFICATIONS OF SURETY
14.1 Within ten (10) calendar days of being notified of the award, CMR shall furnish a Performance
Bond and a Payment Bond containing all the provisions of the Performance Bond and Payment
Bond attached hereto. All bonds regardless of form, will be on the form required and set forth in
A.R.S. § 34-222(1).
14.1.1 Each Bond shall be in the amount of one hundred percent (100%) of the GMP
guaranteeing to OWNER the completion and performance of the Work covered in such
Contract as well as full payment concerning all suppliers, material providers, laborers, or
subcontractors employed pursuant to this Project. Each Bond shall be with a surety
company which is qualified pursuant to Article 14.2.
OET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. # 30

14.1.2 Each Bond shall continue in effect for two years after final completion and acceptance of
the Work with liability equal to one hundred percent (100%) of the Contract sum, or an
additional bond shall be conditioned that CMR will, upon notification by OWNER,
correct any defective or faulty Work or materials which appear within two years after
final completion of the Contract.
14.1.3 Alternate form of Security: In lieu of a Performance Bond and a Payment Bond, CMR
may furnish The CMR shall have the right, pursuant to Arizona Revised Statues, to
submit securities in lieu of retention. The CMR must identify either the securities in lieu
of retention option or retention option prior to first Application for Payment. The CMR
is required to request this option at least ten (10) business days prior to submission of first
Application for Payment to allow time for preparation of forms. The CMR shall request
and obtain securities forms through OWNER.
14.2 QUALIFICATIONS OF SURETY:
14.2.1 Each bond must be executed by a surety company in recognized standing, authorized to
do business in the State of Arizona as surety, having a resident agent in the State of
Arizona and having been in business with a record of successful continuous operation for
at least five years.
14.2.2 The Surety Company shall hold a current certificate of authority as acceptable surety on
federal bonds in accordance with United States Department of Treasury Circular 570,
Current Revisions. If the amount of the Bond exceeds the underwriting limitation set
forth in the circular, in order to qualify, the net retention of the surety company shall not
exceed the underwriting limitation in the circular, and the excess risks must be protected
by coinsurance, reinsurance, or other methods in accordance with Treasury Circular 297,
revised September 1, 1973 (31 DFR Section 223.10, Section 223.111). Further, the
Surety Company shall provide OWNER with evidence satisfactory to OWNER, that such
excess risk has been protected against in an acceptable manner.
14.2.3 The OWNER will accept a surety bond from a company with a rating of B+ or better for
bonds up to $2 million, provided, however, that if any surety company appears on the
watch list that is published quarterly by Intercom of the Office of the Arizona Insurance
Commissioner, the OWNER shall review and either accept or reject the surety company
based on the financial information available to the OWNER. A surety company that is
rejected by the OWNER may be substituted by the bidder or proposer with a surety
company acceptable to the OWNER, only if the bid amount does not increase. The
ratings of Surety shall correspond to the amount of bonds as follows:
Policy
Holder's Financial Size
Amount of Bond Rating s Cate
500,001 to 1,000,000 B+ Class I
1,000,001 to 2,000,000 B+ Class II
2,000,001 to 5,000,000 A Class III
5,000,001 to 10,000,000 A Class IV
10,000,001 to 25,000,000 A Class V
25,000,001 to 50,000,000 A Class VI
50,000,001 or more A Class VII
OET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. # 31

ARTICLE 15 - INDEPENDENT CMR
15.1 In performing, the CMR shall be deemed an independent CMR and not an agent or employee of
the OWNER. The CMR shall be solely responsible for and have control over construction
means, methods, techniques, sequences and procedures and for coordinating all portions of the
Work under this Contract, unless the Contract Documents give other specific instructions
concerning these matters.
ARTICLE 16 - ACCESS TO AND RETENTION OF PROJECT RECORDS FOR THE PURPOSE
OF AUDIT AND/OR OTHER REVIEW
16.1 OWNER or its designee shall have the right to audit, inspect and copy the books and records and
accounts of CMR and all major subcontractors including but not limited to books, records,
correspondence, instructions, drawings, receipts, payment records, vouchers, and memoranda
which relate in any way to the Project, and to any claim for additional compensation made by
CMR which relate to the Project and to any claim for additional compensation made by CMR.
CMR shall preserve and make available to OWNER all financial records, supporting documents,
statistical records and any other documents which relate to the Project and to any claim for a
period of nine (9) years following final completion of the Project. During the Project and for the
appropriate record retention period, CMR shall provide OWNER access to its books and records
at CMR's usual place of business upon seventy-two (72) hours written notice. If any audit has
been initiated and audit findings have not been resolved at the end of the end of the retention
period or within Five (5) years, whichever is longer, the books, records and accounts shall be
retained until resolution of the audit findings.
16.2 If the Arizona Public Records Act (A.R.S. § 41-1347.B.) is determined by OWNER to be
applicable to CMR's records, CMR shall comply with all requirements thereof. Any incomplete
or incorrect entry in such books, records and accounts shall be a basis for OWNER's
disallowance and recovery of any payment upon such entry.
16.2.1 CMR's records shall include, but not be limited to accounting records (hard copy, as well
as computer readable data), written policies and procedures; subcontractor files
(including proposals of successful and unsuccessful bidders and bid recaps), surety files
and bond company files, original estimates, estimating work sheets, correspondence,
change order files (including, but not limited to, documentation covering negotiated
settlements), back charge logs and supporting documentation, general ledger entries
detailing cash and trade discounts earned, insurance rebates and dividends and any other
supporting evidence deemed necessary by the OWNER to substantiate charges related to
this Contract (all of the foregoing hereinafter referred to as records).
16.2.2 CMR shall require all subcontractors, insurance agents and material suppliers (payees) to
keep and maintain comparable records for the same time period and to permit the
OWNER to review, inspect and audit such records. CMR shall include such
requirements in all written subcontracts and purchase orders issued.
16.3 The OWNER reserves the right to audit the CMR records at any time during the life of this
contract whether or not the Project has been completed. If an audit inspection or other
examination by the OWNER or the OWNER's representatives in accordance with this Article,
disclose overcharges (of any nature) by the CMR to the OWNER, the cost of the OWNER's audit
(whether performed by the OWNER or outside auditors) shall be reimbursed or paid to the
OWNER by the CMR. Any adjustments and/or records of overcharges shall be made within a
reasonable amount of time (not to exceed thirty (30) days) from presentation of the OWNER
findings to the CMR.
GET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. # 32

ARTICLE 17- AS BUILT RECORDS
17.1 As required by the General Conditions, General Requirements, and the technical specifications
(or, in absence of technical specification requirements, concurrent with the Final Request for
Payment), the CMR shall furnish final surveys in electronic media and pdf format utilizing CAD
Standards, all external references bound, as designated by the PROJECT MANAGER, in addition
to three (3) sets of hard copy, showing the exact locations of all structures and underground site
utilities installed by CMR, including all water, sewer, gas, fuel, telephone, security and electric
lines and main, and locations of all easements for such utilities. Such surveys shall be prepared
by a licensed Arizona surveyor who shall certify that the Work is installed and erected entirely
upon the Project Site and within the building restriction lines, if any, and does not overcharge or
encroach upon any easement or right-of-way of others.
ARTICLE 18 - CMR'S RESPONSIBILITY FOR THE WORK
18.1 CMR shall bear full responsibility for the Work against all loss or damage of whatsoever nature
sustained until final acceptance by OWNER, and shall promptly repair any damage done from
any cause whatsoever.
18.2 CMR shall be responsible for all materials, equipment and supplies pertaining to the Project. In
the event any such materials, equipment and supplies are lost, stolen, damaged or destroyed prior
to final acceptance by OWNER; CMR shall replace it without cost to OWNER. CMR shall be
responsible to protect all materials, equipment and supplies, keeping them free from deterioration,
weathering, rusting or other action detrimental to the materials.
18.3 OWNER reserves the right to award other contracts in connection with this Project. CMR shall
afford other persons or contractors reasonable opportunity for the introduction and storage of
materials and the execution of Work under such separate contracts. CMR shall properly connect
and coordinate this Work with the Work of any other persons or contractors that might contract
separately with OWNER.
18.4 If any part of CMR's Work depends on proper execution or results upon the Work of any other
persons, CMR shall inspect and promptly report to PROJECT MANAGER any defects in such
Work that render it unsuitable for such proper execution and results. CMR's failure to so inspect
and report shall constitute an acceptance of the other person's Work as fit and proper for the
reception of CMR's Work, except as to defects which may develop in other CMR'S Work after
the execution of CMR's Work.
18.5 CMR shall conduct its operations and take all reasonable steps to coordinate the prosecution of
the Work so as to create no interference or impact on any other contractor on the site. Should
such interference or impact occur, and the CMR did not take reasonable steps, the CMR shall be
liable to the affected contractor for the cost of such interference or impact.
18.6 To ensure the proper execution of subsequent Work, CMR shall inspect the Work already in place
and shall at once report to PROJECT MANAGER any discrepancy between the executed Work
and the requirements of the Contract Documents.
ARTICLE 19 - OCCUPATIONAL HEALTH AND SAFETY
19.1 CMR'S DUTY TO PROTECT: The CMR shall take reasonable precautions for safety of, and
shall provide reasonable protection to prevent damage, injury or loss to:
19.1.1 Employees on the Work and other persons who may be affected thereby;
OET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. #33

19.1.2 The Work and materials and equipment to be incorporated therein, whether in storage
on or off the Site, under care, custody or control of the CMR or the CMR's
subcontractors;
19.1.3 The Work and materials and equipment to be incorporated therein, if the Project Site is
within a floodplain;
19.1.4 Other property at the Site or adjacent thereto, such as trees, shrubs, lawns, walks,
pavements, roadways, structures and utilities not designated for removal, relocation or
replacement in the course of construction; and
19.1.5 Construction or operations by the OWNER or other contractors.
19.2 COMPLIANCE WITH SAFETY NOTICES AND LAWS: The CMR shall comply with
applicable laws, ordinances, rules, regulations and lawful orders of public authorities bearing on
safety of persons or property or their protection from damage, injury or loss.
19.3 SAFETY PRECAUTIONS: The CMR shall erect and maintain, as required by existing
conditions and performance of the Contract, reasonable safeguards for safety and protection,
including posting danger signs and other warnings against hazards, promulgating safety
regulations and notifying OWNERs and users of adjacent sites and utilities. The CMR shall also
be responsible, at the CMR's sole cost and expense, for all measures necessary to protect any
property adjacent to the Site and improvements thereon. Any damage to such property or
improvements shall be promptly repaired by the CMR. Without limiting the indemnity
provisions elsewhere in the Contract, the CMR shall indemnify, defend and hold harmless the
Indemnitees from and against any and all liabilities, claims or demands (including attorney's fees
and costs) arising out of or resulting from damage to such property or improvements.
19.4 USE OF EXPLOSIVES OR HAZARDOUS MATERIALS: When use or storage of explosives
or other hazardous materials or equipment or unusual methods is necessary for execution of the
Work, the CMR shall exercise utmost care and carry on such activities under supervision of
properly qualified personnel. When use or storage of explosives, other hazardous materials or
equipment or unusual methods are necessary, the CMR shall secure the OWNER's approval prior
to their storage or use.
19.5 CMR LIABILITY: The CMR shall promptly remedy damage and loss to any property caused in
whole or in part by the CMR or subcontractor or anyone or by anyone for whose acts they may be
liable.
19.6 SAFETY REPRESENTATIVE: The CMR shall designate a responsible member of the CMR's
organization at the Site whose duty shall be the prevention of accidents and administration of the
CMR's written Safety Program. The Safety Representative, if required by OWNER, shall be
onsite full-time and shall have a minimum of a 10-Hour Occupational Safety and Health Training
Course within the past (2) years and must maintain that competency. This person shall attend all
Project safety meetings and shall conduct regular safety meetings for employees of the CMR and
Subcontractors engaged in construction activities at the Site.
19.7 ACCIDENT REPORTS: The CMR shall report in writing within one (1) working day of the
CMR's knowledge, to the OWNER, all accidents arising out of or in connection with the Work
which cause death, personal injury or property damage, giving full details and statements of any
witnesses. In addition, if death or serious personal injuries or serious damages are caused, the
accident shall be reported immediately by telephone or messenger to the OWNER.
OET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. #34

19.8 SAFETY COOPERATION The CMR and its subcontractors shall cooperate fully with the
OWNER and all interested parties on accident prevention and claim handling procedures.
19.9 RISK OF LOSS: The CMR shall be fully responsible for, and shall bear the full risk of loss of,
all the CMR's tools, equipment, materials, and other property.
19.10 EMERGENCIES:
19.10.1 In an emergency affecting safety of persons or property, the CMR shall act, at the
CMR's discretion, to prevent damage, injury or loss. Additional compensation or
extension of time claimed by the CMR on account of an emergency shall be determined
as provided in Article 7.
ARTICLE 20- PERMITS, LICENSES AND IMPACT FEES
20.1 CMR LICENSE REQUIREMENT:
20.1.1 The CMR shall procure all permits, insurance, licenses for, and pay the charges and fees
necessary and incidental to, the lawful conduct of his/her business, and as necessary
complete any required certification requirements, required by any and all governmental
or non-governmental entities as mandated to maintain compliance with and in good
standing for all permits and/or licenses. The CMR shall keep fully informed of existing
and future trade or industry requirements, Federal, State and Local laws, ordinances, and
regulations which in any manner affect the fulfillment of a Contract and shall comply
with the same. CMR shall immediately notify both Office of Procurement Services and
the using agency of any and all changes concerning permits, insurance or licenses.
20.1.2 CMR and its Subcontactors furnishing finished products, materials or articles of
merchandise that will require installation or attachment as part of the Contract, shall
possess any licenses required. A CMR and its Subcontactors arc not relieved of its
obligation to possess the required licenses by a subcontracting of the labor portion of the
Contract.
ARTICLE 21 - PERSONNEL
21.1 All personnel used or employed by the CMR in the performance of the Work shall be qualified by
training and experience to perform their assigned tasks. At the request of the OWNER, the CMR
shall not use in the performance of the Work any personnel deemed by the OWNER to be
incompetent, careless, or unqualified to perform the work assigned to that person him, or
otherwise unsatisfactory to the OWNER.
21.2 The CMR agrees that in the performance of the Work called for by this Contract, it will employ
only such labor, and engage subcontractors that employ only such labor, as will not delay or
interfere with the speedy and lawful progress of the Project, and as will be acceptable to and work
in harmony with all other workers employed on the Project site or on any other building,
structure, or other improvement which the CMR or any other contractor may then be erecting or
alerting on behalf of the OWNER.
21.3 CMR shall furnish the OWNER on request, resumes of CMR's key personnel involved in the day-
to-day Work on the Project.
OET Zone 2 Refresh Downtown CAIR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. # 35

ARTICLE 22- CMR'S WARRANTIES
22.1 CMR warrants to OWNER that all materials and equipment under this Contract will be new
unless otherwise specified and that all of the Work will be of good quality free from faults and
defects and in conformance with the Contract Documents. All Work not conforming to these
requirements, including substitutions not properly approved and authorized by the PROJECT
MANAGER and DESIGN PROFESSIONAL may be considered defective and shall be repaired
or replaced in accordance with the requirements of this Contract. If required by DESIGN
PROFESSIONAL, CMR shall furnish satisfactory evidence as to the kind and quality of materials
and equipment. This warranty is not limited by the provisions of Article 23 herein.
22.2 The CMR further represents and warrants:
22.2.1. That it is financially solvent, able to pay its debts as they mature, and is possessed of
sufficient working capital to perform this Contract; that is able to furnish the Materials, and
Services; that is experienced in and competent to perform the Work contemplated by this
Contract; and it is qualified to do the Work herein and is authorized to do business in the
State of Arizona.
22.2.2 That the CMR holds a license, permit or other special license to perform the services included
in this Contract, as required by law, or employs or works under the general supervision of the
holder of such license, permit or special license.
22.2.3 The CMR agrees that the Work shall be performed in a good and professional manner, free
from defects in materials and execution, and that all Materials shall be new and approved by
or acceptable to the DESIGN PROFESSIONAL and PROJECT MANAGER, except as
otherwise expressly provided for in the Contract Documents.
22.2.4 That CMR warrants that they will be in compliance with A.R.S. § 23-214(A) and 41-4401.
ARTICLE 23- DEFECTIVE WORK
23.1 PROJECT MANAGER shall have the authority to reject or disapprove work which PROJECT
MANAGER finds to be defective. If required by PROJECT MANAGER, CMR shall promptly
either correct all defective work or remove such defective work and replace it with non-defective
work. CMR shall pay all direct, indirect and consequential costs of such removal or corrections
including cost of testing laboratories and personnel. Such costs shall be included in the GMP.
23.2 Should CMR fail or refuse to remove or correct any defective work or to make any necessary
repairs in accordance with the requirements of the Contract Documents within the time indicated
in writing by PROJECT MANAGER, OWNER shall have the authority to cause the defective
work to be removed or corrected, or make such repairs as may be necessary at CMR`s expense.
Any expense incurred by OWNER in making such removals, corrections or repairs shall be paid
for out of any monies due or which may become due to CMR and deducted from the GMP, or
may be charged against the Performance Bond. In the event of failure of CMR to make all
necessary repairs promptly and fully, OWNER may declare a default.
23.3 If, within two (2) years after the date of Substantial Completion or such longer period of time as
may be prescribed by the terms of any applicable special warranty required by the Contract
Documents, any of the work is found to be defective or not in accordance with the Contract
Documents, CMR, after receipt of written notice from OWNER, shall promptly correct such
defective or nonconforming work within the specified by OWNER without cost to OWNER, to
do so. Nothing contained herein shall be construed to establish a period of limitation with respect
to any other obligation, which CMR might have under the Contract Documents.
OET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. # 36

23.4 Failure to reject any defective work or material shall not in any way prevent later rejection when
such defect is discovered, or obligate OWNER to final acceptance.
23.5 The CMR shall (I) replace any part of the work that fails to conform with the requirements of this
Contract that appear during progress of the work on the Project; (II) remedy any defects in the
Work due to faulty materials or workmanship which appear within a period of two (2) years from
the time of Substantial Completion of the Work or portions thereof hereunder or within such
longer period of time as may be set forth in the Contract Documents or as may be required by
law; and (III) replace, repair or restore any parts of the Project or furniture, fixtures, equipment or
other items placed therein (whether by the OWNER or any other part) that are injured or damaged
by any such parts of the Work that do not conform to the requirements of this Contract or are due
to defects in the Work. The provisions of this Article 23 shall not apply to corrective work
attributable solely to the acts or omissions of any separate CMR or subcontractor of the OWNER
unless the CMR is acting in such capacity or capacities. The cost of the CMR of performing any
of its obligations under this Article 23 shall be within the Guaranteed Maximum Price. The
CMR's responsibility to make repairs and redo work under this Article 23 is in addition to the
CMR's responsibility to the OWNER for any other damages of any kind •for which the CMR
would be legally responsible.
23.6 If the OWNER and the CMR deem it inexpedient to require the correction of work damaged or
not performed in accordance with the Contract Documents, an equitable deduction from the
Contract Price and the Guaranteed Maximum Price shall be made by agreement between the
CMR and the OWNER. Until such settlement, the OWNER may withhold such sums as the
OWNER deems just and reasonable from monies, if any, due the CMR. If no monies are held by
the OWNER, reimbursement shall be made to the OWNER within thirty (30) days by the CMR.
23.7 The CMR's express warranty herein shall be in addition to, and not in lieu of, any other
warranties or remedies the OWNER may have under this Contract, at law, or in equity for
defective Work and warranty periods will commence at Substantial Completion date.
ARTICLE 24- CONSTRUCTION SIGNAGE
24.1 Any requirements for a Project sign shall be as set forth within the Technical Specifications
section.
24.2 All construction signage located at the Project location shall be subject to the prior written
approval of the PROJECT MANAGER. The CMR recognizes that all signage may be disallowed,
in the PROJECT MANAGER's sole discretion, and that existing signage or advertising on
construction field offices, trailers, construction fences, and other construction elements or aids,
may be required to be masked or deleted at no cost or expense to the OWNER. Such signage will
be considered an overhead expense pursuant to Article 8.4 and if allowed shall not be included
within the Cost of the Work.
ARTICLE 25- OWNERSHIP OF CONTRACT DOCUMENTS
25.1 Drawing, specifications, designs, models, photographs, reports, surveys, and other data submitted
by the CMR provided in connection with this Agreement are and shall remain the property of the
OWNER whether the Project for which they are made is completed or not. All finished or
unfinished documents, data, studies, surveys, drawings, maps, models, photographs, and reports
prepared by CMR shall become the property of OWNER and shall be delivered by CMR to
OWNER within seven (7) days of termination of the Contract Documents by either party. Any
compensation due to CMR shall be withheld until all documents are received as provided herein.
OET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. #37

ARTICLE 26- CMR'S REPRESENTATIVE
26.1 CMR shall advise, the OWNER, in writing of any limitations on the authority of CMR's
representative; otherwise, CMR's representative shall be considered to have full authority to
execute any and all instruments requiring the CMR's signature and to act on behalf of the CMR
with respect to all matters arising out of this Agreement.
ARTICLE 27- OWNER'S RIGHT TO TERMINATE CONTRACT
27.1 If CMR fails to begin the Work within the (10) calendar days after the Project initiation Date, or
fails to perform the Work with sufficient workers and equipment or with sufficient materials to
insure the prompt completion of the Work, or performs the Work unsuitably, or causes it to be
rejected as defective and unsuitable, or delays or discontinues the prosecution of the Work
pursuant to the accepted schedule or if CMR shall fail to perform any material term set forth in
the Contract Documents, including non-payment of subcontractors or materials providers, or if
CMR shall become insolvent or be declared bankrupt, or commit any act of bankruptcy or
insolvency, or shall make an assignment for the benefit of creditors, or from any other cause
whatsoever shall not carry on the Work in an acceptable manner, PROJECT MANAGER may
give notice in writing to CMR and its Surety of such delay, neglect or default, specifying the
same.
If CMR, within a period of ten (10) calendar days after such notice, does not proceed in
accordance therewith, then OWNER may terminate the services of CMR, exclude CMR from the
Project site and take the prosecution of the Work out of the hands of CMR, and appropriate or use
any or all materials and equipment that are an integral part of the Work on the Project site as may
be suitable and acceptable. In such case, CMR shall not be entitled to receive any further
payment until the Project is completed.
In addition OWNER, may enter into an agreement for the completion of the Project according to
the terms and provisions of the Contract Documents, or use such other methods as in OWNER'S
sole opinion shall be required for the completion of the Project according to the terms and
provisions of the Contract Documents, or use such other methods as in OWNER'S sole opinion
shall be required for the completion of the Project in an acceptable manner. All damages, costs
and charges incurred by OWNER, together with the costs of completing the Project, shall be
deducted from any monies due or which may become due to CMR. In case the damages and
expenses so incurred by OWNER shall exceed the unpaid balance, then CMR shall be liable and
shall pay to OWNER the amount of said excess.
27.2 If after notice of termination of CMR's right to proceed, it is determined for any reason that CMR
was not in default, the rights and obligations of OWNER and CMR shall be the same as if the
notice of termination had been issued pursuant to the Termination for Convenience clause as set
forth in Article 27.3 below.
27.3 This Contract may be terminated for convenience in writing by OWNER upon ten- (10) day's
written notice to CMR (delivered by certified mail, return receipt requested) of intent to terminate
and the date on which such termination becomes effective. In such case, CMR shall be paid for
all work executed and expenses incurred prior to termination in addition to termination settlement
costs reasonably incurred by CMR relating to commitments which had become firm prior to the
termination. Payment shall include reasonable profit for work and/or services performed. No
payment shall be made for profit for work and/or services that have not been performed.
27.4 Upon receipt of Notice of Termination pursuant to Article 27 or 27.3 above, CMR shall promptly
discontinue all affected work unless the Notice of Termination directs otherwise and deliver or
otherwise make available the OWNER all data, drawings, specifications, reports, estimates,
summaries and such other information as may have been required by the Contract Documents
whether completed or in process.
OET Zone 2 Refresh Downtown CMR Serial # I3152-CMR
Contract between Maricopa County and DPR Construction Pg. # 38

ARTICLE 28- RESOLUTION OF DISPUTES
28.1 To prevent all disputes and litigation, it is agreed by the parties hereto that OWNER shall decide
all questions, claims, difficulties and disputes of whatever nature which may arise relative to the
technical interpretation of the Contract Documents and fulfillment of this Contract as to the
character, quality amount value of any work done and materials furnished, or proposed to be done
or furnished under or by reason of, the Contract Documents and OWNER's estimates and
decisions upon all claims, questions, difficulties and disputes shall be final and binding. Any
claim, question, difficulty or dispute which cannot be resolved by mutual agreement of PROJECT
MANAGER and CMR shall be submitted to the Alternative Dispute Resolution process as
outlined in Exhibit G.
28.2 This Agreement shall be interpreted and construed in accordance with and governed by the laws
of the State of Arizona. Any controversies or legal problems arising out of this Agreement and
any action involving the enforcement or interpretation of any rights hereunder which might be
eligible for judicial resolution shall be submitted to the jurisdiction of the Superior Court of the
State of Arizona in and for Maricopa County, and shall be governed by the laws of the State of
Arizona. By entering into this Contract, CMR and OWNER hereby expressly waive any rights
either party may have to trial by jury of any civil litigation related to, or arising out of the Project.
CMR, pursuant to Article 11 of this Agreement, shall specifically bind all subcontractors to the
provisions of this Contract.
Pending resolution of any dispute arising under this Contract, other than termination hereof, the
CMR shall proceed diligently with performance of this Contract and the OWNER shall continue
to make payments in accordance with the Contract Documents.
ARTICLE 29- NOTICES
29.1 Notices: All notices to be given hereunder shall be in writing, and may be given by depositing
the same in the United States Mail addressed to the party to be notified, postpaid, return receipt
requested or by delivering the same in person to such party with written receipt of
acknowledgement of delivery by a person at the address (s) set forth below. All notices to be
given to the parties hereto shall be sent to or made to the addresses shown below. The place for
giving notice shall remain the same as set forth herein unless changed in the manner provided in
this Article.
Whenever either party desires to give notice to the other, such notice must be in writing, sent by
certified United States mail, postage prepaid, return receipt requested, or by hand-delivery with a
request for a written receipt of acknowledgment of delivery, addressed to the party for whom it is
intended at the place last specified. The place for giving notice shall remain the same as set forth
herein until changed in writing in the manner provided in this section. For the present, the parties
designate the following:
Monica Perrin, Facilities Capital Project Manager
Facilities Management Department
Maricopa County
401 West Jefferson Street
Phoenix, Arizona 85003
OET Zone 2 Refresh Downtown CMR Serial # I3152-CMR
Contract between Maricopa County and DPR Construction Pg. #39

AND
Wes Baysinger, Chief Procurement Officer
Office of Procurement Services
Maricopa County
320 W. Lincoln Street
Phoenix, Arizona 85003
FOR CMR:
David Elrod, Regional Manager
DPR Construction
222 N. 44th Street
Phoenix, Arizona 85003
And to DESIGN PROFESSIONAL:
Jeff Ruthstrom, P.E. Senior Vice President
Pearson Engineering Associates, Inc.
8825 N. 23rd Avenue, Suite 11
Phoenix, Arizona 85003
ARTICLE 30- REQUIREMENTS FOR CONTRACTS WITH SBE GOALS
30.1 It is Maricopa County's policy to provide Small Business Enterprises (SBE) with the opportunity
to participate in the County's solicitation process and to be considered to fulfill the requirements
for various commodities and services. This contract has no requirement for utilization of SBEs,
however it does require that utilization of SBE firms by CMR be reported for tracking by the
County. A full description of the County's SBE program and the contractual requirements are
attached hereto and incorporated herein by reference in Exhibit F.
ARTICLE 31- OTHER TERMS & CONDITIONS
31.1 THIRD PARTY BENEFICIARIES:
Neither CMR nor OWNER intends to directly or substantially benefit a third party by this
Contract. Therefore, the parties agree that there are no third party beneficiaries to this Contract
and that no third party shall be entitled to asset a claim against either of them based upon this
Contract.
31.2 CONFLICTS:
Neither CMR nor its employees shall have or hold any continuing or frequently recurring
employment or contractual relationship that is substantially antagonistic or incompatible with
CMR's loyal and conscientious exercise of judgment related to its performance under this
Agreement.
CMR agrees that none of its officers or employees shall, during the term of this Agreement, serve
as an expert witness against COUNTY in any legal or administrative proceeding in which he or
OET Zone 2 Refresh Downtown CMR Serial # I3152-CMR
Contract between Maricopa County and DPR Construction Pg. # 40

she is not a party, unless compelled by court process. Further, CMR agrees that such persons
shall not give sworn testimony or issue a report or writing, as an expression of his or her expert
opinion, which is adverse or prejudicial to the interests of COUNTY in connection with any such
pending or threatened legal or administrative proceeding. The limitations of this section shall not
preclude CMR or any other persons from representing themselves in any action or in any
administrative or legal proceeding.
In the event CMR is permitted to utilize subcontractor to perform any services required by this
Agreement, CMR agrees to prohibit such subcontractor, by written contract, from having any
conflicts within the meaning of this section.
31.3 CANCELLATION:
The OWNER hereby gives notice that pursuant to A.R.S. § 38-511 (A) this contract may be
canceled without penalty or further obligation within three (3) years after execution if any person
significantly involved in initiating, negotiating, securing, drafting, or creating a contract on behalf
of the OWNER is, at any time while the contract or an extension of the contract is in effect, an
employee or agent of any other part to the contract in any capacity or a consultant to any other
party of the contract with respect to the subject matter of the contract. Cancellation under this
section shall be effective when written notice from the OWNER is received by all parties to the
contract. In addition, the OWNER may recoup any fee or commission paid or due to any person
significantly involved in initiating, negotiating, securing, drafting or creating the contract on
behalf of the OWNER from any other party to the contract arising as a result of the contract.
31.4 COMPLIANCE WITH LAWS:
CMR shall comply with all federal state, and local laws, codes, ordinances, rules, and regulations
in performing its duties, responsibilities, and obligations pursuant to this Agreement.
31.5 SEVERANCE:
In the event a portion of this Agreement is found by a court of competent jurisdiction to be
invalid, the remaining provisions shall continue to be effective unless COUNTY or CMR elects
to terminate this Agreement. An election to terminate this Agreement based upon this provision
shall be made within seven (7) days after the finding by the court becomes final.
31.6 JOINT PREPARATION:
Preparation of this Contract has been a joint effort of OWNER and CMR and the resulting
document shall not, solely as a matter of judicial construction, be construed more severely against
one of the parties than any other.
31.7 DRUG FREE WORKPLACE:
It is a requirement of OWNER that it enter into contracts only with firms that certify the
establishment of a drug-free workplace. Execution of this Contract by CMR shall also serve, as
CMR's required certification that it either has or that it will establish a drug-free workplace.
31.8 ASSIGNMENT:
The CMR shall not assign this Contract or subcontract it as a whole without the written consent
of the OWNER by and through the Chief Procurement Officer for Maricopa County; nor shall the
CMR assign any monies due or to become due to it hereunder, without the previous written
consent of the OWNER.
OET Zone 2 Refresh Downtown CMR Serial #13152 -CMR
Contract between Maricopa County and DPR Construction Pg. # 41

31.9 ASSIGNMENT:
No consent or waiver, express or implied, by either party to this Contract to or of any breach or
default by the other in the performance of any obligations hereunder shall be deemed or construed
to be a consent or waiver to or of any other of future breach or default by such party hereunder,
nor deemed to be a modification of this Contract.
Failure on the part of any party hereto to complain of any act or failure to act of the other party or
to declare the other party in default hereunder, irrespective of how long such failure continues,
shall not constitute a waiver of the rights of such party hereunder, provided however this section
shall not alter or amend the notice provisions set forth in the Construction Documents including
but not limited to, in Article 6. Inspection by, payment by or tentative approval or acceptance by
the OWNER, or the failure of the OWNER to perform any inspection hereunder shall not
constitute a final acceptance of the Work or any part thereof and shall not release the CMR from
any of its obligations hereunder.
31.10 CONSTRUCTION OF TERMS:
Unless the context clearly intends to the contrary, words singular or plural in number shall be
deemed to include the other and pronouns having masculine or feminine gender shall be deemed
to include the other. The term "person" shall be deemed to include an individual, corporation,
unincorporated organization, partnership, trust, government and governmental agency or
subdivision, as the context shall require.
31.11 CAPTIONS:
The captions used for the Articles of this Contract are inserted only as a matter of convenience
and for reference and in no way define, limit or describe the scope of the intent of this Contract or
any Article hereof.
31.12 ENTIRE AGREEMENT; SEVERABILITY; AMENDMENTS:
These Contract Documents incorporate and include all prior negotiations, correspondence,
conversations, agreements, and understandings applicable to the matters contained herein and the
parties agree that there are no commitments, agreements or understanding concerning the subject
matter of this Contract that are not contained in the Contract Documents. Accordingly, the
parties agree that no deviation from the terms hereof shall be predicated upon any prior
representations or agreements, whether oral or written. It is further agreed that no modification,
amendment or alteration in the terms or conditions contained herein shall be effective unless
contained in a written document in accordance with Article 7. In the event any provision of the
Contract Documents shall be found by a court of competent jurisdiction to be invalid or otherwise
unenforceable, the remainder of this Contract shall not be affected thereby and each remaining
provision, term, covenant or condition of the Contract Documents shall continue to be effective.
31.13 PRIOR AGREEMENTS:
This document incorporates and includes all prior negotiations, correspondence, conversations,
agreements, and understandings applicable to the matters contained herein and the parties agree
that there are no commitments, agreements or understandings concerning the subject matter of
this Agreement that are not contained in this document. Accordingly, the parties agree that no
deviation from the terms hereof shall be predicated upon any prior representations or agreements,
whether oral or written. It is further agreed that no modification, amendment or alteration in the
terms or conditions contained herein shall be effective unless set forth in writing in accordance
with Article 7 of this document.
OET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. # 42

31.14 INCORPORATION BY REFERENCE:
The truth and accuracy of each "Whereas" clause set forth herein is acknowledged by the parties.
The attached Exhibits are incorporated into and made a part of this Agreement.
31.15 LEGAL WORKER REQUIREMENTS:
As required by Arizona Revised Statutes §41-4401, the County is prohibited after September 30,
2008 from awarding a contract to any service or construction CMR who fails, or whose
subcontractors fail, to comply with Arizona Revised Statutes § 23-214-A. The CMR warrants
that it complies fully with all federal immigration laws and regulations that relate to its
employees, that it shall verify, through the employment verification pilot program as jointly
administered by the U.S. Department of Homeland Security and the Social Security
Administration or any of its successor programs, the employment eligibility of each employee
hired after December 31, 2007, and that it shall require its subcontractors and sub-subcontractors
to provide the same warranties to the CMR. The CMR acknowledges that a breach of this
warranty by CMR or by any subcontractor or sub-subcontractor under this Contract shall be
deemed a material breach of this Contract, and is grounds for penalties, including termination of
this Contract, by Maricopa County. Maricopa County retains the right to inspect the records of
any CMR, subcontractor and sub-subcontractor employee who performs work under this
Contract, and to conduct random verification of the employment records of the CMR and any
subcontractor and sub-subcontractor who works on this Contract, to ensure that the CMR and
each subcontractor and sub-subcontractors complying with the warranties set forth above. CMR
shall be responsible for all costs associated with compliance with this requirement.
31.16 CERTIFICATION REGARDING DEBARMENT AND SUSPENSION:
31.16.1 The undersigned (authorized official signing for the CMR) certifies to the best of his or
her knowledge and belief, that the CMR, defined as the primary participant in
accordance with 45 CFR Part 76, and its principals:
31.16.1.1 are not presently debarred, suspended, proposed for debarment, declared
ineligible, or voluntarily excluded from covered transactions by any Federal
Department or agency;
31.16.1.2 have not within 3-year period preceding this Contract been convicted of or
had a civil judgment rendered against them for commission of fraud or a
criminal offense in connection with obtaining, attempting to obtain, or
performing a public (Federal, State or local) transaction or contract under a
public transaction; violation of Federal or State antitrust statues or
commission of embezzlement, theft, forgery, bribery, falsification or
destruction of records, making false statements, or receiving stolen property;
31.16.1.3 are not presently indicted or otherwise criminally or civilly charged by a
government entity (Federal, State or local) with commission of any of the
offenses enumerated in paragraph (2) of this certification; and
31.16.1.4 have not within a 3-year period preceding this Contract had one or more
public transaction (Federal, State or local) terminated for cause of default.
31.16.2 Should the CMR not be able to provide this certification, an explanation as to why
should be attached to the Contact.
OET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. # 43

31.16.3 The CMR agrees to include, without modification, this clause in all lower tier covered
transactions (i.e. transactions with subcontractors) and in all solicitations for lower tier
covered transactions related to this Contract.
31.17 INFLUENCE:
31.17.1 As prescribed in MC1-1202 of the Maricopa County Procurement Code, any effort to
influence an employee or agent to breach the Maricopa County Ethical Code of
Conduct or any ethical conduct, may be grounds for Debarment or Suspension under
MC1-902. An attempt to influence includes, but is not limited to:
31.17.1.1 A Person offering or providing a gratuity, gift, tip, present, donation, money,
entertainment or educational passes or tickets, or any type valuable
contribution or subsidy,
31.17.1.2 That is offered or given with the intent to influence a decision, obtain a
contract, garner favorable treatment, or gain favorable consideration of any
kind.
31.17.2 If a Person attempts to influence any employee or agent of Maricopa County, the Chief
Procurement Officer, or his designee, reserves the right to seek any remedy provided
by the Maricopa County Procurement Code, any remedy in equity or in the law, or any
remedy provided by this contract
31.18 AMENDMENTS:
All amendments to this Contract shall be in writing and approved/signed by both parties.
Maricopa County Office of Procurement Services shall be responsible for approving all amendments for
Maricopa County.
[SIGNATURES ON FOLLOWING PAGE]
GET Zone 2 Refresh Downtown CMR Serial # I3152-CMR
Contract between Maricopa County and DPR Construction Pg. # 44

IN WITNESS WHEREOF, the parties hereto have executed this Agreement on the day and date first above written,
in counterparts, each of which shall, without proof or accounting for the other counterparts, be deemed an original
contract.
OET Zone 2 Refresh Downtown CMR
13152-CMR
PrinMar(Signature)/ Date
David Elrod 27-0853429
Printed Name Federal Tax Identification Number
Regional Manager 271230
Title Arizona CMR's License Number
Net 30 92544
Vendor Terms NIGP Commodity Code (Advantage)
COUNTY OF MARICOPA, ARIZONA
RECOMMENDED BY: ACCEPTED AND APPROVED:
Department Head Date Chairman, Board of Supervisors Date
ATTEST:
Clerk of the Board Date
LEGAL REVIEW
Approved as to form and within the powers
and authority granted under the laws of the
State of Arizona to Maricopa County.
By:
Attorney for the Board of Supervisors
Date:
OET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. # 45

ATTACHMENT A
[General Condition Costs, Key Personnel and Labor Rates per Section 8.3.2.]
GET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. # 46

ATTACHMENT A BILLABLE RATE SCHEDULE
CONTRACTOR'S FIXED RATES
TO THE AGREEMENT BETWEEN
MARICOPA COUNTY AND
DPR CONSTRUCTION, A GENERAL PARTNERSHIP
This Attachment is incorporated into the above referenced Agreement between the parties, as the parties desire
to amend said document. In the event of any conflict, inconsistency or ambiguity between the terms and
provisions of this Attachment and those of the above referenced Agreement between the parties, this
Attachment shall govern.
Labor Rates - 1/1/14 - 12/31/14
Classification Rates Overtime Rates Double-time
Rates
Principal 155.00 n/a n/a
Project Executive 135.00 n/a n/a
Preconstruction Manager 115.00 n/a n/a
Senior Estimator 105.00 n/a n/a
Estimator 90.00 n/a n/a
Estimating Assistant 55.00 n/a n/a
MEP Estimator/Coordinator 95.00 n/a n/a
Senior Project Manager 115.00 n/a n/a
Project Manager 90.00 n/a n/a
Senior Project Engineer 75.00 n/a n/a
Project Engineer 65.00 n/a n/a
Senior MEP Coordinator 105.00 n/a n/a
Senior Project Accountant 65.00 n/a n/a
Project Accountant 55.00 55.00 55.00
Senior Field Office Coordinator n/a n/a n/a
Field Office Coordinator 50.00 50.00 50.00
Senior Information Tech n/a n/a n/a
Information Systems Personnel n/a n/a n/a
Safety Manager 80.00 n/a n/a
General Superintendent 90.00 n/a n/a
Senior Superintendent 110.00 n/a n/a
Superintendent 90.00 n/a n/a
Assistant Superintendent 70.00 n/a n/a
Safety Coordinator 65.00 n/a n/a
Courier n/a n/a n/a
BIM Manager 80.00 n/a n/a
BIM Engineer 65.00 n/a nIa
BIM Draftsperson 58.50 81.10 89.36
Cement Finisher Foreman 55.00 73.48 90.83
Cement Finisher 52.00 73.28 87.34
Carpenter General Foreman 66.00 88.13 97.42
Carpenter Foreman 58.50 81.10 89.36
Carpenter/Carpenter Assistant 51.50 71.56 83.74
Taper Foreman 58.50 79.58 94.77
Taper 51.50 69.36 81.15
Labor Foreman 50.00 68.34 85.58
Laborer/Carpenter Craft Assistant 41.00 55.65 53.53

The rates defined in this Attachment are fixed as stipulated rates by agreement of the Owner and Contractor.
Notwithstanding any language in the Contract Documents to the contrary, these fixed rates shall, when multiplied
by actual, allowable units, constitute Cost of the Work, as that term is used in the Contract Documents, to
calculate Contractor's Contract compensation and/or Change Order pricing for each Labor, Equipment,
Insurance and Bond classification item listed. Owner agrees to compensate Contractor solely in accordance
with these fixed rates. Where Owner has the right under the Contract Documents to audit Contractor's costs,
such right with respect to these fixed rates shall be limited to auditing the quantity of allowable units, multiplied by
the fixed rates defined herein, and shall not include items of cost within the fixed rates.
-END OF ATTACHMENT A -

EXHIBIT A - CONSTRUCTION DOCUMENTS
a. Drawings & Plans dated: January 23, 2014
b. Specifications dated: January 30, 2014
These documents are voluminous and maintained separately from the contract documents but are
incorporated into the contract as though fully set forth and attached.
OET Zone 2 Refresh Downtown CMR Serial # I 3152-CMR
Contract between Maricopa County and DPR Construction Pg. # 47

EXHIBIT B - GMP PROPOSAL
(GMP Summary Document follows — full proposal is found in the Project file and is incorporated into the
contract as though fully set forth and attached)
OET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. # 48

1/31/14
Exhibit B GMP Summary
Maricopa County OET Zone 2 Refresh
DPR Construction
a. Construction $1,740,972
b. General Conditions $452,045
C. Construction (OWNER) Contingnecy $68,149
d. CMR's Fee $98,271
e. CMR's Overhead with line b
f. Bonds $43,860
g. Builder's Risk Insurance $6,711
h. General Liability Insurance $28,045
Taxes $131,533
TOTAL GMP (ALL INCLUSIVE) $2,569,586

EXHIBIT C - INSURANCE CERTIFICATE(S)
The Insurance Certificate document(s) follow this cover page and are incorporated into the contract as
though fully set forth therein.
OET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. # 49

DPRCONS-01 ESPINESENMI
J4CC:01?1:3' DATE (MM/DDIYYYY)
CERTIFICATE OF LIABILITY INSURANCE
44traissioI---- 2/3/2014
THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS
CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES
BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED
REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER.
IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to
the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the
certificate holder in lieu of such endorsement(s).
r PRODUCER CONTACT
NAME:
Willis Insurance Services of California, Inc. PHONE (877) 945-7378 ra, No): (888) 467 -2378
c/o 26 Century Blvd. , E-MAIL- c,W.ggii
P.O. Box 305191 ADDRESS:
Nashville, TN 37230-5191 INSURER(S) AFFORDING COVERAGE NAIC 0
,---. INSURER A : National Union Fire Insurance Company of Pittsbu 19445
INSURED INSURER B : Insurance Company of the State of Pennsylvania 19429
DPR Construction, A General Partnership INSURER C:
222 North 44th Street INSURER D:
Phoenix, AZ 85034 INSURER B:
INSURER F:
COVERAGES CERTIFICATE NUMBER: REVISION NUMBER:
THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD
INDICATED, NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS
CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
INSR LTR I I TYPE OF INSURANCE ADDL INSR SUBRI WVD ' POLICY NUMBER IPF I (MM/DD/YYYY)IMM/DD/YYYY) CY EXP LIMITS
GENERAL LIABILITY , • EACH OCCURRENCE $ 2,000,000
A X COMMERCIAL GENERAL LIABILITY X X GL 5142588 9/1/2013 9/1/2014 —DANAAGE PREMISES TD (Ea R occurrence) .N -rED 2,000,000
1 CLAIMS-MADE x] OCCUR MED EXP (Any one person) 10,000
PERSONAL & ADV INJURY 2,000,000
X SIR -$250,000 GENERAL AGGREGATE $ 4,000,000
GEN'L AGGREGATE LIMIT APPLIES PER: PRODUCTS - COMP/OP AGO $ 4,000,000
POLICY n JECT PRO- LL $
AUTOMOBILE LIABILITY COMBINED (Ea accident) SINGLE LIMIT 2,000,000
A , X 1 ANY AUTO X X 3275252 9/1/2013 9/1/2014 BODILY INJURY (Per person)
rti ALL OWNED --1 SCHEDULED BODILY INJURY (Per accident) $
i t AUTOS i AUTOS
1 HIRED AUTOS • 1 1 i 1 AUTOS NON-OWNED _TER PROPERTY ACCIDENT) DAMAGE $
tii 1 r- ---I
I 1 Comp/Coll-ded $ 1,000
UMBRELLA LIAB X OCCUR EACH OCCURRENCE 25,000,000
A x EXCESS LIAB CLAIMS-MADE BE 11665545 9/1/2013 9/1/2014 AGGREGATE 25,000,000
DED RETENTION $ $
WORKERS AND EMPLOYERS' COMPENSATION LIABILITY X T\ laM1AFITE I 0ETR-1
B ANY PROPRIETOR/PARTNER/EXECUTIVE YIN ---- WC 015 65 5970 9/1/2013 9/1/2014 E.L. EACH ACCIDENT $ 1,000,000
OFFICER/MEMBER EXCLUDED? N NIA
(Mandatory in NH) E.L. DISEASE - EA EMPLOYEE $ 1,000,000
i DESCRIPTION If yes, describe under OF OPERATIONS below EL. DISEASE-POLICY LIMIT $ 1,000,000
,.. .,_.
DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (Attach ACORD 101, Additional Remarks Schedule, if more space is required)
RE: DPR Job #D2-A13076-00; OET Zone 2 Refresh Downtown CMR .
It is agreed that Maricopa County, Arizona, Pearson Engineering and Arrington Watkins are named as Additional Insureds as respects to General Liability and
Auto Liability where required by written contract.
It is understood and agreed that this insurance is primary and any other insurance maintained by the additional insured shall be excess only and not
contributing with this insurance where required by written contract.
SEE ATTACHED ACORD 101
CERTIFICATE HOLDER CANCELLATION
SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE
THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN
ACCORDANCE WITH THE POLICY PROVISIONS.
Maricopa County, Arizona AUTHORIZED REPRESENTATIVE
ATTN: Paul Shamrock
320 W. Lincoln St.
phoenix, AZ 85003
@ 1988-2010 ACORD CORPORATION. All rights reserved.
ACORD 25 (2010105) The ACORD name and logo are registered marks of ACORD

AGENCY CUSTOMER ID: DPRCONS-01 ESPINESENMI
LOC #:
ACC)RD
ADDITIONAL REMARKS SCHEDULE Page 1 of 1
AGENCY NAMED INSURED
DPR Construction, A General Partnership
Willis Insurance Services of California, Inc. 222 North 44th Street
POLICY NUMBER Phoenix, AZ 85034
SEE PAGE 1
—
CARRIER NAIC CODE
SEE PAGE 1 1SEE P 1 EFFECTIVE DATE: SEE PAGE 1
ADDITIONAL REMARKS
THIS ADDITIONAL REMARKS FORM IS A SCHEDULE TO ACORD FORM,
FORM NUMBER: ACORD 25 FORM TITLE: Certificate of Liability Insurance
Description of Operations/LocationsNehicles:
Waiver of Subrogation applies in favor of Maricopa County, Arizona, Pearson Engineering and Arrington Watkins with respects to
General Liability and Auto Liability, where required by written contract.
ACORD 101 (2008/01) © 2008 ACORD CORPORATION. All rights reserved.
The ACORD name and logo are registered marks of ACORD

THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY.
ENDORSEMENT
This endorsement, effective 12:01 A.M. 09/01/2013 forms a part of
Policy No. GL5142588 issued to DPR Construction, A General Partnership
By National Union Fire Ins Co of Pittsburgh PA
ADDITIONAL INSURED- OWNERS, LESSEES, OR CONTRACTORS - COMPLETED
OPERATIONS
This endorsement modifies insurance provided under the following:
COMMERCIAL GENERAL LIABILITY COVERAGE FORM
SCHEDULE
NAME OF ADDITIONAL INSURED PERSON OR ORGANIZATION:
WHERE REQUIRED BY WRITTEN CONTRACT
LOCATION AND DESCRIPTION OF COMPLETED OPERATIONS:
ADDITIONAL PREMIUM:
(If No entry appears above, information required to complete this endorsement will be shown
in the Declarations as applicable to the endorsement.)
SECTION II - WHO IS AN INSURED is amended to include as an insured;
The person or organization shown in the Schedule, but only with respect to liability
arising out of "your work" at the location designated and described in the schedule of
this endorsement performed for that additional insured and included in the "products-
completed operations hazard".
All other terms and conditions remain unchanged.
AUTHORIZED REPRESENTATIVE
97837 (4/08) Includes copyrighted material of
Insurance Services Office, Inc., with its permission.

ENDORSEMENT
This endorsement, effective 12:01 A.M. 09/01/2013
forms a part of Policy No. GL5142588 issued to DPR Construction, A General Partnership
by National Union Fire Ins Co of Pittsburgh
THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY.
ADDITIONAL INSURED- OWNERS, LESSEES, OR CONTRACTORS -
SCHEDULED PERSON OR ORGANIZATION
This endorsement modifies insurance provided under the following:
COMMERCIAL GENERAL LIABILITY COVERAGE FORM
SCHEDULE
NAME OF PERSON OR ORGANIZATION: WHERE REQUIRED BY WRITTEN CONTRACT
(If No entry appears above, information required to complete this endorsement will be shown in the
Declarations as applicable to the endorsement.)
A. SECTION II - WHO IS AN INSURED is amended to include as an insured;
The person or organization shown in the Schedule, but only with respect to liability arising
out of your ongoing operations performed for that additional insured.
B. With respect to the insurance afforded to these additional insureds, SECTION I -
COVERAGES, COVERAGE A - BODILY INJURY AND PROPERTY DAMAGE LIABILITY, 2. -
Exclusions, is amended to include the following additional exclusion;
This insurance does not apply to "bodily injury" or "property damage" occurring after:
(1) all work, including materials, parts or equipment furnished in connection with such
work, on the project (other than service, maintenance or repairs) to be performed by
or on behalf of the additional insured(s) at the site of the covered operations has been
completed; or,
(2) that portion of "your work" out of which the injury or damage arises has been put to its
intended use by any person or organization other than another contractor or
subcontractor engaged in performing operations for a principal as a part of the same
project.
All other terms and conditions remain unchanged.
AUTHORIZED REPRESENTATIVE
97838 (4/08) Includes copyrighted material of
Insurance Services Office, Inc., with its permission.

THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY.
This endorsement, effective 12:01 A. M. 09/01/2013 forms part of Policy No. GL5142588
issued to DPR CONSTRUCTION, A GENERAL PARTNERSHIP
by NATIONAL UNION FIRE INSURANCE CO. OF PITTSBURGH PA
PRIMARY COVERAGE FOR SPECIFIED PERSONS OR ORGANIZATIONS
NAMED AS ADDITIONAL INSUREDS -
ONGOING AND COMPLETED OPERATIONS
This endorsement modifies insurance provided under the following:
COMMERCIAL GENERAL LIABILITY COVERAGE FORM
The following paragraph is added to SECTION II - WHO IS AN INSURED and applies only to
persons or organizations we have added to your policy as additional insureds by endorsement to
comply with insurance requirements of written contracts relative to: a) the performance of
your ongoing operations for the additional insureds; or b) "your work" performed for the
additional insureds and included in the "products-completed operations hazard:
This insurance is primary over any similar insurance available to any person or organization we
have added to this policy as an additional insured. However, this insurance is primary over any
other similar insurance only if the additional insured is designated as a named insured in the
Declarations of the other similar insurance. We will not require contribution of limits from the
other similar insurance if the insurance afforded by this endorsement is primary.
This insurance is excess over any other valid and collectible insurance, whether primary,
excess, contingent or on any other basis, if it is not primary as defined in the paragraph above.
All other terms and conditions of the policy are the same.
Authorized Representative
Page 1 of 1
90533 (3/06)

POLICY NUMBER: GL5142588 COMMERCIAL GENERAL LIABILITY
CG 24 04 05 09
WAIVER OF TRANSFER OF RIGHTS OF RECOVERY
AGAINST OTHERS TO US
This endorsement modifies insurance provided under the following:
COMMERCIAL GENERAL LIABILITY COVERAGE PART
PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART
SCHEDULE
Name Of Person Or Organization:
WHERE REQUIRED BY WRITTEN CONTRACT
Information required to complete this Schedule, if not shown above, will be shown in the Declarations.
The following is added to Paragraph 8. Transfer Of
Rights Of Recovery Against Others To Us of
Section IV — Conditions:
We waive any right of recovery we may have against
the person or organization shown in the Schedule
above because of payments we make for injury or
damage arising out of your ongoing operations or
"your work" done under a contract with that person
or organization and included in the "products-
completed operations hazard". This waiver applies
only to the person or organization shown in the
Schedule above.
CG 24 04 05 09 0 Insurance Services Office, Inc., 2008 Page 1 of 1

THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY.
ENDORSEMENT #
This endorsement, effective 12:01 A.M. 09/01/2013 forms a part of
Policy No. 3275252 issued to DPR CONSTRUCTION, A GENERAL PARTNERSHIP
By NATIONAL UNION FIRE INSURANCE COMPANY OF PITTSBURGH, PA
ADDITIONAL INSURED - WHERE REQUIRED UNDER CONTRACT OR
AGREEMENT
This endorsement modifies insurance provided under the following:
BUSINESS AUTO COVERAGE FORM
SCHEDULE
ADDITIONAL INSURED:
ANY PERSON OR ORGANIZATION FOR WHOM YOU ARE CONTRACTUALLY BOUND
TO PROVIDE ADDITIONAL INSURED STATUS BUT ONLY TO THE EXTEND OF SUCH
PERSON OR ORGANIZATIONS LIABILITY ARISING OUT OF THE USE OF COVERED
"AUTO"
I. SECTION II - LIABILITY COVERAGE, A. Coverage, 1. — Who Is Insured, is amended
to add:
d. Any person or organization, shown in the schedule above, to whom you become
obligated to include as an additional insured under this policy, as a result of any contract
or agreement you enter into which requires you to furnish insurance to that person or
organization of the type provided by this policy, but only with respect to liability arising
out of use of a covered "auto". However, the insurance provided will not exceed the
lesser of:
(1) The coverage and/or limits of this policy, or
(2) The coverage and/or limits required by said contract or agreement.
AUTHORIZED REPRESENTATIVE
87950 (10/05)

THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT
CAREFULLY.
ENDORSEMENT #
Insurance Primary as to Certain Additional Insureds
This endorsement, effective 12:01 A.M. 09/01/2013 forms a part of
Policy No. 3275252
issued to DPR CONSTRUCTION, A GENERAL PARTNERSHIP
by NATIONAL UNION FIRE INSURANCE COMPANY OF PITTSBURGH, PA
This endorsement modifies insurance provided under the o owing:
BUSINESS AUTO COVERAGE FORM
Section IV - Business Auto Conditions, B., General Conditions, 5., Other Insurance, c., is
amended by the addition of the following sentence:
The insurance afforded under this policy to an additional insured will apply as primary
insurance for such additional insured where so required under an agreement executed prior
to the date of accident. We will not ask any insurer that has issued other insurance to such
additional insured to contribute to the settlement of loss arising out of such accident.
All other terms and conditions remain unchanged.
AUTHORIZED REPRESENTATIVE
74445 (10-99)

THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY.
ENDORSEMENT
This endorsement, effective 12:01 A.M. 09/01/2013 forms a part of
Policy No. 3275252 issued to DPR CONSTRUCTION, A GENERAL PARTNERSHIP
By NATIONAL UNION FIRE INSURANCE COMPANY OF PITTSBURGH, PA
WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US
This endorsement modifies insurance provided under the following:
BUSINESS AUTO COVERAGE FORM
Section IV - Business Auto Conditions, A. - Loss Conditions, 5. - Transfer of Rights of Recovery
Against Others to Us, is amended to add:
However, we will waive any right of recovery we have against any person or organization with whom you
have entered into a contract or agreement because of payments we make under this Coverage Form arising
out of an "accident" or "loss" if:
(1) The "accident" or "loss" is due to operations undertaken in accordance with the contract existing
between you and such person or organization; and
(2) The contract or agreement was entered into prior to any "accident" or "loss".
No waiver of the right of recovery will directly or indirectly apply to your employees or employees of the
person or organization, and we reserve our rights or lien to be reimbursed from any recovered funds
obtained by any injured employee.
AUTHORIZED REPRESENTATIVE
62897 (6/95)

EXHIBIT D - PAYMENT BOND
(Document follows and is incorporated into the contract as though fully set forth therein.)
OET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. # 50

STATUTORY PAYMENT BOND
PURSUANTTO TITLE 34 CHAPTER 2, ARTICLE 2 OF THE ARIZONA REVISED STATUTES
(Penalty of this bond must be 100% of the contract amount)
KNOWALL MEN BY THESE PRESENTS:
That, DPR Construction, A General Partnership (hereinafter called the Principal), as Principal, and the
Liberty Mutual Insurance Company, Continental Casualty Company and Fidelity and Deposit
Company of Maryland, a corporation duly organized under the laws of the States of
Massachusetts, Illinois and Maryland , with its principal office in the City of Boston, Chicago and
Schaumburg, IL respectively (hereinafter called the Surety), as Surety are held and firmly bound unto
Maricopa County (hereinafter called the Obligee), in the amount of Two Million Five Hundred
Sixty Nine Thousand Five Hundred Eighty Five Dollars and No/100
($ 2,569,585.00) for the paymentwhereof, the said Principal and Surety, bind themselves, and their heirs, administrators,
executors, successors and assigns,jointly and severally, firmly by these presents.
WHEREAS, the Principal has entered into a certain written contract with the Obligee, dated the _
27 day of January, 2014
to construct OET Zone 2 Refresh Downtown CMR, Serial No. 13152.CMR, which contract is hereby referred to and made a
part hereof as fully and to the same extent as if copied at length herein.
NOW, THEREFORE, THE CONDITION OF THE OBLIGATION IS SUCH, that if the Principal faithfully performs and
fulfills all of the undertaking, covenants, terms, conditions, and agreements of the contract during the original term of the contract
and any extension of the contract with or without notice to the Surety, and during the life of any guaranty required under the
contract, and also performs and fulfills all the undertakings, covenants, terms, conditions, and agreements of all duly authorized
modifications of the contract that may hereafter be made, notice of which modifications to the Surety being hereby waived, the
above obligation is void. Otherwise it remains in full force and effect.
PROVIDED, HOWEVER, that this bond is executed pursuant to the provisions of Title 34, Chapter 2, Article 2, Arizona
Revised Statutes, and all liabilities on this bond shall be determined in accordance with the provisions of Title 34, Chapter 2,
Article 2, Arizona Revised Statutes to the same extent as if it were copied at length in this agreement.
The prevailing party in a suit on this bond shall be entitled as part of the judgment reasonable attorney's fees as may
be fixed by the judge of the court.
Witness our hands this 31st day of January , 2014.
Willis of AZ, Inc.
AGENCY OF RECORD, STATE OF ARIZONA PRINCIPAL: DPR Construction, A General Partnership
16220 North Scottsdale Road, Suite 600
Scottsdale, AZ 85254
BY:
TITLE: Michele Le iva CFO —
AGENCY ADDRESS
Surety: Liberty Mutual Insurance Company,
Continental Casualty Company
Fidelity & Deposit Company of Maryland
BY:
TITLE: Cy hia M. Partin — Attorney-in-Fact
BOND NUMBER, ATTACH SURETY OF POWER OF ATTORNEY
018030327, 929581486, 09082743
OET Zone 2 Refresh Downtown l-1V1R
Construction Manager at Risk Serial #13152-CMI?

EXHIBIT E - PERFORMANCE BOND
(Document follows and is incorporated into the contract as though fully set forth therein.)
OET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. #51

STATUTORY PERFORMANCE BOND
PURSUANT TO TITLE 34, CHAPTER 2, ARTICLE 2, OF THE ARIZONA REVISED STATUTES
(Penalty of this bond must be 100% of the contract amount)
KNO WALL MEN BY THESE PRESENTS:
That, DPR Construction, A General Partnership (hereinafter called the Principal), as Principal, and the
Liberty Mutual Insurance Company, Continental Casualty Company, Fidelity & Deposit Company of Maryland, a
corporation duly organized under the laws of the State of Massachusetts, Illinois & Maryland, with
its principal office in the City of Boston, Chicago and Schaumburg, IL respectively hereinafter called the Surety),
as Surety are held and firmly bound unto Maricopa County (hereinafter called the Obligee),
in the amount of Two Million Five Hundred Sixty Nine Thousand Five Hundred Eighty Five Dollars and
No/100 ($ 2569,58500) for the payment whereof, the said Principal and Surety bind themselves, and their heirs,
administrators, executors, successors and assigns,jointly and severally, firmly by these presents.
WHEREAS, the Principal has entered into a certain written contract with the Obligee, dated the _27 th day of January,
2014
, to construct OET Zone 2 Refresh Downtown CMR, Serial No. 13152.CMR, which contract is hereby
referred to and made a part hereof as fully and to the same extent as if copied at length herein.
NOW, THEREFORE, THE CONDITION OF THE OBLIGATION IS SUCH, that if the Principal faithfully performs and
fulfills all of the undertaking, covenants, terms, conditions, and agreements of the contract during the original term of the
contract and any extension of the contract with or without notice to the Surety, and during the life of any guaranty required
under the contract, and also performs and fulfills all the undertakings, covenants, terms, conditions, and agreements of all duly
authorized modifications of the contract that may hereafter be made, notice of which modifications to the Surety being hereby
waived, the above obligation is void. Otherwise it remains in full force and effect.
PROVIDED, HOWEVER, that this bond is executed pursuant to the provisions of Title 34, Chapter 2, Article
2, Arizona Revised Statutes, and all liabilities on this bond shall be determined in accordance with the provisions of
Title 34, Chapter 2, Article 2, Arizona Revised Statutes to the extent as if it were copied at length in this agreement.
The prevailing party in a suit on this bond shall be entitled as part of the judgment reasonable attorney's fees as may
be fixed by the judge of the court.
Witness our hands this 31st ,dayof January , 2014.
AGENCY OF RECORD, STATE OF ARIZONA PRINCIPAL DPR Construction, A General Partnership
Willis of AZ, Inc.
16220 North Scottsdale Road, Suite 600
Scottsdale, AZ 85254
TITLE: Michele Le iva CFO
AGENCY ADDRESS
Liberty Mutual Insurance Company
Continental Casualty Company
Fidelity & Deposit Company of Maryland —
Surety
BY:
TITLE: Cynthia M. Partin – Attorney-in-Fact
BOND NUMBER
018030327, 929581486, 09082743 ATTACH SURETY POWER OF ATTORNEY
OET Zone 2 Refresh Downtown CAIR
Construction Manager at Risk Serial #J 3152-CMR

THIS POWER OF ATTORNEY IS NOT VALID UNLESS ii IS PRINTED ON RED BACKGROUND.
This Power of Attorney limits the acts of those named herein and they have no authority to bind the Company except in the mariner and to the extent herein stated.
Certificsee No. 6073036
American Fire and Casuaity Company Liberty Mutuai Ensurance Company
The Ohio Casualty Insurance Company West American Insurance ;Company
POWER OF ATTORNEY .
KNCYWN ALL PERSONEr. BY THESE PRESENTS: That American Fire & Casualty Company anc The Ohio Casualty Insurance Company arecorporations duly organized under the laws of
the State of Nes Hampshire. that Liberty Mutual Insure:acts Company is a ccrrporaton duly organized an der the laws of the State of Massachusetts. and West American Insurance Company'
is a corpGraticAl duly Grgai -,Izec, under the laws of the State of indiana (herein collective:1y ca. ad the -Campaniesl. pursuant to and by authority' herein set forth, does hereby name, constitute r
and appoint Brad Lorenzetti; Cynthia M. Partin: Heidi K. Harrell: dames M. Maloney; Pamela Brandt: Rebecca E. Cano
all of the city of Columbia , state of SO each individually if there be more than one named, Its true and lawful attorney-fir-Luc:11c make, execute, seal, acknowledge
and deliver, for and on its behalf as surety'[Id a- its ert and deed, any and all undertakings, bonds, recognizances and other surety obligatior e in pursuance of these presents and shall
be as binding upon the Companies as if "-Pen duly signer: l)y the president and attested by the secretary of the Companies in their own proper persons.
IN WITNESS WHEREOF, this Rowe' of Ad lee Libe n b cri ay an authorized officer or official of the Companies and the corporate seals of the Companies have been affixed
tteretcr this 1C1 I day of ApPI
American Fire arid Casualty Company
The Ohio CasLialty Insurance Company
Liberty Mutual Insurance Company
West American Ir[surance Company
By:
STATE OF vlIASHINGTON Gregor:, ienpor. ssistant Sec mi -zary
COUNTY OF KING
On thie 10th dgy of iggril . 2013 . before in personally appeared Crergory W. Davenport. who acknowledged himself to be the Assistant Secretary of American
Fire and Ceasualty C.)mpaily, Liberty Mutual Insurance Company, The Ohio Casualty Company, and West American Insurance Company, and that he such, being authorized so to clo,
ezei.t.te the Memcmi nstruntent for the purposes therm n contairrod by signing on behalf of the corporations by himself as a duly authorized officer.
WITNESf.-.: WHEREOF, I have hereunto subscribed my name and affixed my notarial seal at Seattle, Washirlgton, on the'dayand year first written.
Thrt Power of Attorney is made end executed pursuant to end by authority r)f the following By-laws ails Authorizations of American Fire and Casualty Company, The Ohre Castialtylnistirance
O 4-, Company, Liberty Mutual Insurance Company. and Wt. st American Insurance Comp ony which resolutions are now in full force end effect reading as follows:
0) Ut
at 0 ARTICLE IV -- OFFICERS -- Set Hon 12. Power of ;Biome AI T:/ C:'1U r or other official of the Corpomtion authorized for that purec se in writiilg hy the Chairman or the President, and subject
to :such limitat.on as the Chamnarr ;')E: Fres:Oen: may prescribe. snarl a ate int such attorneys-in-fact, as may be necessary to act in behalf of the Corhmation to make, execute. sear,
ackrcwie.dge End deliver as ssisty arty td ell unc:ertakings. Lancs. recoranizencors and other surety obligations. Such attorneys-in-fact, subject to the limitatrons set forth in their respective
pop/us ct akar shall have lull ['rower ty hint Me Corporation by timir sierm-.tbre and exectition of any such instruments anci to attach thereto the seal of the Corporation. \When so
executed. such instruments shall Le as 1 1 111g as if bier ed by the PIE:Sider -a am: attested to by the Secretary. Any power or authcrity granted to any representative or attorney-in-fact under
the provisions of this article may be revoltec at any time by the Board, the Chairrmin, the President or by the officer or officers granting such power or authority.
ARTICLE XIII --- Exst titian of Contibidb -- 'SECTION 5 Suretv Borits and Undertetirros. Any officer of the Company atithorized for that purpose in writing by the chairmn or the prcsident.
and i-ubjcict to such limitations as. the chairman or -be pre sic e nt ingy prescribe. shall appoint such it as may Jarecessary to act in behalf of the Company to make, execute,
scml. ammiceiledge and detwar softly ap yrr end all undertakings, bonds. recognizances and other surety obligations. Such phorneys-in-fact subl ied to the limitations se.: forth in their
resoective r ewers of aficrney shell Itavre to bind the Company by the' 'ci'.:MEJI.1re and execution of any such instrumeals and to attach thereto the seal of the Company.
execatad such r"Hi uments shell be :Kb cripLisicrt che a:tosted by the secretary.
Certificate of Designation The Fr cut of the Cc wpm/. purstCt te Me Bylaws of the Company authorizes Cappory W. Davenport, Assistant Secretary to appoint such
mtornb/S-B-%Mt 6S IIT&.y neccs sty to or illaalf (rt. tee Carat any to Bake, execute, seal, iclulug.iledge bib] dulivbi I iyeiayaridaIluuidertaari, uia,5upiLdi luCJ
other allety oblige:Hons.
Authorization • Fry unaninicus canton - till Coq party s board or Di -Pi-Tors. Me Company consents that facsimile or mechanically reproduced signature of any assistant secretary of the
Cc mpg ny, whcrcve r up:tarty.: upon certifiecl (soy of any t ower of sitlornr.y is-tied by the Company in connection with surety bonds, shall be valid and binding upon the Company with
the same force am eff: c usti 'I rip:near ly a fa Len
I, David M. C.: -rc. the undersigned. Ass;stant Se,;etary. o', ,=merican Fire and Castre.rty Company, The Ohio Casualty Insurance Company, Liberty Mutual Insurance Company, arc 'Wrest
American Instlr:lf ice Company do hereby certify that the cr'crnai power o' attorney v,..nch the foregoing is a full, true and correctoopy of the Power of Attorney executed by said Companies,„
is in full force rIC Elffe' and ha s not Leca ravokeci.
IN TESTIMONY WHEREOF, I Lave he rear to set my hand and affixsd the seals of said Companies thil

POWER OF ATTORNEY APPOINTING INDIVIDUAL ATTORNEY-IN-FACT
Know All Men By These Presents, That Continental Casualty Company, an Illinois insurance company, National Fire Insurance Company of
Hartford, an Illinois insurance company, and American Casualty Company of Reading, Pennsylvania, a Pennsylvania insurance company (herein called
"the CNA Companies"), are duly organized and existing insurance companies having their principal offices in the City of Chicago, and State of Illinois,
and that they do by virtue of the signatures and seals herein affixed hereby make, constitute and appoint
Cynthia M Partin, Bradley D Lorenzetti, Heidi K Harrell Bennett, Rebecca E Cano, Individually
of Columbia, SC, their true and lawful Attorney(s)-in-Fact with full power and authority hereby conferred to sign, seal and execute for and on their
behalf bonds, undertakings and other obligatory instruments of similar nature
- In Unlimited Amounts -
and to bind them thereby as fully and to the same extent as if such instruments were signed by a duly authorized officer of their insurance companies and
all the acts of said Attorney, pursuant to the authority hereby given is hereby ratified and confirmed.
This Power of Attorney is made and executed pursuant to and by authority of the By-Law and Resolutions, printed on the reverse hereof, duly
adopted, as indicated, by the Boards of Directors of the insurance companies.
In Witness Whereof, the CNA Companies have caused these presents to be signed by their Vice President and their corporate seals to be hereto
affixed on this 27th day of June, 2013.
Continental Casualty Company
National Fire Insurance Company of Hartford
American Casualty Company of Reading, Pennsylvania
State of South Dakota, County of Minnehaha, ss:
On this 27th day of June, 2013, before me personally came Paul T. Brufiat to me known, who, being by me duly sworn, did depose and say: that he
resides in the City of Sioux Falls, State of South Dakota; that he is a Vice President of Continental Casualty Company, an Illinois insurance company,
National Fire Insurance Company of Hartford, an Illinois insurance company, and American Casualty Company of Reading, Pennsylvania, a
Pennsylvania insurance company described in and which executed the above instrument; that he knows the seals of said insurance companies; that the
seals affixed to the said instrument are such corporate seals; that they were so affixed pursuant to authority given by the Boards of Directors of said
insurance companies and that he signed his name thereto pursuant to like authority, and acknowledges same to be the act and deed of said insurance
companies.
My Commission Expires June 23, 2015 J. Mohr
CERTIFICATE
I, D. Bult, Assistant Secretary of Continental Casualty Company, an Illinois insurance company, National Fire Insurance Company of Hartford, an
Illinois insurance company, and American Casualty Company of Reading, Pennsylvania, a Pennsylvania insurance company do hereby certify that the
Power of Attorney herein above set forth is still in force, and further certify that the By-Law and Resolution of the Board of Directors of the insurance
companies printed on thesrse hereof is still in forcetestimony whereof I have hereunto ubscribed my name and affixed the seal of the said
insurance companies thi day of ..c.N211C
Continental Casualty Company
National Fire Insurance Company of Hartford
American Casualty Company of Reading, Pennsylvania
D. Bult Assistant Secretary
Form F6853-4/2012

ZURICH AMERICAN INSURANCE COMPANY
COLONIAL AMERICAN CASUALTY AND SURETY COMPANY
FIDELITY AND DEPOSIT COMPANY OF MARYLAND
POWER OF ATTORNEY
KNOW ALL MEN BY THESE PRESENTS: That the ZURICH AMERICAN INSURANCE COMPANY, a corporation of the State of New
York, the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY, a corporation of the State of Maryland, and the FIDELITY
AND DEPOSIT COMPANY OF MARYLAND a corporation of the State of Maryland (herein collectively called the "Companies"), by
JAMES M. CARROLL, Vice President, in pursuance of authority granted by Article V, Section 8, of the By-Laws of said Companies,
which are set forth on the reverse side hereof and are hereby certified to be in full force and effect on the date hereof, do hereby nominate,
constitute, and appoint Cynthia M. PARTIN, Pamela BRANDT, Brad LORENZETTI, Heidi K. BENNETT and Rebecca E. CANO, all
of Columbia, South Carolina, EACII its true and lawful agent and Attorney-in-Fact, to make, execute, seal and deliver, for, and on its
behalf as surety, and as its act and deed: any and all bonds and undertakings, and the execution of such bonds or undertakings in pursuance
of these presents, shall be as binding upon said Companies, as fully and amply, to all intents and purposes, as if they had been duly executed
and acknowledged by the regularly elected officers of the ZURICH AMERICAN INSURANCE COMPANY at its office in New York, New
York., the regularly elected officers of the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY at its office in Owings
Mills, Maryland., and the regularly elected officers of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND at its office in Owings
Mills, Maryland., in their own proper persons.
The said Vice President does hereby certify that the extract set forth on the reverse side hereof is a true copy of Article V, Section 8, of
the By-Laws of said Companies, and is now in force.
IN WITNESS WHEREOF, the said Vice-President has hereunto subscribed his/her names and affixed the Corporate Seals of the said
ZURICH AMERICAN INSURANCE COMPANY, COLONIAL AMERICAN CASUALTY AND SURETY COMPANY, and
FIDELITY AND DEPOSIT COMPANY OF MARYLAND, this 3rd day of July, A.D. 2012.
ATTEST:
ZURICH AMERICAN INSURANCE COMPANY
COLONIAL AMERICAN CASUALTY AND SURETY COMPANY
FIDELITY AND DEPOSIT COMPANY OF MARYLAND
Assistant Secretary Vice President
Eric D. Barnes James M. Carroll
State of Maryland
City of Baltimore
On this 3rd day of July. A.D. 2012, before the subscriber, a Notary Public of the State of Maryland, duly commissioned and qualified, JAMES M.
CARROLL, Vice President, and ERIC D. BARNES, Assistant Secretary, of the Companies, to me personally known to be the individuals and officers
described in and who executed the preceding instrument, and acknowledged the execution of same, and being by me duly swom, deposeth and saith, that
he/she is the said officer of the Company aforesaid, and that the seals affixed to the preceding instrument are the Corporate Seals of said Companies, and that
the said Corporate Seals and the signature as such officer were duly affixed and subscribed to the said instrument by the authority and direction of the said
Corporations.
IN TESTIMONY WHEREOF, I have hereunto set my hand and affixed my Official Seal the day and year first above written.
/
Constance A. Dunn, Notary Public
My Commission Expires: July 14,2015
POA-F 177-3305

EXHIBIT F - MARICOPA COUNTY SMALL BUSINESS ENTERPRISE PROGRAM
CMR CONTRACTING REQUIREMENTS
PART 1 PURPOSE
1.1 It is Maricopa County's policy to provide Small Business Enterprises (SBE) with the
opportunity to participate in the County's solicitation process and to be considered to fulfill
the requirements for various commodities and services. This contract has no requirement for
utilization of SBEs, however it does require that utilization of SBE firms by CMR be reported
for tracking by the County.
PART 2 REPORTING APPLICABLE TO USE OF SBEs.
2.1 SBE CMR: An SBE CMR may indicate the SBE participation for that portion of the contract
that they themselves perform, plus those portions subcontracted to other SBE firms.
2.2 SBE Subcontractor: The SBE amount will be based on that portion (dollar value) of the
contract that the SBE Subcontractor performs.
2.3 SBE — Non-SBE Joint Venture: A joint venture consisting of SBE participation and non-SBE
participation, functioning as a CMR, may list the SBE participation on the basis of the
percentage of profit accruing to the SBE firm.
2.4 Lower Tier Non-SBE Participation: SBE Subcontractors proposing to further subcontract to
non-SBE CMRs shall not have that portion of subcontracting activity considered when
determining SBE participation.
2.5 SBE Suppliers: Any SBE Supplier that manufactures or substantially alters the material or
product it supplies will have that portion of activity considered when determining SBE
participation.
2.6 SBE Trucking: trucking by SBEs will be the amount to be paid when the SBE trucker has
performed the trucking with his/her trucks, tractors, and employees or when an SBE trucking
broker has signed agreements with SBE truckers.
PART 3 REQUESTS FOR PAY
3.1 Each Request for Payment, including the final Request for Payment must be accompanied by
a Maricopa County SBE Program Participation Report in the form as provided in Attachment
1 to this Section.
PART 4 ATTACHMENTS
4.1 Attachment 1: SBE Participation Reporting Form (1 page).
END OF SECTION
OET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. # 52

Maricopa County Small Business Enterprise Program
Participation Reporting Form
This form is to be submitted with each pay application or invoice. Any pay application or invoice without
this form attached is subject to rejection as not being a completed pay application or invoice pursuant to
the terms of the contract.
Name of Prime Consultant/CMR Contract No.
Contact Person Project No.
Street Address Amount of this Pay Application/Invoice
City, State ZIP
Complete below with information on the SBE firms utilized as SubConsultants/SubContractors for this
pay application/invoice. If work was self-performed and your firm, as the prime, is an SBE firm pursuant
to A.R.S. § 41-1001, et seq., then you may list your firm as the SBE firm.
SBE Firm Name SBE Firm Address Type of Work S Pd to SBE this
Performed App/Inv
$
$
$
$
$
$
$
$
$
0 0
0 A mark in this box certifies that no SBE firms were utilized as the prime, SubConsultant or
SubContractors with respect to this pay application/invoice.
Date:
Signature
Phone No.:
Printed Name
OET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. # 53

EXHIBIT G - ALTERNATIVE DISPUTE RESOLUTION
1.1 Scope. Notwithstanding anything to the contrary provided elsewhere in the Contract, the
alternative dispute resolution ("ADR") process provided for herein shall be the exclusive means
for resolution of claims or disputes arising under, relating to or touching upon the Contract, the
interpretation thereof or the performance or breach by any party thereto, including but not limited
to original claims or disputes asserted as cross claims, counterclaims, third party claims or claims
for indemnity or subrogation, in any threatened or ongoing litigation or arbitration with third
parties, if such disputes involve parties to contracts containing this ADR provision.
1.2 Neutral Evaluator, Arbitrators. The County will select a Neutral Evaluator to serve as set forth
in this ADR process. As needed under § 1.6.2 below, the County and CMR shall each select an
arbitrator to serve as set forth in this ADR process. Each arbitrator selected shall be a member of
the State Bar of the State of Arizona and shall have experience in the field of construction law.
All arbitrators, once selected, shall serve as neutral arbitrators, even if they are party-appointed.
The County and the CMR shall name their respective arbitrators within five (5) calendar days
after the declaration of a failure of mediation or the mutual waiver of mediation.
1.3 Discussion and Partnering. When a claim is made or a dispute arises relating to the Contract,
senior representatives of the County and the claimant will meet personally within ten (10) days to
discuss the claim/dispute and attempt to resolve it. If, after good faith efforts, resolution is not
achieved, the claim/dispute (hereafter "dispute") will proceed to the neutral evaluation process.
1.4 Neutral Evaluation Process. If the parties have been unable to resolve the dispute after
discussions and partnering, the following neutral evaluation process shall be used to resolve any
such dispute.
1.4.1 Notification of Dispute. The County through its Agent shall promptly notify the Neutral
Evaluator in writing of the existence of a dispute within ten days of the County or the
CMR declaring need to commence the neutral evaluation process.
1.4.2 Non-Binding Informal Hearing. The Neutral Evaluator shall schedule a non-binding
informal hearing of the matter to be held within ten (10) calendar days from receipt of
notification of the existence of a dispute. The Neutral Evaluator may conduct the hearing
in such manner as he deems appropriate and shall notify each party of the hearing of its
opportunity to present such evidence as they believe will resolve the dispute. The Neutral
Evaluator shall notify each party to the dispute that they shall submit a written outline of
the issues and evidence intended to be introduced at the hearing and their proposed
resolution of the dispute to the Neutral Evaluator before the hearing commences.
Potential Arbitrators shall not participate in such informal hearing or proceedings
process. The Neutral Evaluator is not bound by the rules of evidence when admitting
evidence in the hearing and may limit the length of the hearing, the number of witnesses
or any evidence introduced to the extent deemed relevant and efficient.
1.4.3 Non-Binding Decision. The Neutral Evaluator shall render a non-binding written
decision as soon as possible, but not later than five (5) calendar days after the hearing
concludes.
1.4.4 Further proceedings. In the event that either party declines to accept the Neutral
Evaluator's decision as the resolution of the dispute, the dispute will proceed to
mediation.
OET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. # 54

1.5 Mediation. In the event that a meeting of principals and neutral evaluation have failed, the
parties shall engage in mediation (as a condition precedent to arbitration) within fifteen (15) days
of a party's notifying the Neutral Evaluator that the party declines to accept the Neutral
Evaluator's decision as the resolution of the dispute. The mediator shall be chosen by the parties'
agreement. If such agreement is not reached by five (5) days after the neutral evaluator's receipt
of a party's notification, then the mediator shall be named by the Neutral Evaluator. In the event
that mediation fails (or is waived by both parties) then the matter shall proceed to binding
arbitration.
1.6 Binding Arbitration Procedure. The following binding arbitration procedure shall serve as the
exclusive method to resolve a dispute if any party chooses not to accept the decision of the
Neutral Evaluator and mediation has failed or has been waived. A party requesting binding
arbitration shall notify the Neutral Evaluator in writing within seven (7) calendar days of the
failure or waiver of mediation of the party's demand for arbitration. If the CMR requests
arbitration it shall post a cash bond with the Neutral Evaluator in an amount agreed upon by the
parties or, in the event of no agreement, the Neutral Evaluator shall establish the amount of the
cash bond to defray the cost of the arbitration as set forth in paragraph 1.6.11 and the proceeds
from the bond shall be allocated in accordance with paragraph 1.6.13 by the Arbitration Panel.
The bond must be in the full amount agreed upon or as established by the Neutral Evaluator to
pay the potential cost of the full arbitration proceeding. The bond must be posted with and
received by the Neutral Evaluator within five (5) calendar days after the demand for arbitration.
1.6.1 Arbitration Panel and Applicable Law and Rules. Disputes involving less than
$200,000 shall be heard by one single arbitrator chosen by agreement of the parties. For
disputes in excess of $200,000, the Arbitration Panel shall consist of three arbitrators: the
County's appointed arbitrator, the CMR's appointed arbitrator and a third arbitrator (or
"neutral arbitrator") who shall be selected by the parties' arbitrators as set forth in Section
1.5.2. The arbitration is to be convened and administered under the Revised Uniform
Arbitration Act ("RUAA") (A.R.S. § 12-3001 et seq.) and the American Arbitration
Association Construction Rules shall serve as a guideline for proceedings, thus as a
supplement to the RUAA.
1.6.2 Selection of Neutral Arbitrator. For disputes in excess of $200,000, the parties'
arbitrators shall choose the Neutral Arbitrator, within ten (10) calendar days of
notification of a demand for arbitration having been received by the Neutral Evaluator.
The Neutral Arbitrator shall have the same qualifications as those of the arbitrators set
forth in paragraph 1.2. above. In the event that the two party selected arbitrators cannot
agree on a Neutral Arbitrator as set forth above, the Neutral Arbitrator shall be selected as
the Default Neutral Arbitrator. If the County and CMR cannot agree on the single
arbitrator or upon a Default Neutral Arbitrator, then County and the CMR shall each
submit two names to Judge Eino Jacobson, or his successor as designated by Maricopa
County, who shall select one person. The Neutral Arbitrator may submit his invoices for
services to the OWNER, and the OWNER shall pay the amounts invoiced (subject to the
provisions of paragraph 1.4.13) unless and until the CMR is determined by the
Arbitration Panel to be the non-prevailing party and the Arbitration Panel determines per
1.6.11 what party pays such costs.
1.6.3 Expedited Hearing. The parties have structured this procedure with the goal of
providing for the prompt, efficient and final resolution of all disputes falling within the
purview of this ADR process. To that end, any party can petition the Neutral Evaluator to
set an expedited hearing. If the Neutral Evaluator determines that the circumstances
justify it, the Neutral Evaluator shall contact the selected single arbitrator or Arbitration
GET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. #55

Panel and arrange for scheduling of the arbitration at the earliest possible date. In any
event, the hearing of any dispute not expedited will commence as soon as practical but in
no event later than twenty (20) calendar days after notification of request for arbitration
having been received. This deadline can be extended only with the consent of all the
parties to the dispute, or by decision of the single arbitrator or the Arbitration Panel upon
a showing of emergency circumstances.
1.6.4 Procedure. The single arbitrator or the Arbitration Panel will conduct the hearing in
such a manner that will resolve disputes in a prompt, cost efficient manner giving regard
to the rights of all parties. Each party shall supply to the single arbitrator or Arbitration
Panel a written pre-hearing statement which shall contain a brief statement of the nature
of the claim or defense, a list of witnesses and exhibits, a brief description of the subject
matter of the testimony of each witness who will be called to testify, and an estimate as to
the length of time that will be required for the arbitration hearing. The single arbitrator or
the Arbitration Panel shall review and consider the Neutral Evaluator decision. The single
arbitrator or the Chairman shall determine the nature and scope of discovery, if any, and
the manner of presentation of relevant evidence consistent with deadlines provided
herein, and the parties' objective that disputes be resolved in a prompt and efficient
manner. No discovery may be had of any materials or information for which a privilege is
recognized by Arizona law. The single arbitrator or the Chairman upon proper
application shall issue such orders as may be necessary and permissible under law to
protect confidential, proprietary or sensitive materials or information from public
disclosure or other misuse. Any party may make application to the Maricopa County
Superior Court to have a protective order entered as may be appropriate to confirm or
enforce such orders of the Chairman.
1.6.5 Hearing Days. In order to effectuate parties' goals, the hearing once commenced, will
proceed from working day to working day until concluded, absent a showing of
emergency circumstances.
1.6.6 Award. The single arbitrator shall within ten (10) calendar days of the conclusion of a
hearing issue a reasoned award. The Arbitration Panel shall, within ten (10) calendar
days from the conclusion of any hearing, by majority vote issue its reasoned award. The
award shall include an allocation of fees and costs pursuant to 1.6.11 herein. The award is
to be in accordance with the Contract and the law of the State of Arizona.
1.6.7 Scope of Award. Regardless of the provisions of the RUAA, the Arbitration Panel shall
be without authority to award punitive damages, and any such punitive damage award
shall be void. If an award is made against any party in excess of one hundred thousand
dollars ($100,000), exclusive of interest, arbitration fees, costs and attorneys' fees, it shall
be supported by written findings of fact, conclusions of law and a statement as to how
damages were calculated.
1.6.8 Jurisdiction. The Arbitration Panel shall not be bound for jurisdictional purposes by the
amount asserted in any party's claim, but shall conduct a preliminary hearing into the
question of jurisdiction over the claim as regards its amount upon application of any party
at the earliest convenient time, but not later than the commencement of the arbitration
hearing. If the dispute is in reality one involving less than $200,000, the arbitration shall
continue before the Neutral Arbitrator as a single arbitrator, with the party appointed
arbitrators being excused.
OET Zone 2 Refresh Downtown CMR Serial #13152-CMR
Contract between Maricopa County and DPR Construction Pg. # 56

1.6.9 Entry of Judgment. As provided in the RUAA, any party can make application to the
Maricopa County Superior Court for confirmation of an award, and for entry of judgment
on it.
1.6.10 Severance and Joinder. To reduce the possibility of inconsistent adjudications, the
Neutral Evaluator or the single arbitrator or Arbitration Panel, may: (i) at the request of
any party, join and/or sever parties, and/or claims arising under other contracts containing
this ADR provision, and (ii) the Neutral Evaluator, on his own authority, or the single
arbitrator or Arbitration Panel may, on its own authority, join or sever parties and/or
claims subject to this ADR process as deemed necessary for a just resolution of the
dispute, consistent with the parties' goal of the prompt and efficient resolution of
disputes, provided, however, that the A/E, OWNER and Project Professionals shall not be
joined as a party to any claim made by a CMR. Nothing herein shall create the right by
any party to assert claims against another party not germane to the Contract or not
recognized under the substantive law as applicable to the dispute. Neither the Neutral
Evaluator nor the single arbitrator or Arbitration Panel is authorized to join to the
proceeding parties not in privity with the County. CMR cannot be joined to any pending
arbitration proceeding, without CMR's express written consent and unless CMR is given
the opportunity to participate in the selection of the single arbitrator or non-County
appointed arbitrator.
1.6.11 Fees and Costs. Each party shall bear its own fees and costs in connection with any
informal hearing before the Neutral Evaluator and the mediation. All fees and costs
associated with any arbitration before the single panel or Arbitration Panel, including
without limitation the Arbitrator fees, and the prevailing party's reasonable attorneys'
fees, expert witness fees and costs, will be paid by the non-prevailing party, except as
provided for herein. In the event that CMR is the non-prevailing party, all fees and costs
as noted above shall first be paid out of the bond posted with the Neutral Evaluator. In no
event shall the CMR's obligation to pay fees and costs be limited to the amount of the
bond posted herein. In no event shall any Arbitrator's hourly fees be awarded in an
amount in excess of $250 per hour and (i) costs shall not include any travel expenses in
excess of mileage at the rate paid by Maricopa County, not to exceed a one way trip of
150 miles, and (ii) all travel expenses, including meals, shall be reimbursed pursuant to
the travel policy of Maricopa County in effect at the time of the hearing. The
determination of prevailing and non-prevailing parties, and the appropriate allocation of
fees and costs, will be included in the award by the single arbitrator or Arbitration Panel.
Fees for the Neutral Evaluator shall be paid by County.
1.6.12 Confidentiality. Any proceeding initiated under this ADR provision shall be deemed
confidential to the maximum extent allowed by Arizona law and, except for disclosures
to a party's attorneys or accountants, no party shall make any disclosure related to the
disputed matter or to the outcome of any proceeding except to the extent required by law,
or to seek interim equitable relief, or to enforce an agreement reached by the parties or an
award made hereunder. This provision does not affect the County's right to inform the
County Supervisors of the resolution of the dispute.
1.6.13 Equitable Litigation. Notwithstanding any other provision of ADR to the contrary, any
party can petition the Maricopa County Superior Court for interim equitable relief as may
become necessary to preserve the status quo and prevent immediate and irreparable harm
to a party or to the Project pending resolution of a dispute pursuant to ADR provided
herein. No court may order any permanent injunctive relief except as may be necessary to
OET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. #57

enforce an order entered by the Arbitration Panel. The fees and costs incurred in
connection with any such equitable proceeding shall be determined and assessed in ADR.
1.6.14 Change Order. Any award in favor of the CMR against the County or in favor of the
County against the CMR shall be reduced to a Change Order and executed by the parties
in accordance with the award and the provisions of the Contract.
1.6.15 Merger and Bar. Any claim asserted pursuant to this ADR process shall be deemed to
include all claims, demands, and requests for compensation for costs and losses or other
relief, including the extension of the Contract performance period which reasonably
should or could have been brought against any party that was or could have been brought
into this ADR process, with respect to the subject claim. The Arbitration Panel shall
apply legal principles commonly known as merger and bar to deny any claim or claims
against any party regarding which claim or claims recovery has been sought or should
have been sought in a previously adjudicated claim for an alleged cost, loss, breach, error,
or omission.
1.7 Inclusion in Other Contracts. The CMR shall cooperate with the County in efforts to include
this ADR provision in all other Project contracts. Subject to CMR's reasonable agreement, the
CMR agrees that any modification to this ADR provision that is included in the construction or
other contracts shall also apply to the CMR. It is the intent of the parties that any changes to this
ADR provision in later contracts will be evolutionary and designed to incorporate the terms of
this ADR provision without material changes to the substance or procedure of this ADR
provision.
END OF EXHIBIT
OET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. # 58

EXHIBIT H - SUBCONTRACTOR MANAGEMENT PLAN
(The Subcontractor Management Plan is incorporated into the CMR's Statement of Qualification
submitted during the procurement process. This Plan is incorporated herein by reference as though fully
set forth in the contract documents.)
GET Zone 2 Refresh Downtown CMR Serial # 13152-CMR
Contract between Maricopa County and DPR Construction Pg. # 59

EXHIBIT I - LEGAL WORKER CERTIFICATION
(Date)
Maricopa County
Facilities Management Department
401 West Jefferson Street
Phoenix, Arizona 85003
As required by Arizona Revised Statutes §41-4401, Maricopa County (the "County") is prohibited, after
September 30, 2008 from awarding a contract to any CMR who fails, or whose subcontractors fail, to
comply with Arizona Revised Statutes § 23-214-A. The undersigned entity warrants that it complies fully
with all federal immigration laws and regulations that relate to its employees, that it shall verify, through
the employment verification pilot program as jointly administered by the U.S. Department of Homeland
Security and the Social Security Administration or any of its successor programs, the employment
eligibility of each employee hired after December 31, 2007, and that it shall require its subcontractors and
sub-subcontractors to provide the same warranties to the below entity.
The undersigned acknowledges that a breach of this warranty by the below entity or by any subcontractor
or sub-subcontractor under any Contract resulting from this solicitation shall be deemed a material breach
of the Contract, and is grounds for penalties, including termination of the Contract, by the County. The
County retains the right to inspect the records of the below entity, subcontractor and sub-subcontractor
employee who performs work under the Contract, and to conduct random verification of the employment
records of the below entity and any subcontractor and sub-subcontractor who works on the Contract, to
ensure that the below entity and each subcontractor and sub-subcontractor is complying with the
warranties set forth above.
DPR Construction 222 N. 44th Street
(Firm) (Address Line 1)
David Elrod Phoenix, Arizona 85003
(Print Name) (Address Line 2)
(Phone)
(Signature ReqUired) (Fax)
0:44. 27-0853429
(Email Address) (Federal Taxpayer ID Number)
OET Zone 2 Refresh Downtown CMR Serial #13152-CMR
Contract between Maricopa County and DPR Construction Pg. # 60