McCarthy Cholla GMP1 - City CM@Risk BGMP Agreement 1.26.24 Signed
Extracted text (via pymupdf)
84384 characters
City of Glendale Standard Form Agreement Between Owner and CM@Risk (May 15, 2023)
Project Name: Cholla Water Treatment Plant 2023 Improvements
Project No.:
212230.1
Amendment No: 001
Date:
This Amendment to that certain Standard Form Agreement dated April 11, 2023 by and between the City of Glendale
and McCarthy Building Companies, Inc. (CM@Risk) for services, deliverables and work related to Project No.
212230.1, Project Name: Cholla Water Treatment Plant 2023 Improvements, (the “Agreement”) is made and entered
into effective this day of , 2024.
1. This Amendment #001 establishes a Guaranteed Maximum Price (“GMP”) and Construction Phase Fee
for Construction Services and incorporates such terms into the Agreement, making the Agreement effective
for Construction Phase Services:
a.
The total fee for Construction Phase Services, which is included in the Guaranteed Maximum Price (GMP)
as defined under the Agreement, shall be fixed at Three Hundred Sixty-three Thousand Seven Hundred
Twelve and 73/100 Dollars ($363,712.73). Fee is not inlclusive for the Allowances included in the GMP
and will be added at the time of Allowance usage. Self-Perform fee will remain as shown in the Executed
Agreement. and is not included in this fee amount but is inlcuded in the GMP.
b. The Guaranteed Maximum Price (“GMP”) for Construction Services, as defined under the Agreement, shall
be Ten Million Three Hundred Forty-One Thousand Three Hundred Five and 14/100 Dollars
($10,341,305.14).
c.
The total compensation under the Agreement, as amended by this Amendment, shall be:
Pre-Construction Phase
Construction Phase
Total
Original Agreement:
$3,232,717.00
$
$3,232,717.00
Previous Amendments:
$
$
$
This Amendment:
$
$10,341,305.14
$10,341,305.14
Total (including this
Amendment):
$3,232,717.00
$10,341,305.14
$13,574,022.14
2. DELETE the blank template “Exhibit C – Cost of the Work – Schedule of Values” from the Agreement,
and ADD “Exhibit C – McCarthy Building Companies, Inc. Cost of the Work – Schedule of Values” dated
12/14/23 (4 Pages), attached herein.
3. ADD “Exhibit E – Construction Documents necessary to define Scope of Work and deliverables for the
Construction Phase Services, including plans, designs, drawings, specifications and other required
Contract Documents” dated 12/14/23 (6 Pages), attached herein.
4. ADD “Exhibit F - Statement of All Clarifications and Assumptions” dated 12/14/23 (3 Pages), attached
herein.
5. ADD “Exhibit G – Schedule of Major Milestones” dated 12/14/23 (9 Pages), attached herein.
6.
All other provisions, terms and conditions of the Agreement shall remain unchanged and in full effect.
(Signature on following page)
City of Glendale Standard Form Agreement Between Owner and CM@Risk (May 15, 2023)
EXHIBIT C
Cost of the Work
(Four (4) pages to be included with GMP Amendment)
Exhibit C - Cost of Work
CONSTRUCTION MANAGER AT RISK AGREEMENT
Cholla WTP 2023 Improvements
GMP 1
12/14/23
Cost Code
Item of Work
GMP 1
Total
Sub/Supplier Direct Cost
22.86%
$2,363,519.00
$2,363,519.00
Cost Reimbursable Self Perform
22.07%
$2,281,966.00
$2,281,966.00
General Conditions
14.88%
$1,538,369.00
$1,538,369.00
CMAR Contingency (Direct Cost)
3.00%
$139,364.55
$139,364.55
SUBTOTAL DIRECT CONSTRUCTION COST (DCC)
$6,323,218.55
$6,323,218.55
FEE
Fixed Fee, Equal to 9% of DCC
$569,089.67
$569,089.67
Self Perform 9% Fee Removal
($205,376.94)
($205,376.94)
SUBTOTAL CONSTRUCTION PHASE FEE
$363,712.73
$363,712.73
BONDS
CMR Performance and Payment Bonds: Actual Cost not to Exceed
.627% of DCC
$41,927.06
$41,927.06
INSURANCE
CMR Insurance (Worker'sComp, General Liablity, Auto Insurance,
Umbrella) - Actual Cost, not to exceed .99% of DCC
$66,200.62
$66,200.62
Builder's Risk- Actual Cost not-to-exceed 0.15% of DCC
$10,338.00
$10,338.00
TAXES
Actual Cost, Equal to (65% of 9.2%) of DCC + Fee +Bond + Insurance
$406,962.73
$406,962.73
Tax Exempt Cost
($34,983.00)
($34,983.00)
SUBTOTAL INDIRECT CONSTRUCTION COST (ICC)
$490,445.40
$490,445.40
Solids Handling Maintenance/Coordination
$200,000.00
$200,000.00
Chemical Trench Allowance
$986,367.49
$986,367.49
Electrical Allowance
$909,827.05
$909,827.05
Equipment Relocation Allowance
$561,876.44
$561,876.44
90-100 Allowance (3% Direct Cost)
$189,696.56
$189,696.56
Owner Contingency (5% Direct Cost )
$316,160.93
$316,160.93
SUBTOTAL ALLOWANCE COST (AC)
$3,163,928.46
$3,163,928.46
TOTAL GMP 1 = DCC+FEE+ICC+AC
$10,341,305.14
$10,341,305.14
DIRECT CONSTRUCTION COST
CONSTRUCTION PHASE FEE
INDIRECT CONSTRUCTION COST (ICC)
3 of 24
City Glendale: Cholla WTP 2023 Improvements - Chlorine Dioxide System
Project No. 212230
12/14/2023
Hourly
Project Director
$153.16
Senior Project Manager
$144.61
Project Manager
$136.05
Assistant Project Manager
$109.00
Project Safety Manager
$136.05
General Superintendent
$148.28
Project Superintendent
$140.45
Area Superintendent
$128.42
Assistant Project Superintendent
$110.71
Senior Project Engineer
$93.53
Project Engineer
$86.69
Project Administrator
$68.19
Rates include salary and burden, vehicle, fuel, oil, parts, cell phone, computer, software & maintenance, subsistence,
travel, training and relocation. Sick and Vacation are included in the rates; holidays have been included as cost of the
work.
McCarthy Staff Unit Rates
13 of 24
City Glendale: Cholla WTP 2023 Improvements - Chlorine Dioxide System
Project No. 212230
12/14/2023
McCarthy Non-Staff Rates
Hourly
General Foreman
$85.16
Foreman
$65.09
Carpenter
$62.14
Laborer
$44.37
Operator - Crane / Equipment
$69.65
Operator - Forklift
$65.62
Truck Driver
$52.12
Pipefitter / Pipelayer
$56.25
Welder
$76.36
Grade Checker
$55.67
Cement Mason
$57.03
Rates include wages plus burden, cell phone, travel, safety incentive, and training. Overtime hours to be billed at 1.43
times the straight time rate.
14 of 24
EQUIPMENT RATES
All equipment not included in the rate table will be billed at a daily rate consisng of the ADOT Hourly
Equipment Rental Rate (HERR) at 8 hours/day.
Descripon
UOM
Rate
CAT 420 Backhoe
DY
$645.04
CAT 140 Blade
DY
$1,405.76
CAT 315 Excavator
DY
$1,219.20
CAT H115 Hydraulic Hammer
DY
$348.56
CAT 950 Loader
DY
$814.00
CAT CP56 Roller
DY
$1,535.28
Remote Trench Roller
DY
$1,076.64
CAT 415 Skip Loader
DY
$679.68
CAT 262 Skid Steer
DY
$872.64
2k Water Truck
DY
$363.04
15 of 24
City of Glendale Standard Form Agreement Between Owner and CM@Risk (May 15, 2023)
EXHIBIT E
Construction Documents necessary to define Scope of Work and Deliverables for the
Construction Phase Services, including plans, designs, drawings, specifications and other
required Contract Documents
(6 pages - To be Incorporated by Amendment)
See Attached
Exhibit E - Construction Document List
Cholla WTP Improvements - Chlorine Dioxide System
GMP 1
12/14/23
Section
Specification
# of
Pages
Date Issued
01110
Summary of Work
3
October 2023
01111
Schedule of Completion
1
October 2023
01143
Coordination with OWNER’S Operations
7
October 2023
01291
Schedule of Values
3
October 2023
01301
Pre-Construction Conference
2
October 2023
01311
Project Coordination
1
October 2023
01312
Progress Meetings
2
October 2023
01322
Progress Schedule (Cost Loaded CPM)
9
October 2023
01323
Construction Photographs
3
October 2023
01330
Submittals
4
October 2023
01331
Reference Forms
36
October 2023
01332
Shop Drawing Procedures
7
October 2023
01333
Samples
2
October 2023
01412
Stormwater Pollution Prevention Plan and
2
October 2023
01413
Contractor’s Hazardous Materials Manageme
4
October 2023
01414
Earthmoving and Dust Control
2
October 2023
01415
Confined Space Entry Plan
2
October 2023
01416
Special Inspections
2
October 2023
01420
References
10
October 2023
01451
Testing Laboratory Services Furnished by
2
October 2023
01452
Testing Laboratory Services Furnished by
3
October 2023
01521
ENGINEER’S Field Office and
6
October 2023
01522
CONTRACTOR’S Field Office and Sheds
2
October 2023
01550
Access Roads and Parking Areas
2
October 2023
01551
Maintenance and Protection of Traffic
2
October 2023
01561
Security
2
October 2023
01570
Temporary Controls
2
October 2023
01580
Project Identification and Signs
2
October 2023
01600
General Equipment Provisions
8
October 2023
01620
Installation of Equipment
5
October 2023
01651
Transportation and Handling of Materials
3
October 2023
01661
Storage of Materials and Equipment
4
October 2023
01680
Equipment and Valve Identification
4
October 2023
01721
Protection of the Work and Property
4
October 2023
01722
Field Engineering
5
October 2023
01723
Cutting and Patching
5
October 2023
01724
Connections to Existing Facilities
1
October 2023
01731
Installation Data
2
October 2023
01740
Cleaning
3
October 2023
01751
Starting and Placing Equipment in Operat
3
October 2023
01752
Equipment and System Startup and Perform
8
October 2023
01781
Operations and Maintenance Data
5
October 2023
01782
Record Documents
3
October 2023
01783
Spare Parts and Maintenance Materials
2
October 2023
01785
Preventative Maintenance Data
4
October 2023
01810
Commissioning
6
October 2023
01821
Instruction of Operations and Maintenanc
6
October 2023
02220
Demolitions
6
October 2023
02230
Clearing
3
October 2023
02315
Structural Excavation and Backfill
21
October 2023
02318
Crushed Stone and Gravel
2
October 2023
02630
Drainage Structures
3
October 2023
02666
High Density Polyethylene Geomembrane Lin
11
October 2023
4 of 24
Exhibit E - Construction Document List
Cholla WTP Improvements - Chlorine Dioxide System
GMP 1
12/14/23
02742
Bituminous Paving
9
October 2023
02771
Concrete Curbs, Gutters and Sidewalk
4
October 2023
02981
Decorative Stone Landscaping
4
October 2023
03100
Concrete Formwork
9
October 2023
03200
Concrete Reinforcement
7
October 2023
03251
Concrete Joints
11
October 2023
03252
Anchorage in Concrete
6
October 2023
03300
Cast-in-Place Concrete
28
October 2023
03402
Precast Pipe Trenches
3
October 2023
03600
Grout
10
October 2023
04060
Mortar and Masonry Grout
6
October 2023
04090
Masonry Accessories
6
October 2023
04201
Unit Masonry Construction
13
October 2023
04220
Concrete Masonry Units
4
October 2023
05051
Anchor Bolts, Toggle Bolts and Concrete Inserts and Adhesive Anchors
7
October 2023
05120
Structural Steel
8
October 2023
05311
Metal Roof Decking
8
October 2023
05501
Miscellaneous Metal Fabrications
5
October 2023
05522
Aluminum Handrails and Railings
14
October 2023
05561
Castings
3
October 2023
06100
Rough Carpentry
4
October 2023
06611
Fiberglass Reinforced Plastic Gratings, Treads & Support Framing Members
4
October 2023
07220
Roof Insulation
7
October 2023
07240
Exterior Insulation and Finish System
13
October 2023
07501
Single Ply Membrane Roofing
12
October 2023
07530
Elastic Sheet Roofing
10
October 2023
07620
Flashing and Trim
7
October 2023
07710
Roof Drainage Specialties
4
October 2023
07920
Calking and Sealants
12
October 2023
08105
Hollow Metal Doors and Frames
10
October 2023
08505
Window Film
4
October 2023
08710
Finish Hardware
15
October 2023
08800
Glass Plastic and Glazing
11
October 2023
09900
Painting
37
October 2023
09982
Vinyl Ester Lining System
20
October 2023
10200
Louvers and Vents
9
October 2023
10400
Identification Signs
11
October 2023
10522
Portable Fire Protection Equipment
3
October 2023
11000
Electric Motors 250 Horsepower or Less
10
October 2023
11200
Quarter Turn Actuators
6
October 2023
15050
Piping Systems
16
October 2023
15051
Buried Piping Installation
36
October 2023
15052
Exposed Piping Installation
13
October 2023
15061
Pipe Hangers and Supports
9
October 2023
15082
Insulation of Piping and Equipment – HVAC and Process Air
6
October 2023
15083
Duct Insulation
4
October 2023
15101
Ductile Iron Pipe
6
October 2023
15102
Steel Pipe
7
October 2023
15105
Copper Pipe
4
October 2023
15106
Thermoplastic Pipe
6
October 2023
15109
Chlorination Systems, Pipe, Valves and Specials
October 2023
15110
Gate Valves, Operators and Appurtenances
13
October 2023
15113
Thermoplastic Valves, Operators and Appurtenances
9
October 2023
15114
Check Valves and Appurtenances
5
October 2023
15115
Ball Valves, Operators and Appurtenances
8
October 2023
5 of 24
Exhibit E - Construction Document List
Cholla WTP Improvements - Chlorine Dioxide System
GMP 1
12/14/23
15119
Specialty Valves and Appurtenances
12
October 2023
15120
Piping Specialties and Accessories
5
October 2023
15121
Wall Pipes, Floor Pipes, and Pipe Sleeves
4
October 2023
15142
Disinfection - Plumbing
2
October 2023
15143
Installation of Plumbing Piping
5
October 2023
15144
Testing of Plumbing Piping Systems
4
October 2023
15145
Pipe Sleeves – Plumbing
4
October 2023
15146
Pipe Hangers, Supports, and Restraints – Plumbing
7
October 2023
15151
Waste and Vent Piping Systems
8
October 2023
15161
Roof Drainage System
6
October 2023
15442
Non-Metallic Sump Pumps
5
October 2023
15732
Packaged Heat Pumps and Air Conditioning Units
6
October 2023
15811
Ductwork and Accessories
9
October 2023
15883
Fans
8
October 2023
15901
Automatic Temperature Controls
27
October 2023
15940
Air Intake and Relief Vents
5
October 2023
15951
Testing, Adjusting and Balancing of HVAC Systems
7
October 2023
16111
Conduits
6
October 2023
16117
Concrete Manholes, Handholes And Pull Boxes
8
October 2023
16137
Underground Duct Banks
4
October 2023
16141
Wiring Devices
5
October 2023
16142
Weatherproof While In Use Outlet Enclosures
3
October 2023
16161
Control Panels
31
October 2023
16170
Grounding And Bonding
9
October 2023
16190
Supporting Devices
5
October 2023
16195
Electrical Identification
5
October 2023
16282
Surge Protection Devices
4
October 2023
16440
Disconnect Switches
2
October 2023
16461
Transformers Dry Type
2
October 2023
16470
Panelboards
7
October 2023
16474
Motor Control Equipment
6
October 2023
16500
LED Lighting
4
October 2023
16720
Fire Surveillance And Alarm System
7
October 2023
16912
Ethernet Network Equipment
3
October 2023
16920
Electrical Acceptance Testing
7
October 2023
16951
Short Circuit, Coordination, and Arc-Flash Hazard Report
5
October 2023
17051
Process Control Description
10
October 2023
17052
Process Control System Primary Sensors and Field Instruments
16
October 2023
17451
Modicon M580 Programmable Logic Controller System (MODICON M580)
6
October 2023
17452
Modicon ControlExpert System Software and Accessories
7
October 2023
18005
Integrated Security Management System General Requirements
11
October 2023
18007
Integrated Security Management System Start-up Commissioning and Field Testing
6
October 2023
18008
Integrated Security Management System Training
2
October 2023
18121
Security Systems Cable
5
October 2023
18260
Integrated Security Management System Enclosure
19
October 2023
18910
Integrated Security Management System
34
October 2023
11246
Chemical Transfer Pump
5
June 2023
6 of 24
Exhibit E - Construction Document List
Cholla WTP Improvements - Chlorine Dioxide System
GMP 1
12/14/23
Sheet #
Sheet Name
Sheet Version
Date of Issuance
G - 1.0
Cover Sheet
90% Submittal
October 2023
G - 2.0
Sheet Index and Sheet Identification
90% Submittal
October 2023
G - 3.0
General Notes
90% Submittal
October 2023
G - 4.0
Symbols and Legends
90% Submittal
October 2023
G - 5.0
Symbols, Abbreviations, and Legends
90% Submittal
October 2023
G - 6.0
Abbreviations
90% Submittal
October 2023
G - 7.0
Process Schematic
90% Submittal
October 2023
G - 8.0
Work Area Overall 3D View
90% Submittal
October 2023
G - 9.0
Survey Control
90% Submittal
October 2023
D - 1.0
Existing Partial Site Plan - Demolition
90% Submittal
October 2023
D - 1.1
Existing Chlorine Building Area Upper Plan Modification
90% Submittal
October 2023
D - 1.2
Existing Chlorine Building Area Lower Plan Modification
90% Submittal
October 2023
D - 1.3
Existing Chlorine Building Area Demolition - Sections
90% Submittal
October 2023
D - 2.0
Raw Water Pump Station and Piping Demolition
90% Submittal
October 2023
D - 3.0
Site Demolition Photos - 1
90% Submittal
October 2023
D - 4.0
Site Demolition Photos - 2
90% Submittal
October 2023
D - 5.0
Existing Disinfection Area Plan Fire and Alarm Interface
90% Submittal
October 2023
D - 6.0
Existing Fire and Alarm Interface Demoltion Photos
90% Submittal
October 2023
D - 7.0
Existing Electrical Building Demolition/Modification Photos
90% Submittal
October 2023
D - 8.0
Disinfection Area Safety Items Photos - 1
90% Submittal
October 2023
D - 8.1
Disinfection Area Safety Items Photos - 2
90% Submittal
October 2023
D - 8.2
Disinfection Area Safety Items Photos - 3
90% Submittal
October 2023
D - 8.3
Disinfection Area Safety Items Photos - 4
90% Submittal
October 2023
C - 1.0
Overall Site Plan and Area of Work
90% Submittal
October 2023
C - 2.0
Partial Site Plan
90% Submittal
October 2023
C - 3.0
Enlarged Site Plan and Elevation
90% Submittal
October 2023
C - 4.0
Grading and Paving
90% Submittal
October 2023
C - 5.0
Overall Site Yard Piping Plan
90% Submittal
October 2023
C - 6.0
Enlarged Yard Piping Site Plan
90% Submittal
October 2023
C - 7.0
Chemical Pipe Trench Plan and Details - 1
90% Submittal
October 2023
C - 8.0
Chemical Pipe Trench Plan and Details - 2
90% Submittal
October 2023
C - 9.0
Chemical Pipe Trench Plan and Details - 3
90% Submittal
October 2023
C - 10.0
Caustic Trench Partial Plan Views
90% Submittal
October 2023
C - 11.0
Caustic Trench - Photo Modifications
90% Submittal
October 2023
C - 12.0
Chemical Pipe Trench Plan and Detail - 4
90% Submittal
October 2023
C - 13.0
Chemical Pipe Trench Sumps Plans and Section
90% Submittal
October 2023
C - 14.0
Pre-Sed Area Rapid Mix Plans, Sections, and Dosing Details
90% Submittal
October 2023
C - 15.0
Sedimentation Area Static Mixer Vault Plan View
90% Submittal
October 2023
C - 16.0
Sedimentation Area Static Mixer Vault Section and Dosing Details
90% Submittal
October 2023
C - 17.0
Typical Details I
90% Submittal
October 2023
M - 1.0
Partial Site Plan and Area of Work
90% Submittal
October 2023
M - 1.1
Sodium Chlorite and Chlorine Dioxide Facility Overall Isometric
90% Submittal
October 2023
M - 2.0
Sodium Chlorite Bulk Storage Tanks 3D View
90% Submittal
October 2023
M - 2.1
Sodium Chlorite Bulk Storage Tanks Plans
90% Submittal
October 2023
M - 2.2
Sodium Chlorite Bulk Storage Tanks Section - 1
90% Submittal
October 2023
M - 2.3
Sodium Chlorite Bulk Storage Tanks Section - 2
90% Submittal
October 2023
M - 2.4
Sodium Chlorite Storage Area Sections and Details
90% Submittal
October 2023
M - 2.5
Sodium Chlorite Tank Orientation Plan Views
90% Submittal
October 2023
M - 2.6
Sodium Chlorite Tank Details - 1
90% Submittal
October 2023
M - 2.7
Sodium Chlorite Tank Details - 2
90% Submittal
October 2023
M - 2.8
Sodium Chlorite Tank Details - 3
90% Submittal
October 2023
7 of 24
Exhibit E - Construction Document List
Cholla WTP Improvements - Chlorine Dioxide System
GMP 1
12/14/23
M - 3.0
Chlorine Dioxide Building 3D View
90% Submittal
October 2023
M - 3.1
Chlorine Dioxide Building Plan Views
90% Submittal
October 2023
M - 3.2
Chlorine Dioxide Building Sections
90% Submittal
October 2023
M - 4.0
Existing Chlorine Storage Building 3D View
90% Submittal
October 2023
M - 4.1
Chlorine Storage Building Isometric View
90% Submittal
October 2023
M - 4.2
Existing Chlorine Storage Building Plan and Section
90% Submittal
October 2023
M - 4.3
Chlorine Storage Building Section and Details
90% Submittal
October 2023
M - 4.4
Chlorination Room Section and Details
90% Submittal
October 2023
M - 5.0
Disinfection Area Plan Proposed Fire and Alarm Interface
90% Submittal
October 2023
M - 5.1
Disinfection Area Proposed Alarm Control Interface
90% Submittal
October 2023
M - 5.2
Disinfection Area Door Elevations
90% Submittal
October 2023
M - 6.0
Typical Details - 1
90% Submittal
October 2023
M - 6.1
Typical Details - 2
90% Submittal
October 2023
M - 6.2
Typical Details - 3
90% Submittal
October 2023
M - 6.3
Typical Details - 4
90% Submittal
October 2023
M - 6.4
Typical Details - 5
90% Submittal
October 2023
M - 6.5
Typical Details - 6
90% Submittal
October 2023
M - 6.6
Typical Details - 7
90% Submittal
October 2023
S - 1
General Structural Notes 1
90% Submittal
October 2023
S - 2
General Structural Notes 2
90% Submittal
October 2023
S - 3
General Structural Notes 3
90% Submittal
October 2023
S - 4
General Structural Notes 5
90% Submittal
October 2023
S - 5
Standard Sections and Details 1
90% Submittal
October 2023
S - 6
Standard Sections and Details 2
90% Submittal
October 2023
S - 7
Standard Sections and Details 3
90% Submittal
October 2023
S - 8
Standard Sections and Details 4
90% Submittal
October 2023
S - 9
Sodium Chlorite and Chlorine Dioxide Facility Foundation Plan
90% Submittal
October 2023
S - 10
Chlorine Dioxide Facility Upper Plan
90% Submittal
October 2023
S - 11
Sodium Chlorite and Chlorine Dioxide Facility Sections and Details 1
90% Submittal
October 2023
S - 12
Sodium Chlorite and Chlorine Dioxide Facility Sections and Details 2
90% Submittal
October 2023
S - 13
Sodium Chlorite and Chlorine Dioxide Facility Sections and Details 3
90% Submittal
October 2023
A - 1
Chlorine Dioxide Building Schedules
90% Submittal
October 2023
A - 2
Chlorine Dioxide Building Site Plan
90% Submittal
October 2023
A - 3
Chlorine Dioxide Building Life Safety Plan
90% Submittal
October 2023
A - 4
Chlorine Dioxide Building Floor Plan
90% Submittal
October 2023
A - 5
Chlorine Dioxide Building Roof Plan
90% Submittal
October 2023
A - 6
Chlorine Dioxide Building North & South Elevation
90% Submittal
October 2023
A - 7
Chlorine Dioxide Building East & West Elevation
90% Submittal
October 2023
A - 8
Chlorine Dioxide Building Building Sections
90% Submittal
October 2023
A - 9
Chlorine Dioxide Building Typical Details 1
90% Submittal
October 2023
A - 10
Chlorine Dioxide Building Typical Details 2
90% Submittal
October 2023
H - 1.0
HVAC Specifications
90% Submittal
October 2023
H - 2.0
HVAC Plan
90% Submittal
October 2023
H - 3.0
HVAC Details
90% Submittal
October 2023
H - 4.0
HVAC Details
90% Submittal
October 2023
E - 1.0
Electrical Symbols and Legend Sheet 1
90% Submittal
October 2023
E - 1.1
Electrical Symbols and Legend Sheet 2
90% Submittal
October 2023
E - 2.0
MCC-2 Single Line Diagram Modifications (Sheet 1 of 2)
90% Submittal
October 2023
E - 2.1
MCC-2 Single Line Diagram Modifications (Sheet 2 of 2)
90% Submittal
October 2023
E - 2.2
PNL-EL-0101 Single Line Diagram
90% Submittal
October 2023
E - 2.3
Chemical Area Load Summary and Panel Schedule
90% Submittal
October 2023
E - 3.0
Electrical Overall Site Plan
90% Submittal
October 2023
E - 3.1
Chemical Area Enlarged Plan Electrical Demolition
90% Submittal
October 2023
8 of 24
Exhibit E - Construction Document List
Cholla WTP Improvements - Chlorine Dioxide System
GMP 1
12/14/23
E - 3.2
Chemical Building Electrical Plan - Modifications
90% Submittal
October 2023
E - 3.3
New Sodium Chlorite Area Electrical Plan
90% Submittal
October 2023
E - 3.4
New Chlorine Dioxide Building Electrical Plan
90% Submittal
October 2023
E - 3.5
Electrical Room Plan - Modifications
90% Submittal
October 2023
E - 3.6
Sodium Chlorite & Chlorine Dioxide Lighting and Grounding Plan
90% Submittal
October 2023
E - 3.7
Chlorine Building Partial Electrical Plan - Modifications
90% Submittal
October 2023
E - 4.0
Control Schematic Sheet 1
90% Submittal
October 2023
E - 4.1
Control Schematic Sheet 2
90% Submittal
October 2023
E - 5.0
Power Conduit Block Diagram
90% Submittal
October 2023
E - 5.1
Controls Conduit Block Diagram Sheet 1 of 3
90% Submittal
October 2023
E - 5.2
Controls Conduit Block Diagram Sheet 2 of 3
90% Submittal
October 2023
E - 5.3
Controls Conduit Block Diagram Sheet 3 of 3
90% Submittal
October 2023
E - 6.0
Electrical Details Sheet 1
90% Submittal
October 2023
E - 6.1
Electrical Details Sheet 2
90% Submittal
October 2023
E - 6.2
Electrical Details Sheet 3
90% Submittal
October 2023
I - 1.0
Instrumentation Symbols and Legend 1 of 3
90% Submittal
October 2023
I - 1.1
Instrumentation Symbols and Legend 2 of 3
90% Submittal
October 2023
I - 1.2
Instrumentation Symbols and Legend 3 of 3
90% Submittal
October 2023
I - 2.0
Sodium Chlorite System P&ID
90% Submittal
October 2023
I - 2.1
Chlorine Dioxide Skid #1 P&ID
90% Submittal
October 2023
I - 2.2
Chlorine Dioxide Skid #2 P&ID
90% Submittal
October 2023
I - 2.3
Chlorine Building - Storage Tank P&ID
90% Submittal
October 2023
I - 2.4
Chlorine Building Exhaust Fan/Louver P&ID
90% Submittal
October 2023
I - 2.5
Chlorine Building Chlorine Alarm System - P&ID
90% Submittal
October 2023
I - 2.6
Chlorine/Chlorine Dioxide Building Chlorine Gas Analyzer - P&ID
90% Submittal
October 2023
9 of 24
City of Glendale Standard Form Agreement Between Owner and CM@Risk (May 15, 2023)
T H I S P A G E I S B L A N K
City of Glendale Standard Form Agreement Between Owner and CM@Risk (May 15, 2023)
EXHIBIT F
Statement of All Clarifications and Assumptions (if any)
(9 pages - To be Incorporated by Amendment)
See Attached
Exhibit F – Clarifications and Assumptions
The following scope clarifications and assumptions are based on the 90% Contract Drawings and Specifications. The
assumptions and clarifications provide clarity for scope of work and pricing in addition to the documents as prepared
by Wilson Engineers. In order to reduce the costs to the project, the items below were coordinated, discussed, and
agreed upon between the City of Glendale, McCarthy, and Wilson Engineers. Once the items have been updated on
the 100% documents, they will be removed from the assumptions and clarifications.
General
1. The cost of sewer, power, and chemical usage during construction and start-up is not included.
2. Draining, flushing, and removal of chemicals has been assumed to be by the Owner.
3. Transaction Privilege Tax has been included at 65% of 9.2% based on the project being in the City of Glendale.
4. It has been assumed that any dewatering efforts for removal of existing sludge liquids/solids would be on-site
wasted. No special hazardous waste haul off costs were included.
5. General Liability (G/L) Insurance has been included that meets the requirements of the contract utilizing
McCarthy’s Master Insurance Program. The rate for the G/L Insurance is 0.99%.
6. The following are City of Glendale Project Costs and have not been included in this GMP:
a. Temporary/construction/startup use and permanent utility hookup and usage cost including power,
sewer and water.
b. City Building Permits
c.
Plan review fees and impact costs
d. Chemical costs
e. Soils Report
f.
Special/QA Inspection Fees
g.
MCDES and ADEQ review and permitting fees
h. Permanent Right of way or related construction easement fees
i.
Hazardous Waste removal
j.
Furnishings, Fixtures, and Equipment (FFE) and design of FFE
k.
Asbestos abatement and removal
7. It was agreed that a dedicated security guard would not be required for the scope of work and gate access is
to be managed by McCarthy. Per the Security Specification Section 01561.1.1.C, “Contractor shall make no
claim against the Owner for damage or injury resulting from trespass.”
8. Code upgrades have not been included. It is assumed that all work being performed on existing systems or
structures will leave the structures code compliant and not require any additional work to bring the systems
or structures up to code.
9. It is assumed that the Owner is responsible for any cost associated with the Independent Testing Lab required
in specification section 01451 Testing Laboratory Services Furnished By Owner.
10. Remediation of hazardous materials, if encountered, has not been included.
11. Construction schedule provided is per the contract documents and is subject to change with changes in
scope.
12. No materials will be salvaged and returned to the Owner.
13. The GMP is submitted as an overall project GMP. No work categories are considered line-item GMPs, and
CMAR reserves the right to cover overruns within any work category from other work categories within the
GMP.
14. Payment Schedule of Values for equipment/ materials included in Work Categories 11A.1 Weight Scales and
11C Chemical Transfer Pumps shall be as follows.
a. Approved Submittals – 10%
b. Approval of Draft Operation and Maintenance Manuals – 3%
c.
Equipment/ Material Delivery Including Spare Parts - Balance
d. The following where applicable:
i. Manufacturer Startup and Services – 5%
ii. Approval of Final O&M - 2%
iii. Owner Training - 5%
15. Procurement and post construction services have been included in the amount of 5% for the procurement of
the chlorine scales and chemical transfer pumps. This amount will be considered a Cost of construction
services to be billed on a percent complete basis (at the same percent complete as the equipment).
16. All equipment not included in the rate table will be billed at a daily rate consisting of the ADOT Hourly
Equipment Rental Rate (HERR) at 8 hours/day.
02B Earthwork and Yard Piping
A Geotechnical report is not currently available for the project. The assumptions and clarifications below detail the
cost of work included in the GMP.
1. 08” Scarification and recompaction has been included under new structures and pavement.
2. Excavation and backfill has been included as shown on the drawings. Over-excavation and backfill has not
been included.
3. Onsite native soils will be utilized as Structure Backfill. Imported fill has not been included.
Additional excavation below the structures where loose soil and/or large rock may be encountered that may
need remedial work with CLSM has not been included.
4. Backfill material will be stockpiled on-site. Excess materials will be hauled off site.
5. Hard dig/rock excavation has not been included.
6. Landscaping decomposed granite has been included as 03” thick for disturbed areas.
7. Temporary roadways, laydown areas, and parking lots if required has not been included.
8. Supply and install of the pre-cast chem trench has not been included; only excavation, bedding, and backfill
has been included. All work associated with the chemical trench has been moved to an Allowance.
9. Helical piles and ductbank crossing supports for chem trench has not been included.
10. All yard pipe trench excavation will be backfilled above the pipe bedding zone with native onsite material to
existing grade or bottom of pavement section.
11. Pipe bedding will be placed on undisturbed native soil.
12. All liquids and solids removed from pipelines to accommodate tie-ins will be returned to the plant process and
will not be hauled off-site.
13. Thrust blocks have not been included if not specifically shown on the Contract Drawings
14. The purchase of construction water has not been included. It is the intent to utilize the onsite non-potable
water system yard hydrants for construction water needs.
03A Concrete
1. Concrete wall finishes: Specifications require a “smooth and level finish”. Below provides the ACI level of
finish to be used that qualifies as smooth and level.
a. Not exposed to view ACI 301 SF-1.0
b. Exposed to view ACI 301 SF-2.0
2. No air entrainment is included. Air entrainment is included in the specification but is not necessary due to the
temperature zone area of the project.
05A Misc Metals
1. Exception to section 06611-2.2.C Grating color to be yellow and gray not green as agreed upon by the EOR.
2. Exception is taken to Drwg M-28, Detail 8 – Stud hardware. Strongwell standard hold-down saddle clips &
bolt assemblies provided.
3. Design for FRP grating support structure is not included. Contract drawings did not include layout of
requirements. It is assumed Wilson will provide this design on the 100% documents . Current material cost
includes 16 each C-8 FRP Channel at 6 LF long.
09A Coatings and Paintings
1. Coatings for Chemical Unloading has not been included in the cost.
2. Field coating of factory finished pumps, motors or equipment have not been included. Factory coatings will
meet the specification requirements.
15A – Process Mechanical Piping
1. In the existing Chlorine Building, it is assumed the City will be responsible for the removal of the Chlorine
Tanks without assistance from McCarthy. City is also responsible for the connection to the Chlorine Tanks
after the tank scales have been installed.
2. In the existing Chlorine Building, the piping for the existing Chlorine systems will not be modified. The new 2
EA Chlorine tanks will connect to the existing vent/burp header as well as the existing discharge header.
3. McCarthy's scope of work for the installation of the 2 EA new FRP Chemical Storage Tanks for Sodium Chlorite
does not include an initial tank fill of chemical. McCarthy will turn the tank over empty to the City after the
hydro test approvals.
4. The FRP Chemical Tanks spec requires a hot water detergent cleaning after the installation of the Tank.
McCarthy has included basic tank cleaning with standard detergent and hot water. McCarthy will submit a
tank cleaning procedure that includes filling and draining with potable water. Any damages due to tank
cleaning other than with potable water will be the responsibility of the City.
5. The demolition of the 2 EA Tanks and associated piping in front of the UF Building is included in the total cost.
This is not show on the drawings but will be required.
6. Pipe Support engineering included by McCarthy will include calculations for dead loads, gravity loading,
seismic, wind, and anchorage. Engineering will not include dynamic loading, expansion and contraction,
thrust loading, or pipe stress analysis. It is assumed these items will be completed by Wilson Engineers.
16A Electrical, Instrumentation & Controls
1. No cost for relocating Ductbank is included, the cost associated with the fiber work is now included in an
allowance.
2. Programming is included for PLC signals shown on the drawings, no SCADA or other programming included.
This will be provided by the City of Glendale.
City of Glendale Standard Form Agreement Between Owner and CM@Risk (May 15, 2023)
T H I S P A G E I S B L A N K
City of Glendale Standard Form Agreement Between Owner and CM@Risk (May 15, 2023)
EXHIBIT G
Schedule of Major Milestones
(9 pages - To be Incorporated by Amendment)
See Attached
Activity ID
Activity Name
Orig
Dur
Start
Finish
Total
Float
Cholla Water
Cholla Water Treatment Plant Improvements
458
02-Jun-23 A
11-Apr-25
0
Milestones
Milestones
350
27-Nov-23
11-Apr-25
0
MILE-130
*Milestone: Glendale Council Meeting (10/24/23)
0
27-Nov-23
0
SUM-DUR-B
Summary - Construction (CAL)
349
29-Nov-23
11-Apr-25
0
MILE-110
*Milestone: Construction Start
0
29-Nov-23
179
MILE-140
Cholla WTP 2024 Shutdown
23
08-Jan-24*
07-Feb-24
0
MILE-100
*Milestone: Substantial Completion GMP 1
0
28-Feb-25
0
MILE-120
*Milestone: Construction Complete
0
11-Apr-25
0
Preconstruct
Preconstruction
379
02-Jun-23 A
19-Dec-24
49
GMP 1a Early P
GMP 1a Early Procurement
229
02-Jun-23 A
16-May-24
171
GMP 1a Develop
GMP 1a Development & Approval
39
02-Jun-23 A
18-Aug-23 A
PR-GMP1-1000
Early Procurement - Building Connected Setup and Send Invitation for Bids
1
02-Jun-23 A
02-Jun-23 A
PR-GMP1-1010
Early Procurement - Front End Documents Issued
1
13-Jun-23 A
13-Jun-23 A
PR-GMP1-1020
Early Procurement - Bids Due
10
14-Jun-23 A
22-Jun-23 A
PR-GMP1-1030
Early Procurement - Scope Sheets Complete
2
23-Jun-23 A
26-Jun-23 A
PR-GMP1-1040
Early Procurement - Draft Early Procurement Package Complete
1
27-Jun-23 A
27-Jun-23 A
PR-GMP1-1050
Early Procurement - Executive Review
2
28-Jun-23 A
29-Jun-23 A
PR-GMP1-1060
Early Procurement - Early Procurement Package Submitted
1
29-Jun-23 A
29-Jun-23 A
PR-GMP1-1070
Early Procurement - Glendale Review Early Procurement Package
19
30-Jun-23 A
14-Jul-23 A
PR-GMP1-1080
Early Procurement - Glendale Approve Early Procurement Package
5
17-Jul-23 A
17-Jul-23 A
PR-GMP1-1090
Early Procurement - Glendale Execute Allowance Request
7
02-Aug-23 A 18-Aug-23 A
GMP 1a Procure
GMP 1a Procurement
197
17-Jul-23 A
16-May-24
171
Chlorine Tank S
Chlorine Tank Scales and Regulators
114
21-Jul-23 A
29-Jan-24
249
PR-GMP1-1290 Chlorine Tank Scales, Regulator, & Closure Valve Submittal Prep
20
21-Jul-23 A
24-Oct-23
249
PR-GMP1-1280 Execute Purchase Order with MISCO
10
21-Aug-23 A
20-Nov-23
249
PR-GMP1-1300 McCarthy Submittal Review
5
25-Oct-23
31-Oct-23
249
PR-GMP1-1310 Owner/Engineer Submittal Review
20
01-Nov-23
30-Nov-23
249
PR-GMP1-1320 Fabrication & Delivery
40
01-Dec-23
29-Jan-24
249
Sodium Chlorit
Sodium Chlorite Tanks
160
21-Aug-23 A
02-Apr-24
171
PR-GMP1-1160 Execute Purchase Order with American Fiberglass
10
21-Aug-23 A
24-Oct-23
171
PR-GMP1-1170 Chemical Storage Tank Submittal Prep
10
23-Oct-23
03-Nov-23
171
PR-GMP1-1180 McCarthy Submittal Review
3
06-Nov-23
08-Nov-23
171
PR-GMP1-1190 Owner/Engineer Submittal Review
20
09-Nov-23
08-Dec-23
171
PR-GMP1-1240 Fabrication & Delivery
80
11-Dec-23
02-Apr-24
171
Chlorine Dioxid
Chlorine Dioxide Generation Skids
197
17-Jul-23 A
16-May-24
161
PR-GMP1-1330 Letter of Intent to Evoqua
10
17-Jul-23 A
20-Jul-23 A
PR-GMP1-1200 Chlorine Dioxide Skid Electrical Submittal Prep
30
21-Jul-23 A
20-Oct-23 A
PR-GMP1-1250 Chlorine Dioxide Skid Mechanical Submittal Prep
30
21-Jul-23 A
20-Oct-23 A
PR-GMP1-1100 Execute Purchase Order with Evoqua
10
21-Aug-23 A 25-Sep-23 A
PR-GMP1-1210 McCarthy Electrical Submittal Review
5
23-Oct-23
27-Oct-23
161
PR-GMP1-1260 McCarthy Mechanical Submittal Review
5
23-Oct-23
27-Oct-23
161
PR-GMP1-1220 Owner/Engineer Electrical Submittal Review
20
30-Oct-23
28-Nov-23
161
PR-GMP1-1270 Owner/Engineer Mechanical Submittal Review
20
30-Oct-23
28-Nov-23
161
PR-GMP1-1230 Fabrication & Delivery
120
29-Nov-23
16-May-24
161
GMP 1
GMP 1
347
27-Jun-23 A
19-Dec-24
49
GMP 1 Developm
GMP 1 Development & Approval
77
27-Jun-23 A
28-Nov-23
0
PR-GMP1-1000
30% Cost Model - Develop Package
18
27-Jun-23 A
10-Aug-23 A
Oct
Nov
Dec
Jan
Feb
Mar
Apr
May
Jun
Jul
Aug
Sep
Oct
Nov
Dec
Jan
Feb
Mar
Apr
May un
2024
2025
*Milestone: Glendale Council Meeting (10/24/23)
Summary - C
*Milestone: Construction Start
Cholla WTP 2024 Shutdown
*Milestone: Substantial
*Milestone: C
Connected Setup and Send Invitation for Bids
t End Documents Issued
s Due
cope Sheets Complete
raft Early Procurement Package Complete
Executive Review
arly Procurement Package Submitted
t - Glendale Review Early Procurement Package
nt - Glendale Approve Early Procurement Package
curement - Glendale Execute Allowance Request
Chlorine Tank Scales, Regulator, & Closure Valve Submittal Prep
Execute Purchase Order with MISCO
McCarthy Submittal Review
Owner/Engineer Submittal Review
Fabrication & Delivery
Execute Purchase Order with American Fiberglass
Chemical Storage Tank Submittal Prep
McCarthy Submittal Review
Owner/Engineer Submittal Review
Fabrication & Delivery
Evoqua
Chlorine Dioxide Skid Electrical Submittal Prep
Chlorine Dioxide Skid Mechanical Submittal Prep
Execute Purchase Order with Evoqua
McCarthy Electrical Submittal Review
McCarthy Mechanical Submittal Review
Owner/Engineer Electrical Submittal Review
Owner/Engineer Mechanical Submittal Review
Fabrication & Delivery
Model - Develop Package
Run Date - 24-Oct-23
Start Date - 02-Jun-23
Finish Date - 11-Apr-25
Data Date - 23-Oct-23
Remaining Level of Effort
Actual Level of Effort
Actual Work
Remaining Work
Critical Remaining Work
Cholla Water Treatment Plant Improvements
Full Detail with Float
1 of 9
16 of 24
Activity ID
Activity Name
Orig
Dur
Start
Finish
Total
Float
PR-GMP1-1050
30% Cost Model - Executive Review
4
11-Aug-23 A
15-Aug-23 A
PR-GMP1-1060
30% Cost Model - Submitted
1
16-Aug-23 A 16-Aug-23 A
PR-GMP1-1070
30% Cost Model - Glendale Review
12
17-Aug-23 A
11-Oct-23 A
PR-GMP1-1080
GMP 1 - Develop Package
27
27-Sep-23 A
09-Nov-23
0
PR-GMP1-1140
GMP 1 - Submitted
1
10-Nov-23
10-Nov-23
0
PR-GMP1-1130
GMP 1 - Glendale Review
9
13-Nov-23
27-Nov-23
0
PR-GMP1-1090
GMP 1 - Glendale Issue NTP
1
28-Nov-23
28-Nov-23
0
Contracts
Contracts
10
29-Nov-23
12-Dec-23
169
PR-CNT-100
Contract - Civil
10
29-Nov-23
12-Dec-23
169
PR-CNT-110
Contract - Mechanical
10
29-Nov-23
12-Dec-23
169
GMP 1 Procurem
GMP 1 Procurement
270
29-Nov-23
19-Dec-24
49
Air Scour Blow
Air Scour Blower
190
29-Nov-23
26-Aug-24
129
PR-GMP1-1150 Execute Purchase Order
20
29-Nov-23
27-Dec-23
129
PR-GMP1-1240 Air Scour Blower Submittal Prep
60
28-Dec-23
21-Mar-24
129
PR-GMP1-1850 McCarthy Submittal Review
10
22-Mar-24
04-Apr-24
129
PR-GMP1-1890 Owner/Engineer Submittal Review
20
05-Apr-24
02-May-24
129
PR-GMP1-1990 Air Scour Blower Fab & Deliver
80
03-May-24
26-Aug-24
129
Air Scour Moto
Air Scour Motor Operated Valves
235
29-Nov-23
29-Oct-24
84
PR-GMP1-1160 Execute Purchase Order
20
29-Nov-23
27-Dec-23
84
PR-GMP1-1250 Air Scour MOV Submittal Prep
40
28-Dec-23
22-Feb-24
84
PR-GMP1-1560 McCarthy Submittal Review
5
23-Feb-24
29-Feb-24
84
PR-GMP1-1680 Owner/Engineer Submittal Review
20
01-Mar-24
28-Mar-24
84
PR-GMP1-1870 Air Scour MOV Fab & Deliver
150
29-Mar-24
29-Oct-24
84
Chemical Trans
Chemical Transfer Pump
185
29-Nov-23
19-Aug-24
125
PR-GMP1-1170 Execute Purchase Order
20
29-Nov-23
27-Dec-23
125
PR-GMP1-1260 Transfer Pump Submittal Prep
40
28-Dec-23
22-Feb-24
125
PR-GMP1-1570 McCarthy Submittal Review
5
23-Feb-24
29-Feb-24
125
PR-GMP1-1690 Owner/Engineer Submittal Review
20
01-Mar-24
28-Mar-24
125
PR-GMP1-1880 Transfer Pump Fab & Deliver
100
29-Mar-24
19-Aug-24
125
HVAC Units
HVAC Units
115
29-Nov-23
09-May-24
196
PR-GMP1-1190 Execute Subcontract
20
29-Nov-23
27-Dec-23
196
PR-GMP1-1280 Chlorine Dioxide Bldg HVAC Submittal Prep
20
28-Dec-23
25-Jan-24
196
PR-GMP1-1430 Chlroine Dioxide Bldg HVAC McCarthy Submittal Review
5
26-Jan-24
01-Feb-24
196
PR-GMP1-1460 Chlroine Dioxide Bldg HVAC Owner/Engineer Submittal Review
20
02-Feb-24
29-Feb-24
196
PR-GMP1-1700 Chlroine Dioxide Bldg HVAC Fab & Deliver
50
01-Mar-24
09-May-24
196
Chemical Sump
Chemical Sump Pump
135
29-Nov-23
07-Jun-24
145
PR-GMP1-1200 Execute Purchase Order
20
29-Nov-23
27-Dec-23
145
PR-GMP1-1290 Sump Pump Submittal Prep
30
28-Dec-23
08-Feb-24
145
PR-GMP1-1480 McCarthy Submittal Review
5
09-Feb-24
15-Feb-24
145
PR-GMP1-1530 Owner/Engineer Submittal Review
20
16-Feb-24
14-Mar-24
145
PR-GMP1-1820 Sump Pump Fab & Deliver
60
15-Mar-24
07-Jun-24
145
Electrical
Electrical
270
29-Nov-23
19-Dec-24
15
PR-GMP1-1210 Execute Subcontract
20
29-Nov-23
27-Dec-23
0
Programmable
Programmable Logic Controller (PLC)
230
28-Dec-23
19-Nov-24
20
PR-GMP1-13
PLC Submittal Prep
40
28-Dec-23
22-Feb-24
20
PR-GMP1-15
McCarthy Submittal Review
10
23-Feb-24
07-Mar-24
20
PR-GMP1-173 Owner/Engineer Submittal Review
20
08-Mar-24
04-Apr-24
20
PR-GMP1-19
PLC Fab & Deliver
160
05-Apr-24
19-Nov-24
20
Oct
Nov
Dec
Jan
Feb
Mar
Apr
May
Jun
Jul
Aug
Sep
Oct
Nov
Dec
Jan
Feb
Mar
Apr
May un
2024
2025
Model - Executive Review
Model - Submitted
30% Cost Model - Glendale Review
GMP 1 - Develop Package
GMP 1 - Submitted
GMP 1 - Glendale Review
GMP 1 - Glendale Issue NTP
Contract - Civil
Contract - Mechanical
Execute Purchase Order
Air Scour Blower Submittal Prep
McCarthy Submittal Review
Owner/Engineer Submittal Review
Air Scour Blower Fab & Deliver
Execute Purchase Order
Air Scour MOV Submittal Prep
McCarthy Submittal Review
Owner/Engineer Submittal Review
Air Scour MOV Fab & Deliver
Execute Purchase Order
Transfer Pump Submittal Prep
McCarthy Submittal Review
Owner/Engineer Submittal Review
Transfer Pump Fab & Deliver
Execute Subcontract
Chlorine Dioxide Bldg HVAC Submittal Prep
Chlroine Dioxide Bldg HVAC McCarthy Submittal Review
Chlroine Dioxide Bldg HVAC Owner/Engineer Submittal Review
Chlroine Dioxide Bldg HVAC Fab & Deliver
Execute Purchase Order
Sump Pump Submittal Prep
McCarthy Submittal Review
Owner/Engineer Submittal Review
Sump Pump Fab & Deliver
Execute Subcontract
PLC Submittal Prep
McCarthy Submittal Review
Owner/Engineer Submittal Review
PLC Fab & Deliver
Run Date - 24-Oct-23
Start Date - 02-Jun-23
Finish Date - 11-Apr-25
Data Date - 23-Oct-23
Remaining Level of Effort
Actual Level of Effort
Actual Work
Remaining Work
Critical Remaining Work
Cholla Water Treatment Plant Improvements
Full Detail with Float
2 of 9
17 of 24
Activity ID
Activity Name
Orig
Dur
Start
Finish
Total
Float
Pump Control
Pump Control Panels
190
28-Dec-23
24-Sep-24
57
PR-GMP1-13
Pump Control Panels Submittal Prep
40
28-Dec-23
22-Feb-24
57
PR-GMP1-16
McCarthy Submittal Review
10
23-Feb-24
07-Mar-24
57
PR-GMP1-174 Owner/Engineer Submittal Review
20
08-Mar-24
04-Apr-24
57
PR-GMP1-192 Pump Control Panels Fab & Deliver
120
05-Apr-24
24-Sep-24
57
Fire Alarm Acc
Fire Alarm Access Panel
170
28-Dec-23
26-Aug-24
80
PR-GMP1-132 FACP Submittal Prep
40
28-Dec-23
22-Feb-24
80
PR-GMP1-16
McCarthy Submittal Review
10
23-Feb-24
07-Mar-24
80
PR-GMP1-175 Owner/Engineer Submittal Review
20
08-Mar-24
04-Apr-24
80
PR-GMP1-193 FACP Fab & Deliver
100
05-Apr-24
26-Aug-24
80
Chemical Unlo
Chemical Unloading Panel
190
28-Dec-23
24-Sep-24
54
PR-GMP1-13
Chemical Unloading Panel Submittal Prep
40
28-Dec-23
22-Feb-24
54
PR-GMP1-165 McCarthy Submittal Review
10
23-Feb-24
07-Mar-24
54
PR-GMP1-178 Owner/Engineer Submittal Review
20
08-Mar-24
04-Apr-24
54
PR-GMP1-19
Chemical Unloading Panel Fab & Deliver
120
05-Apr-24
24-Sep-24
54
Access Contro
Access Control Cabinet
250
28-Dec-23
19-Dec-24
0
PR-GMP1-133 Access Control Cabinet Submittal Prep
40
28-Dec-23
22-Feb-24
0
PR-GMP1-162 McCarthy Submittal Review
10
23-Feb-24
07-Mar-24
0
PR-GMP1-17
Owner/Engineer Submittal Review
20
08-Mar-24
04-Apr-24
0
PR-GMP1-194 Access Control Cabinet Fab & Deliver
180
05-Apr-24
19-Dec-24
0
Lighting
Lighting
85
28-Dec-23
25-Apr-24
180
PR-GMP1-134 Lighting Submittal Prep
20
28-Dec-23
25-Jan-24
180
PR-GMP1-144 McCarthy Submittal Review
5
26-Jan-24
01-Feb-24
180
PR-GMP1-14
Owner/Engineer Submittal Review
20
02-Feb-24
29-Feb-24
180
PR-GMP1-17
Lighting Fab & Deliver
40
01-Mar-24
25-Apr-24
180
Chlorine Leak
Chlorine Leak Detection Panel
200
28-Dec-23
08-Oct-24
47
PR-GMP1-14
Chlorine Leak Detection Panel Submittal Prep
40
28-Dec-23
22-Feb-24
47
PR-GMP1-16
McCarthy Submittal Review
10
23-Feb-24
07-Mar-24
47
PR-GMP1-17
Owner/Engineer Submittal Review
20
08-Mar-24
04-Apr-24
47
PR-GMP1-19
Chlorine Leak Detection Panel Fab & Deliver
130
05-Apr-24
08-Oct-24
47
MCC Breaker
MCC Breaker
105
28-Dec-23
23-May-24
148
PR-GMP1-135 MCC Breaker Submittal Prep
30
28-Dec-23
08-Feb-24
148
PR-GMP1-14
McCarthy Submittal Review
5
09-Feb-24
15-Feb-24
148
PR-GMP1-154 Owner/Engineer Submittal Review
20
16-Feb-24
14-Mar-24
148
PR-GMP1-183 MCC Breaker Fab & Deliver
50
15-Mar-24
23-May-24
148
Transformer
Transformer
175
28-Dec-23
03-Sep-24
68
PR-GMP1-13
Transformer Submittal Prep
30
28-Dec-23
08-Feb-24
68
PR-GMP1-15
McCarthy Submittal Review
5
09-Feb-24
15-Feb-24
68
PR-GMP1-155 Owner/Engineer Submittal Review
20
16-Feb-24
14-Mar-24
68
PR-GMP1-184 Transformer Fab & Deliver
120
15-Mar-24
03-Sep-24
68
Power & Light
Power & Lighting Distribution Panels
230
28-Dec-23
19-Nov-24
13
PR-GMP1-13
Power & Lighting Distribution Panels Submittal Prep
40
28-Dec-23
22-Feb-24
13
PR-GMP1-163 McCarthy Submittal Review
10
23-Feb-24
07-Mar-24
13
PR-GMP1-17
Owner/Engineer Submittal Review
20
08-Mar-24
04-Apr-24
13
PR-GMP1-195 Power & Lighting Distribution Panels Fab & Deliver
160
05-Apr-24
19-Nov-24
13
FRP Grating
FRP Grating
160
29-Nov-23
15-Jul-24
122
PR-GMP1-1220 Execute Purchase Order
20
29-Nov-23
27-Dec-23
122
PR-GMP1-1380 FRP Grating Submittal Prep
30
28-Dec-23
08-Feb-24
122
Oct
Nov
Dec
Jan
Feb
Mar
Apr
May
Jun
Jul
Aug
Sep
Oct
Nov
Dec
Jan
Feb
Mar
Apr
May un
2024
2025
Pump Control Panels Submittal Prep
McCarthy Submittal Review
Owner/Engineer Submittal Review
Pump Control Panels Fab & Deliver
FACP Submittal Prep
McCarthy Submittal Review
Owner/Engineer Submittal Review
FACP Fab & Deliver
Chemical Unloading Panel Submittal Prep
McCarthy Submittal Review
Owner/Engineer Submittal Review
Chemical Unloading Panel Fab & Deliver
Access Control Cabinet Submittal Prep
McCarthy Submittal Review
Owner/Engineer Submittal Review
Access Control Cabinet Fab & Deliver
Lighting Submittal Prep
McCarthy Submittal Review
Owner/Engineer Submittal Review
Lighting Fab & Deliver
Chlorine Leak Detection Panel Submittal Prep
McCarthy Submittal Review
Owner/Engineer Submittal Review
Chlorine Leak Detection Panel Fab & Deliver
MCC Breaker Submittal Prep
McCarthy Submittal Review
Owner/Engineer Submittal Review
MCC Breaker Fab & Deliver
Transformer Submittal Prep
McCarthy Submittal Review
Owner/Engineer Submittal Review
Transformer Fab & Deliver
Power & Lighting Distribution Panels Submittal Prep
McCarthy Submittal Review
Owner/Engineer Submittal Review
Power & Lighting Distribution Panels Fab & Del
Execute Purchase Order
FRP Grating Submittal Prep
Run Date - 24-Oct-23
Start Date - 02-Jun-23
Finish Date - 11-Apr-25
Data Date - 23-Oct-23
Remaining Level of Effort
Actual Level of Effort
Actual Work
Remaining Work
Critical Remaining Work
Cholla Water Treatment Plant Improvements
Full Detail with Float
3 of 9
18 of 24
Activity ID
Activity Name
Orig
Dur
Start
Finish
Total
Float
PR-GMP1-1510 McCarthy Submittal Review
10
09-Feb-24
22-Feb-24
122
PR-GMP1-1640 Owner/Engineer Submittal Review
20
23-Feb-24
21-Mar-24
122
PR-GMP1-1860 FRP Grating Fab & Deliver
80
22-Mar-24
15-Jul-24
122
Masonry
Masonry
85
29-Nov-23
28-Mar-24
172
PR-GMP1-2000 Execute Sub Contract Order
20
29-Nov-23
27-Dec-23
172
PR-GMP1-2010 Masonry Submittal Prep
20
28-Dec-23
25-Jan-24
172
PR-GMP1-2020 McCarthy Submittal Review
5
26-Jan-24
01-Feb-24
172
PR-GMP1-2030 Owner/Engineer Submittal Review
20
02-Feb-24
29-Feb-24
172
PR-GMP1-2040 Masonry Fab & Deliver
20
01-Mar-24
28-Mar-24
172
Coatings
Coatings
85
29-Nov-23
28-Mar-24
159
PR-GMP1-2300 Execute Sub Contract Order
20
29-Nov-23
27-Dec-23
159
PR-GMP1-2310 Coatings Submittal Prep
20
28-Dec-23
25-Jan-24
159
PR-GMP1-2320 McCarthy Submittal Review
5
26-Jan-24
01-Feb-24
159
PR-GMP1-2330 Owner/Engineer Submittal Review
20
02-Feb-24
29-Feb-24
159
PR-GMP1-2340 Coatings Fab & Deliver
20
01-Mar-24
28-Mar-24
159
Fire Protection
Fire Protection
115
29-Nov-23
09-May-24
145
PR-GMP1-2250 Execute Sub Contract Order
20
29-Nov-23
27-Dec-23
145
PR-GMP1-2260 Fire Protection Submittal Prep
30
28-Dec-23
08-Feb-24
145
PR-GMP1-2270 McCarthy Submittal Review
5
09-Feb-24
15-Feb-24
145
PR-GMP1-2280 Owner/Engineer Submittal Review
20
16-Feb-24
14-Mar-24
145
PR-GMP1-2290 Fire Protection Fab & Deliver
40
15-Mar-24
09-May-24
145
Doors & Hardw
Doors & Hardware
105
29-Nov-23
25-Apr-24
152
PR-GMP1-2200 Execute Sub Contract Order
20
29-Nov-23
27-Dec-23
152
PR-GMP1-2210 Doors & Hardware Submittal Prep
20
28-Dec-23
25-Jan-24
152
PR-GMP1-2220 McCarthy Submittal Review
5
26-Jan-24
01-Feb-24
152
PR-GMP1-2230 Owner/Engineer Submittal Review
20
02-Feb-24
29-Feb-24
152
PR-GMP1-2240 Doors & Hardware Fab & Deliver
40
01-Mar-24
25-Apr-24
152
Roofing
Roofing
95
29-Nov-23
11-Apr-24
182
PR-GMP1-2150 Execute Sub Contract Order
20
29-Nov-23
27-Dec-23
182
PR-GMP1-2160 Roofing Submittal Prep
20
28-Dec-23
25-Jan-24
182
PR-GMP1-2170 McCarthy Submittal Review
5
26-Jan-24
01-Feb-24
182
PR-GMP1-2180 Owner/Engineer Submittal Review
20
02-Feb-24
29-Feb-24
182
PR-GMP1-2190 Roofing Fab & Deliver
30
01-Mar-24
11-Apr-24
182
Misc. Metals
Misc. Metals
105
29-Nov-23
25-Apr-24
184
PR-GMP1-2100 Execute Sub Contract Order
20
29-Nov-23
27-Dec-23
184
PR-GMP1-2110 Misc. Metals Submittal Prep
20
28-Dec-23
25-Jan-24
184
PR-GMP1-2120 McCarthy Submittal Review
5
26-Jan-24
01-Feb-24
184
PR-GMP1-2130 Owner/Engineer Submittal Review
20
02-Feb-24
29-Feb-24
184
PR-GMP1-2140 Misc. Metals Fab & Deliver
40
01-Mar-24
25-Apr-24
184
Structural Steel
Structural Steel
105
29-Nov-23
25-Apr-24
164
PR-GMP1-2050 Execute Sub Contract Order
20
29-Nov-23
27-Dec-23
164
PR-GMP1-2060 Structural Steel Submittal Prep
30
28-Dec-23
08-Feb-24
164
PR-GMP1-2070 McCarthy Submittal Review
5
09-Feb-24
15-Feb-24
164
PR-GMP1-2080 Owner/Engineer Submittal Review
20
16-Feb-24
14-Mar-24
164
PR-GMP1-2090 Structural Steel Fab & Deliver
30
15-Mar-24
25-Apr-24
164
GMP 1 Const
GMP 1 Construction
339
13-Dec-23
11-Apr-25
0
Demolition
Demolition
15
13-Dec-23
04-Jan-24
169
STE-DEM-100
Demolition Per Drawings
15
13-Dec-23
04-Jan-24
169
Oct
Nov
Dec
Jan
Feb
Mar
Apr
May
Jun
Jul
Aug
Sep
Oct
Nov
Dec
Jan
Feb
Mar
Apr
May un
2024
2025
McCarthy Submittal Review
Owner/Engineer Submittal Review
FRP Grating Fab & Deliver
Execute Sub Contract Order
Masonry Submittal Prep
McCarthy Submittal Review
Owner/Engineer Submittal Review
Masonry Fab & Deliver
Execute Sub Contract Order
Coatings Submittal Prep
McCarthy Submittal Review
Owner/Engineer Submittal Review
Coatings Fab & Deliver
Execute Sub Contract Order
Fire Protection Submittal Prep
McCarthy Submittal Review
Owner/Engineer Submittal Review
Fire Protection Fab & Deliver
Execute Sub Contract Order
Doors & Hardware Submittal Prep
McCarthy Submittal Review
Owner/Engineer Submittal Review
Doors & Hardware Fab & Deliver
Execute Sub Contract Order
Roofing Submittal Prep
McCarthy Submittal Review
Owner/Engineer Submittal Review
Roofing Fab & Deliver
Execute Sub Contract Order
Misc. Metals Submittal Prep
McCarthy Submittal Review
Owner/Engineer Submittal Review
Misc. Metals Fab & Deliver
Execute Sub Contract Order
Structural Steel Submittal Prep
McCarthy Submittal Review
Owner/Engineer Submittal Review
Structural Steel Fab & Deliver
Demolition Per Drawings
Run Date - 24-Oct-23
Start Date - 02-Jun-23
Finish Date - 11-Apr-25
Data Date - 23-Oct-23
Remaining Level of Effort
Actual Level of Effort
Actual Work
Remaining Work
Critical Remaining Work
Cholla Water Treatment Plant Improvements
Full Detail with Float
4 of 9
19 of 24
Activity ID
Activity Name
Orig
Dur
Start
Finish
Total
Float
Yard
Yard
271
13-Dec-23
07-Jan-25
38
Civil
Civil
72
05-Jan-24
15-Apr-24
222
YRD-CIV-120
Excavate & Compact for Emergency Generator
3
05-Jan-24
09-Jan-24
275
YRD-CIV-100
Excavate Chemical Trenches
10
24-Jan-24
06-Feb-24
206
YRD-CIV-130
Backfill Emergency Generator Pad
1
24-Jan-24
24-Jan-24
275
YRD-CIV-150
Fine Grade for Chemical Unloading Area/Apron
2
14-Feb-24
15-Feb-24
252
YRD-CIV-170
D/L/B Potable Water Line to Chemical Storage & Feed Area
5
15-Feb-24
21-Feb-24
217
YRD-CIV-140
Fine Garde for Asphalt Pavement
3
28-Feb-24
01-Mar-24
252
YRD-CIV-110
Backfill Pipe Trenches
8
03-Apr-24
12-Apr-24
222
YRD-CIV-160
Place Asphalt Pavement
1
15-Apr-24
15-Apr-24
222
Concrete
Concrete
52
22-Jan-24
02-Apr-24
227
YRD-CON-100
F/R/P Generator Pad
2
22-Jan-24
23-Jan-24
275
YRD-CON-120
F/R/P Chemical Trench Section #1
5
07-Feb-24
13-Feb-24
206
YRD-CON-130
F/R/P Chemical Trench Section #2
5
14-Feb-24
20-Feb-24
206
YRD-CON-110
F/R/P Chemical Unloading Area/Apron
8
16-Feb-24
27-Feb-24
252
YRD-CON-140
F/R/P Chemical Trench Section #3
5
21-Feb-24
27-Feb-24
206
YRD-CON-150
F/R/P Chemical Trench Section #4
5
28-Feb-24
05-Mar-24
206
YRD-CON-160
F/R/P Chemical Trench Section #5
5
06-Mar-24
12-Mar-24
206
YRD-CON-170
F/R/P Chemical Trench Section #6
5
13-Mar-24
19-Mar-24
206
YRD-CON-180
F/R/P Chemical Trench Section #7
5
20-Mar-24
26-Mar-24
206
YRD-CON-190
F/R/P Chemical Trench Section #8
5
27-Mar-24
02-Apr-24
206
Electrical
Electrical
271
13-Dec-23
07-Jan-25
37
YRD-ELEC-100
Relocate Existing Ductbank in Conflict with New Construction
10
13-Dec-23
27-Dec-23
210
YRD-ELEC-130
Place Electrical Handhole EHH-P01, EHH-P02, & EHH-C01
3
28-Dec-23
02-Jan-24
210
YRD-ELEC-120
Excavate & Install New Ductbank from Existing MCC-2 to EHH-P01
8
03-Jan-24
12-Jan-24
210
YRD-ELEC-110
Excavate & Install Ductbank to Relocated Emergency Generator
8
10-Jan-24
19-Jan-24
275
YRD-ELEC-170
Excavate & Install New Ductbank from EHH-P01 to EHH-P02
8
15-Jan-24
24-Jan-24
210
YRD-ELEC-160
Relocate Emergency Generator
1
25-Jan-24
25-Jan-24
275
YRD-ELEC-180
Excavate & Install Ductbank from EHH-P02 to EHH-C01
5
25-Jan-24
31-Jan-24
210
YRD-ELEC-150
Pull & Term Wire to Relocated Emergency Generator
3
26-Jan-24
30-Jan-24
275
YRD-ELEC-190
Excavate & Install Ductbank from EHH-C01 to Existing Ammonia Electrical Room
5
01-Feb-24
07-Feb-24
210
YRD-ELEC-200
Install Conduits from EHH-P02 & EHH-C01 to Chemical Storage & Chlorine Dioxide Bldg
4
08-Feb-24
13-Feb-24
210
YRD-ELEC-140
Pull Wire from Chemical Bldg Electrical Room to Chlorine Dioxide Bldg
8
26-Dec-24
07-Jan-25
0
Mechanical
Mechanical
5
24-Apr-24
30-Apr-24
206
YRD-MECH-100 Install Chemical Feed Lines from Chlorine Dioxide Bldg to Injection Points
5
24-Apr-24
30-Apr-24
206
Finishes
Finishes
23
03-Apr-24
03-May-24
206
YRD-FIN-100
Install HDPE Liner in Chemical Trench
15
03-Apr-24
23-Apr-24
206
YRD-FIN-110
Pipe Painting & Labeling
3
01-May-24
03-May-24
206
Sodium Chlorite
Sodium Chlorite Containment Area
267
05-Jan-24
22-Jan-25
27
Civil
Civil
29
05-Jan-24
14-Feb-24
190
SCC-CIV-100
Excavate for Sodium Chlorite Storage Area Slab & Sumps
4
05-Jan-24
10-Jan-24
169
SCC-CIV-110
Backfill Sumps
1
15-Jan-24
15-Jan-24
169
SCC-CIV-120
Backfill Sodium Chlorite Storage Area Slab
2
13-Feb-24
14-Feb-24
190
Concrete
Concrete
26
11-Jan-24
15-Feb-24
187
SCC-CON-100
F/R/P Sump Slab on Grades
2
11-Jan-24
12-Jan-24
169
SCC-CON-110
F/R/P Containment Area Slab
5
16-Jan-24
22-Jan-24
169
SCC-CON-120
F/R/P Containment Area Walls
10
23-Jan-24
05-Feb-24
169
SCC-CON-130
F/R/P Tank Pads
8
06-Feb-24
15-Feb-24
169
Oct
Nov
Dec
Jan
Feb
Mar
Apr
May
Jun
Jul
Aug
Sep
Oct
Nov
Dec
Jan
Feb
Mar
Apr
May un
2024
2025
Excavate & Compact for Emergency Generator
Excavate Chemical Trenches
Backfill Emergency Generator Pad
Fine Grade for Chemical Unloading Area/Apron
D/L/B Potable Water Line to Chemical Storage & Feed Area
Fine Garde for Asphalt Pavement
Backfill Pipe Trenches
Place Asphalt Pavement
F/R/P Generator Pad
F/R/P Chemical Trench Section #1
F/R/P Chemical Trench Section #2
F/R/P Chemical Unloading Area/Apron
F/R/P Chemical Trench Section #3
F/R/P Chemical Trench Section #4
F/R/P Chemical Trench Section #5
F/R/P Chemical Trench Section #6
F/R/P Chemical Trench Section #7
F/R/P Chemical Trench Section #8
Relocate Existing Ductbank in Conflict with New Construction
Place Electrical Handhole EHH-P01, EHH-P02, & EHH-C01
Excavate & Install New Ductbank from Existing MCC-2 to EHH-P01
Excavate & Install Ductbank to Relocated Emergency Generator
Excavate & Install New Ductbank from EHH-P01 to EHH-P02
Relocate Emergency Generator
Excavate & Install Ductbank from EHH-P02 to EHH-C01
Pull & Term Wire to Relocated Emergency Generator
Excavate & Install Ductbank from EHH-C01 to Existing Ammonia Electrical Room
Install Conduits from EHH-P02 & EHH-C01 to Chemical Storage & Chlorine Dioxide Bldg
Pull Wire from Chemical Bldg Elect
Install Chemical Feed Lines from Chlorine Dioxide Bldg to Injection Points
Install HDPE Liner in Chemical Trench
Pipe Painting & Labeling
Excavate for Sodium Chlorite Storage Area Slab & Sumps
Backfill Sumps
Backfill Sodium Chlorite Storage Area Slab
F/R/P Sump Slab on Grades
F/R/P Containment Area Slab
F/R/P Containment Area Walls
F/R/P Tank Pads
Run Date - 24-Oct-23
Start Date - 02-Jun-23
Finish Date - 11-Apr-25
Data Date - 23-Oct-23
Remaining Level of Effort
Actual Level of Effort
Actual Work
Remaining Work
Critical Remaining Work
Cholla Water Treatment Plant Improvements
Full Detail with Float
5 of 9
20 of 24
Activity ID
Activity Name
Orig
Dur
Start
Finish
Total
Float
SCC-CON-140
F/R/P Containment Area Stairs
5
06-Feb-24
12-Feb-24
190
Mechanical
Mechanical
90
19-Apr-24
26-Aug-24
125
SCC-MECH-100 Set Chemical Storage Tanks
1
19-Apr-24
19-Apr-24
159
SCC-MECH-190 On-site Leak Test of Chemical Storage Tanks
3
22-Apr-24
24-Apr-24
159
SCC-MECH-110
Install Chemical Storage Ladder & Handrail on Tanks
4
25-Apr-24
30-Apr-24
159
SCC-MECH-120 Install Chemical Feed Tank Fil Lines
3
01-May-24
03-May-24
159
SCC-MECH-150 Install Chemical Feed Lines to Chlorine Dioxide Building
5
06-May-24
10-May-24
159
SCC-MECH-160 Set Emergency Eye Wash/Shower Stations
1
13-May-24
13-May-24
159
SCC-MECH-170 Install PW Lines to Eyewash/Shower Stations
4
14-May-24
17-May-24
159
SCC-MECH-180 Install Chemical Area Sump & Piping
2
10-Jun-24
11-Jun-24
145
SCC-MECH-210 Install Handrail
4
16-Jul-24
19-Jul-24
129
SCC-MECH-220 Install FRP Gating
8
16-Jul-24
25-Jul-24
122
SCC-MECH-200 Chemical Storage Tank Clean
3
26-Jul-24
30-Jul-24
122
SCC-MECH-140 Set Chemical Transfer Pump
1
20-Aug-24
20-Aug-24
125
SCC-MECH-130 Install Chemical Transfer Lines
4
21-Aug-24
26-Aug-24
125
Electrical
Electrical
255
15-Jan-24
14-Jan-25
30
SCC-ELEC-130
Install Conduits in Slab
2
15-Jan-24
16-Jan-24
173
SCC-ELEC-170
Install Grounding
2
17-Jan-24
18-Jan-24
281
SCC-ELEC-140
Set & Run Conduits to Instruments & MOVs
4
13-May-24
16-May-24
193
SCC-ELEC-100
Set Chemical Unloading Local Control Panel
3
25-Sep-24
27-Sep-24
54
SCC-ELEC-110
Set Transfer Pump Motor Control Panel
3
30-Sep-24
02-Oct-24
54
SCC-ELEC-120
Set Sump Pump Controller Panel
3
03-Oct-24
07-Oct-24
54
SCC-ELEC-150
Pull & Term Wire to Control Panels
5
08-Jan-25
14-Jan-25
27
SCC-ELEC-160
Pull & Term Wire to Instruments & MOVs
3
08-Jan-25
10-Jan-25
32
Finishes
Finishes
88
29-Mar-24
01-Aug-24
140
SCC-FIN-100
Install Chemical Resistant Coating
10
29-Mar-24
11-Apr-24
159
SCC-FIN-110
Paint & Label Pipe
6
20-May-24
28-May-24
186
SCC-FIN-120
Install Signage
2
31-Jul-24
01-Aug-24
122
Startup & Testin
Startup & Testing
6
15-Jan-25
22-Jan-25
27
SCC-TEST-100
Start-up & Testing of Sump Pump Control Panel
1
15-Jan-25
15-Jan-25
27
SCC-TEST-110
Start-up & Testing of Unloading Local Control Panel
1
16-Jan-25
16-Jan-25
27
SCC-TEST-120
Start-up & Testing of Transfer Pump Motor Control Panel
1
17-Jan-25
17-Jan-25
27
SCC-TEST-130
Start-up & Testing of Motor Operatored Valves
1
20-Jan-25
20-Jan-25
27
SCC-TEST-140
Start-up & Testing of Emergency Eye Wash/Shower
1
21-Jan-25
21-Jan-25
27
SCC-TEST-150
Start-up & Testing of Chemical Storage Area Sump Level Switch
1
22-Jan-25
22-Jan-25
27
Chlorine Dioxid
Chlorine Dioxide Generation Building
270
05-Jan-24
27-Jan-25
24
Civil
Civil
13
05-Jan-24
23-Jan-24
206
CDG-CIV-100
Excavate & Compact of Sodium Dioxide Generation Building
3
05-Jan-24
09-Jan-24
206
CDG-CIV-110
Backfill Slab at Sodium Dioxide Generation Building
2
22-Jan-24
23-Jan-24
206
Concrete
Concrete
14
10-Jan-24
29-Jan-24
269
CDG-CON-100
F/R/P Slab
8
10-Jan-24
19-Jan-24
206
CDG-CON-110
F/R/P Equipment Pads
3
22-Jan-24
24-Jan-24
242
CDG-CON-120
F/R/P Door Stoop & HVAC Pad
3
25-Jan-24
29-Jan-24
269
Structural
Structural
20
26-Apr-24
23-May-24
152
CDG-STRU-100 Place 1st Lift of CMU Block
4
26-Apr-24
01-May-24
152
CDG-STRU-110
Place 2nd Lift of CMU Block
4
02-May-24
07-May-24
152
CDG-STRU-120 Place 3rd Lift of CMU Block
4
08-May-24
13-May-24
152
CDG-STRU-130 Place Steel Beams & Ledger for Roof
3
14-May-24
16-May-24
152
Oct
Nov
Dec
Jan
Feb
Mar
Apr
May
Jun
Jul
Aug
Sep
Oct
Nov
Dec
Jan
Feb
Mar
Apr
May un
2024
2025
F/R/P Containment Area Stairs
Set Chemical Storage Tanks
On-site Leak Test of Chemical Storage Tanks
Install Chemical Storage Ladder & Handrail on Tanks
Install Chemical Feed Tank Fil Lines
Install Chemical Feed Lines to Chlorine Dioxide Building
Set Emergency Eye Wash/Shower Stations
Install PW Lines to Eyewash/Shower Stations
Install Chemical Area Sump & Piping
Install Handrail
Install FRP Gating
Chemical Storage Tank Clean
Set Chemical Transfer Pump
Install Chemical Transfer Lines
Install Conduits in Slab
Install Grounding
Set & Run Conduits to Instruments & MOVs
Set Chemical Unloading Local Control Panel
Set Transfer Pump Motor Control Panel
Set Sump Pump Controller Panel
Pull & Term Wire to Control Pane
Pull & Term Wire to Instruments &
Install Chemical Resistant Coating
Paint & Label Pipe
Install Signage
Start-up & Testing of Sump Pump
Start-up & Testing of Unloading L
Start-up & Testing of Transfer Pu
Start-up & Testing of Motor Ope
Start-up & Testing of Emergenc
Start-up & Testing of Chemical
Excavate & Compact of Sodium Dioxide Generation Building
Backfill Slab at Sodium Dioxide Generation Building
F/R/P Slab
F/R/P Equipment Pads
F/R/P Door Stoop & HVAC Pad
Place 1st Lift of CMU Block
Place 2nd Lift of CMU Block
Place 3rd Lift of CMU Block
Place Steel Beams & Ledger for Roof
Run Date - 24-Oct-23
Start Date - 02-Jun-23
Finish Date - 11-Apr-25
Data Date - 23-Oct-23
Remaining Level of Effort
Actual Level of Effort
Actual Work
Remaining Work
Critical Remaining Work
Cholla Water Treatment Plant Improvements
Full Detail with Float
6 of 9
21 of 24
Activity ID
Activity Name
Orig
Dur
Start
Finish
Total
Float
CDG-STRU-150 Grout Beam Pockets
2
17-May-24
20-May-24
152
CDG-STRU-140 Place Metal Deck for Roof
3
21-May-24
23-May-24
152
Mechanical
Mechanical
18
10-May-24
05-Jun-24
184
CDG-MECH-100 Set Chlorine Dioxide Generator Skids
1
17-May-24
17-May-24
161
CDG-MECH-140 Install Potable Line to Skids
3
20-May-24
22-May-24
182
CDG-MECH-150 Install Chemical Feed Lines to Skids
4
23-May-24
29-May-24
182
CDG-MECH-130 Install Louver & Exhaust Fan
2
24-May-24
28-May-24
159
CDG-MECH-190 Install HVAC Unit
3
29-May-24
31-May-24
184
CDG-MECH-160 Install Chemical Feed Lines to Chemical Trench
2
30-May-24
31-May-24
182
CDG-MECH-120 Set Emergency Eye Wash/Shower
1
03-Jun-24
03-Jun-24
182
CDG-MECH-180 Install Grating
1
03-Jun-24
03-Jun-24
186
CDG-MECH-170 Install Potable Water Line to Eye Wash/Shower
2
04-Jun-24
05-Jun-24
182
Fire Protection
Fire Protection
10
10-May-24
23-May-24
145
CDG-FP-100
Install Fire Protection System
10
10-May-24
23-May-24
145
Electrical
Electrical
266
10-Jan-24
24-Jan-25
25
CDG-ELEC-100
Install Conduits in Slab
3
10-Jan-24
12-Jan-24
285
CDG-ELEC-240
Install Grounding
2
15-Jan-24
16-Jan-24
285
CDG-ELEC-290
Test Grounding
1
17-Jan-24
17-Jan-24
285
CDG-ELEC-250
Install Conduits in CMU Wall
12
26-Apr-24
13-May-24
171
CDG-ELEC-140
Install Conduit to Chemical Dioxide Skids
2
20-May-24
21-May-24
161
CDG-ELEC-200
Install Louver & Exhaust Fan Control Panel
1
29-May-24
29-May-24
159
CDG-ELEC-150
Install Lighting
4
06-Jun-24
11-Jun-24
152
CDG-ELEC-130
Install Transformer & Electrical Feed Panels
4
20-Nov-24
25-Nov-24
13
CDG-ELEC-110
Install Chlorine Leak Detection Control Panel
3
26-Nov-24
02-Dec-24
13
CDG-ELEC-260
Install Conduits to Lighting
3
26-Nov-24
02-Dec-24
35
CDG-ELEC-270
Install Conduits to HVAC Unit
3
26-Nov-24
02-Dec-24
60
CDG-ELEC-120
Install Fire Alarm Control Panel
3
03-Dec-24
05-Dec-24
13
CDG-ELEC-180
Pull & Term Wire to Transformer & Power Feed Panels
3
08-Jan-25
10-Jan-25
0
CDG-ELEC-280
Pull & Term Wire to HAVC Unit
1
08-Jan-25
08-Jan-25
36
CDG-ELEC-190
Pull & Term Wire to Chlorine Dioxide Skids
3
13-Jan-25
15-Jan-25
0
CDG-ELEC-210
Pull & Term Wire to Louver & Exhaust Fan Control Panel
1
16-Jan-25
16-Jan-25
0
CDG-ELEC-220
Pull & Term Wire to Outlets
2
17-Jan-25
20-Jan-25
0
CDG-ELEC-160
Pull & Term Wire to Chlorine Leak Detection Control Panel
2
21-Jan-25
22-Jan-25
0
CDG-ELEC-230
Pull & Term Wire for Lighting
1
23-Jan-25
23-Jan-25
0
CDG-ELEC-170
Pull & Term Wire to Fire Alarm Control Panel
1
24-Jan-25
24-Jan-25
0
Finishes
Finishes
13
24-May-24
12-Jun-24
180
CDG-FIN-100
Install Roof
8
24-May-24
05-Jun-24
152
CDG-FIN-110
Paint & Label Pipe
2
06-Jun-24
07-Jun-24
182
CDG-FIN-120
Install & Paint Doors
5
06-Jun-24
12-Jun-24
180
Startup & Testin
Startup & Testing
13
09-Jan-25
27-Jan-25
24
CDG-TEST-140
Start-up & Testing of HVAC Unit
1
09-Jan-25
09-Jan-25
36
CDG-TEST-150
Start-up & Testing of Emergency Eye Wash/Shower
1
15-Jan-25
15-Jan-25
32
CDG-TEST-160
Start-up & Testing of Pipe Trench and Sump Level Switches
1
15-Jan-25
15-Jan-25
32
CDG-TEST-130
Start-up & Testing of Chlorine Dioxide Skids
2
16-Jan-25
17-Jan-25
30
CDG-TEST-120
Start-up & Testing of Louver & Exhaust Fan
1
17-Jan-25
17-Jan-25
30
CDG-TEST-110
Start-up & Testing of Chlorine Leak Detection Panel
1
23-Jan-25
23-Jan-25
26
CDG-TEST-100
Start-up & Testing of Fire Alarm Control Panel
1
27-Jan-25
27-Jan-25
0
Existing Chlorin
Existing Chlorine Storage Building
44
08-Jan-24
07-Mar-24
249
Oct
Nov
Dec
Jan
Feb
Mar
Apr
May
Jun
Jul
Aug
Sep
Oct
Nov
Dec
Jan
Feb
Mar
Apr
May un
2024
2025
Grout Beam Pockets
Place Metal Deck for Roof
Set Chlorine Dioxide Generator Skids
Install Potable Line to Skids
Install Chemical Feed Lines to Skids
Install Louver & Exhaust Fan
Install HVAC Unit
Install Chemical Feed Lines to Chemical Trench
Set Emergency Eye Wash/Shower
Install Grating
Install Potable Water Line to Eye Wash/Shower
Install Fire Protection System
Install Conduits in Slab
Install Grounding
Test Grounding
Install Conduits in CMU Wall
Install Conduit to Chemical Dioxide Skids
Install Louver & Exhaust Fan Control Panel
Install Lighting
Install Transformer & Electrical Feed Panels
Install Chlorine Leak Detection Control Pane
Install Conduits to Lighting
Install Conduits to HVAC Unit
Install Fire Alarm Control Panel
Pull & Term Wire to Transformer &
Pull & Term Wire to HAVC Unit
Pull & Term Wire to Chlorine Diox
Pull & Term Wire to Louver & Exh
Pull & Term Wire to Outlets
Pull & Term Wire to Chlorine Le
Pull & Term Wire for Lighting
Pull & Term Wire to Fire Alarm
Install Roof
Paint & Label Pipe
Install & Paint Doors
Start-up & Testing of HVAC Unit
Start-up & Testing of Emergency
Start-up & Testing of Pipe Trench
Start-up & Testing of Chlorine Dio
Start-up & Testing of Louver & E
Start-up & Testing of Chlorine L
Start-up & Testing of Fire Alarm
Run Date - 24-Oct-23
Start Date - 02-Jun-23
Finish Date - 11-Apr-25
Data Date - 23-Oct-23
Remaining Level of Effort
Actual Level of Effort
Actual Work
Remaining Work
Critical Remaining Work
Cholla Water Treatment Plant Improvements
Full Detail with Float
7 of 9
22 of 24
Activity ID
Activity Name
Orig
Dur
Start
Finish
Total
Float
Concrete
Concrete
13
17-Jan-24
02-Feb-24
249
ECS-CON-100
F/R/P Chlorine Cylinder Pad
4
17-Jan-24
22-Jan-24
249
ECS-CON-110
Sawcut Opening for Relocated Exhaust Fan
1
02-Feb-24
02-Feb-24
249
Mechanical
Mechanical
16
15-Jan-24
05-Feb-24
249
ECS-MECH-100
Remove & Salvage Existing Chlorine Cylinder Scales
2
15-Jan-24
16-Jan-24
249
ECS-MECH-110
Install Salvaged & New Cylinder Scales
3
23-Jan-24
25-Jan-24
249
ECS-MECH-130
Pressure Test Chlorine Feed Line
2
26-Jan-24
29-Jan-24
249
ECS-MECH-120
Install New Chlorine Cylinder Regulators & Closure Valves
2
30-Jan-24
31-Jan-24
249
ECS-MECH-140
Remove & Salvage Existing Exhaust Fan
1
01-Feb-24
01-Feb-24
249
ECS-MECH-150
Reinstall Salvaged Exhaust Fan
1
05-Feb-24
05-Feb-24
249
Electrical
Electrical
39
08-Jan-24
29-Feb-24
253
ECS-ELEC-100
De-Term Equipment to be Salvaged
1
08-Jan-24
08-Jan-24
253
ECS-ELEC-130
Terminate Weight Scales & Closure Valves
2
01-Feb-24
02-Feb-24
272
ECS-ELEC-120
Reroute Conduit to Existing Relocated Exhaust Fan
1
06-Feb-24
06-Feb-24
249
ECS-ELEC-140
Pull & Term Wire to Relocated Exhaust Fan
1
07-Feb-24
07-Feb-24
249
ECS-ELEC-110
Electrical & Control Upgrades Per OSHA Inspection
15
09-Feb-24
29-Feb-24
249
Startup & Testin
Startup & Testing
24
05-Feb-24
07-Mar-24
249
ECS-TEST-110
Start-up & Testing of Weight Scales & Closure Valves
1
05-Feb-24
05-Feb-24
272
ECS-TEST-100
Start-up & Testing of Relocated Exhaust Fan
1
08-Feb-24
08-Feb-24
249
ECS-TEST-120
Start-up & Testing of EI&C Upgrades for OSHA Inspection
5
01-Mar-24
07-Mar-24
249
Existing Caustic
Existing Caustic Storage & Feed
15
07-Feb-24
27-Feb-24
256
Civil
Civil
8
07-Feb-24
16-Feb-24
262
ECSF-CIV-100
Excavate for Pipe Trench
2
07-Feb-24
08-Feb-24
256
ECSF-CIV-110
Backfill Pipe Trench
1
16-Feb-24
16-Feb-24
262
Concrete
Concrete
5
09-Feb-24
15-Feb-24
256
ECSF-CON-100
F/R/P Pipe Trench
5
09-Feb-24
15-Feb-24
256
Mechanical
Mechanical
4
20-Feb-24
23-Feb-24
256
ECSF-MECH-10 Demo & Relocate Caustic Feed Line
4
20-Feb-24
23-Feb-24
256
Finishes
Finishes
8
16-Feb-24
27-Feb-24
256
ECSF-FIN-100
Install HDPE Liner in Chemical Trench
2
16-Feb-24
19-Feb-24
256
ECSF-FIN-110
Paint & Label Pipe
2
26-Feb-24
27-Feb-24
256
Existing Ammo
Existing Ammonia Electrical Room
276
13-Dec-23
14-Jan-25
33
Mechanical
Mechanical
1
13-Dec-23
13-Dec-23
308
EAER-MECH-10 Remove & Salvage Existing Exhaust Fan
1
13-Dec-23
13-Dec-23
308
Electrical
Electrical
35
20-Nov-24
13-Jan-25
33
EAER-ELEC-100 Install New PLC
3
20-Nov-24
22-Nov-24
20
EAER-ELEC-110 Install New Access Control Cabinet
3
20-Dec-24
24-Dec-24
0
EAER-ELEC-120 Pull & Term Wire to New PLC
4
08-Jan-25
13-Jan-25
32
EAER-ELEC-130 Pull & Term Wire to Access Control Cabinet
3
08-Jan-25
10-Jan-25
34
Starup & Testing
Starup & Testing
243
31-Jan-24
14-Jan-25
33
EAER-TEST-120 Start-up & Testing of Existing Emergency Generator ATS
1
31-Jan-24
31-Jan-24
275
EAER-TEST-110 Start-up & Testing of Acess Control Cabinet
1
13-Jan-25
13-Jan-25
34
EAER-TEST-100 Start-up & Testing of New PLC
1
14-Jan-25
14-Jan-25
32
Project Closeout
Project Closeout
54
28-Jan-25
11-Apr-25
0
PR-CLOSE-1000
McCarthy Completion & Corrections
5
28-Jan-25
03-Feb-25
0
PR-CLOSE-1030
Weather Allowance
8
04-Feb-25
13-Feb-25
0
PR-CLOSE-1060
A/E Punchwalk
1
14-Feb-25
14-Feb-25
0
PR-CLOSE-1070
A/E Punchlist Corrections
10
17-Feb-25
28-Feb-25
0
Oct
Nov
Dec
Jan
Feb
Mar
Apr
May
Jun
Jul
Aug
Sep
Oct
Nov
Dec
Jan
Feb
Mar
Apr
May un
2024
2025
F/R/P Chlorine Cylinder Pad
Sawcut Opening for Relocated Exhaust Fan
Remove & Salvage Existing Chlorine Cylinder Scales
Install Salvaged & New Cylinder Scales
Pressure Test Chlorine Feed Line
Install New Chlorine Cylinder Regulators & Closure Valves
Remove & Salvage Existing Exhaust Fan
Reinstall Salvaged Exhaust Fan
De-Term Equipment to be Salvaged
Terminate Weight Scales & Closure Valves
Reroute Conduit to Existing Relocated Exhaust Fan
Pull & Term Wire to Relocated Exhaust Fan
Electrical & Control Upgrades Per OSHA Inspection
Start-up & Testing of Weight Scales & Closure Valves
Start-up & Testing of Relocated Exhaust Fan
Start-up & Testing of EI&C Upgrades for OSHA Inspection
Excavate for Pipe Trench
Backfill Pipe Trench
F/R/P Pipe Trench
Demo & Relocate Caustic Feed Line
Install HDPE Liner in Chemical Trench
Paint & Label Pipe
Remove & Salvage Existing Exhaust Fan
Install New PLC
Install New Access Control Cabinet
Pull & Term Wire to New PLC
Pull & Term Wire to Access Contro
Start-up & Testing of Existing Emergency Generator ATS
Start-up & Testing of Acess Contr
Start-up & Testing of New PLC
McCarthy Completion & Corr
Weather Allowance
A/E Punchwalk
A/E Punchlist Correctio
Run Date - 24-Oct-23
Start Date - 02-Jun-23
Finish Date - 11-Apr-25
Data Date - 23-Oct-23
Remaining Level of Effort
Actual Level of Effort
Actual Work
Remaining Work
Critical Remaining Work
Cholla Water Treatment Plant Improvements
Full Detail with Float
8 of 9
23 of 24
Activity ID
Activity Name
Orig
Dur
Start
Finish
Total
Float
PR-CLOSE-1040
*Milestone - Substantial Completion
0
28-Feb-25
0
PR-CLOSE-1050
*Milestone - Final Completion
30
03-Mar-25
11-Apr-25
0
Oct
Nov
Dec
Jan
Feb
Mar
Apr
May
Jun
Jul
Aug
Sep
Oct
Nov
Dec
Jan
Feb
Mar
Apr
May un
2024
2025
*Milestone - Substantia
*Milestone -
Run Date - 24-Oct-23
Start Date - 02-Jun-23
Finish Date - 11-Apr-25
Data Date - 23-Oct-23
Remaining Level of Effort
Actual Level of Effort
Actual Work
Remaining Work
Critical Remaining Work
Cholla Water Treatment Plant Improvements
Full Detail with Float
9 of 9
24 of 24
City of Glendale Standard Form Agreement Between Owner and CM@Risk (May 15, 2023)
T H I S P A G E I S B L A N K
City of Glendale Standard Form Agreement Between Owner and CM@Risk (May 15, 2023)
EXHIBIT H
Dispute Resolution Procedures
1.
Disputes.
1.1
Each Dispute arising out of or related to this Agreement (including Disputes
regarding any alleged breaches of this Agreement) shall be initiated and decided
under the provisions of this Exhibit.
1.2
CMAR and City shall each designate in writing to the other party, from time to
time, a member of senior management who shall be authorized to attempt to
expeditiously resolve any Dispute relating to the subject matter of this Agreement
in an equitable manner.
1.3
A party shall initiate a Dispute by delivery of written notice to the members of
management designated by the respective parties under Section 1.2 of this Exhibit.
1.4
The parties must:
(A)
Attempt to resolve all Disputes promptly, equitably and in a good faith
manner; and
(B)
Provide each other with reasonable access during normal business hours to
any and all non-privileged records, information and data pertaining to any
such Dispute.
1.5
With respect to matters concerning modification of the GMP or any schedule,
CMAR must first follow the provisions of any Claim procedure established by the
Design-Build Agreement before seeking relief under these Procedures.
2.
Emergency Arbitration.
2.1
If the parties are unable to accomplish resolution of a Dispute, the expedited
resolution of which either party considers necessary to prevent or mitigate a
material delay to the critical path of the Services (a "Time Sensitive Dispute")
within two days after the Time Sensitive Dispute has been initiated by a party, either
party may thereafter seek emergency relief before an emergency arbitrator (the
"Emergency Arbitrator") appointed as follows:
(A)
The parties will exercise best efforts to pre-select an Emergency Arbitrator
within 20 days after entering into this Agreement;
(B)
If the Emergency Arbitrator has not been selected at the time a party delivers
Notice of a Time Sensitive Dispute, the parties will each select a
representative within one day after the Notice is delivered and the two
representatives will then select the Emergency Arbitrator by the third day
following delivery of the Notice.
(C)
The Emergency Arbitrator shall be an attorney with at least ten (10) years’
experience with commercial construction legal matters in Maricopa County,
Arizona, be independent, impartial, and not have engaged in any business
for or adverse to either party for at least ten (10) years.
2.2
The Emergency Arbitrator will conduct a hearing and render a written
determination on the Dispute to both parties within five business days of the matter
being referred to him or her, all in accordance with Rules O-1 to O-8 of the
City of Glendale Standard Form Agreement Between Owner and CM@Risk (May 15, 2023)
American Arbitration Association ("AAA") Commercial Rules-Optional Rules for
Emergency Protection Commercial Rules ("AAA Emergency Rules").
2.3
Although the hearing will be conducted using AAA rules, unless both parties agree
otherwise, this dispute process will not be administered by the AAA but will be
conducted by the parties in accordance with these procedures.
2.4
If, however, an Emergency Arbitrator has not selected within three days after
delivery of the Notice, either party may upon three days additional notice, thereafter
seek emergency relief before the AAA, in accordance with the AAA Emergency
Rules, provided that the Emergency Arbitrator meets the qualifications set forth
above.
2.5
All proceedings to arbitrate Time Sensitive Disputes shall be conducted in
Glendale, Arizona.
2.6
Presentation, request for determination (i.e., a party’s prayer), and the Emergency
Arbitrators decision will adhere to the procedures required in Section 3.6 of this
Exhibit.
2.7
The finding of the Emergency Arbitrator with respect to any Time Sensitive
Dispute will be binding upon the parties on an interim basis during progress of the
Services, subject to review de novo by arbitration after the Project Substantial
Completion Date.
2.8
The time and extent of discovery will be as determined by the Emergency
Arbitrator.
(A)
Discovery orders of the Emergency Arbitrator will consider the time
sensitivity of the matter and the parties desire to resolve the issue in the
most time and costs efficient manner;
(B)
The parties are obligated to cooperate fully and completely in the provision
of documents and other information, including joint interviews of
individuals with knowledge such that the matter moves toward resolution
in the most time and costs efficient manner and the Emergency Arbitrator
is empowered to fashion any equitable penalty against a party that fail to
meet this obligation.
3.
Non-Emergency Arbitration.
3.1
Except as provided in Section 5 of this Exhibit, any Dispute that is either a non-
emergency Dispute that has not been resolved by negotiation, or a de novo review
of an AAA emergency arbitration will be decided by binding arbitration by a panel
of three arbitrators in accordance with, but not necessarily administered by, the
Construction Industry Rules of the AAA.
(A)
The parties shall each select an arbitrator within 15 days after notice that a
party desires to resolve a dispute by arbitration.
(B)
The two arbitrators shall then each select a third arbitrator. If an arbitrator
is not selected within any such 15 day period, then the arbitrator shall be
appointed by the AAA.
3.2
The arbitrator(s) shall meet the qualifications of Emergency Arbitrators as provided
in Section 2 of this Exhibit.
City of Glendale Standard Form Agreement Between Owner and CM@Risk (May 15, 2023)
3.3
The arbitrators do not have the authority to consider or award punitive damages as
part of the arbitrators' award.
3.4
In connection with such arbitration, each party shall be entitled to conduct up to
five depositions, and, no less than 90 days prior to the date of the arbitration hearing,
each party shall deliver to the other party copies of all documents in the delivering
party's possession that are relevant to the dispute.
3.5
The arbitration hearing shall be held within 150 days of the appointment of the
arbitrators.
3.6
At the arbitration hearing, each party will argue its position to the arbitrators in
support of one proposed resolution to the dispute (a “Proposed Resolution”).
(A)
Each party’s Proposed Resolution must be fully dispositive of the dispute.
(B)
The arbitrators must select one Proposed Resolution by majority consent
and are not free to fashion any alternative resolutions.
(C)
The parties must submit their proposed resolution of the matter to the
arbitrators and the other party 15 days prior to the date set for
commencement of the arbitration proceeding.
(D)
The decision of the arbitrators will be forwarded to the parties within 15
days after the conclusion of the arbitration hearing.
(E)
The decision of the arbitration panel is final and binding on the parties and
may be entered in any court of competent jurisdiction for the purpose of
securing an enforceable judgment.
(F)
All costs and expenses associated with the arbitration, including the
reasonable legal fees and costs incurred by the prevailing party, must be
paid by the party whose position was not selected by the arbitrators.
4.
Continuing Work. Unless otherwise agreed to in writing, CMAR must continue to
perform and maintain progress of the Work during any Dispute Resolution or arbitration
proceedings, and City will continue to make payment to CMAR in accordance with the
Agreement.
5.
Exceptions.
5.1
Neither City nor CMAR are required to arbitrate any third-party claim, cross-claim,
counter claim, or other claim or defenses in any action that is commenced by a
third-party who is not obligated by contract to arbitrate disputes with City and
CMAR.
5.2
City or CMAR may commence and prosecute a civil action to contest a lien or stop
notice, or enforce any lien or stop notice (but only to the extent the lien or stop
notice the party seeks to enforce is enforceable under Arizona law), including,
without limitation, an action under A.R.S. § 33-420, without the necessity of
initiating or exhausting the procedures of this Exhibit.
5.3
This Exhibit does not apply to, and may not be construed to require arbitration of,
any claims, actions or other process undertaken, filed, or issued by the City of
Glendale Building Safety Department, Code Compliance Department, Police
Department, Fire Department, or any other agency of City acting in its
City of Glendale Standard Form Agreement Between Owner and CM@Risk (May 15, 2023)
governmental permitting, for the benefit of public health, safety, and welfare, or
other regulatory capacity.
5.4
In connection with any arbitration, the arbitrators do not have the authority to, and
may not enforce, any provision of the Federal or Arizona Rules of Civil Procedure.