Amendment to Agreement with MGC Contractors

City of Glendale — Regular Meeting (2025-05-27)

View PDF Item 9 Meeting page

Extracted text (via pymupdf) 108442 characters 
City of Glendale Standard Form Agreement Between Owner and CM@Risk (January 28, 2025) 
 
 
Project Name: GLENDALE-PHOENIX WATER SUPPLY INTERCONNECTS 
Project No.: 
212238.2 
Amendment No: 01 
Date: 
 
      
 
This Amendment to that certain Standard Form Agreement dated October 22, 2024 by and between the City of 
Glendale and MGC Contractors, Inc., (CM@Risk) for services, deliverables and work related to Project No. 
212238.2, Project Name: Glendale-Phoenix Water Supply Interconnects, (the “Agreement”) is made and entered 
into effective this       day of      , 2025. 
 
1. This Amendment #01 establishes a Guaranteed Maximum Price (“GMP”) and Construction Phase Fee for 
Construction Services and incorporates such terms into the Agreement, making the Agreement effective 
for Construction Phase Services: 
 
a. 
The total fee for Construction Phase Services, which is included in the Guaranteed Maximum Price (GMP) 
as defined under the Agreement, shall be fixed at One Hundred Seventy-Nine Thousand Three Hundred 
Ninety-Seven and 51/100 Dollars ($179,397.51). [INSERT ADDITIONAL LANGUAGE HERE IF 
PHASED AGREEMENT.] 
 
b. The Guaranteed Maximum Price (“GMP”) for Construction Services, as defined under the Agreement, shall 
be Two Million One Hundred Ten Thousand Five Hundred Fifty-Eight and 96/100 Dollars 
($2,110.558.96). [INSERT ADDITIONAL LANGUAGE HERE IF PHASED AGREEMENT.] 
 
c. 
The total compensation under the Agreement, as amended by this Amendment, shall be: 
 
 
Pre-Construction Phase 
Construction Phase 
Total 
Original Agreement: 
$601,931.20 
$      
$601,931.20 
 
 
 
 
Previous Amendments: 
$      
$      
$      
 
 
 
 
This Amendment: 
$      
$2,110,558.96 
$2,110,558.96 
 
 
 
 
Total (including this 
Amendment): 
 
$601,931.20 
 
$2,110,558.96 
 
$2,712,490.16 
 
 
2. DELETE the blank template “Exhibit C – Cost of the Work – Schedule of Values” from the Agreement, 
and ADD “Exhibit C – MGC Contractors, Inc. Cost of the Work – Schedule of Values” dated April 23, 
2025 (12 Pages), attached herein. 
 
3. ADD “Exhibit E – Construction Documents necessary to define Scope of Work and deliverables for the 
Construction Phase Services, including plans, designs, drawings, specifications and other required 
Contract Documents” dated March 25, 2025 (15 Pages), attached herein. 
 
4. ADD “Exhibit F - Statement of All Clarifications and Assumptions” dated March 25, 2025 (3 Pages), 
attached herein. 
 
5. ADD “Exhibit G – Schedule of Major Milestones” dated March 14, 2025 (3 Pages), attached herein. 
 
6. All other provisions, terms and conditions of the Agreement shall remain unchanged and in full effect. 
 
(Signature on following page)

Michael Caruso
Associate Vice President
16 May 2025

City of Glendale Standard Form Agreement Between Owner and CM@Risk (January 28, 2025) 
 
 
EXHIBIT C 
Cost of the Work 
 
(One (1) page - template) 
(12 pages - final document to be included with GMP Amendment) 
 
See attached

3URMHFW7LWOH
$02817
',5(&7&2676

&RVWRI&RQVWUXFWLRQ*OHQGDOH3\UDPLG3HDN,QWHUFRQQHFW



&RVWRI&RQVWUXFWLRQ*OHQGDOH7RQRSDK,QWHUFRQQHFW


68%727$/',5(&7&2676


,1',5(&7&2676
&$/&8/$7('
5$7(
$



%




&




'
68%727$/*(1(5$/&21',7,216&2676


(
68%727$/',5(&7$1',1',5(&7&2676


)



*
68%727$/',5(&7$1',1',5(&7&2676,1&/8',1*)((


+
6DOHV7D[




- $OORZDQFHV




5HPRYHG3URMHFW'LUHFWRU*HQHUDO6XSHUDQG2IILFH7UDLORU
5HGXFHG'XUDWLRQV)RU3URMHFW(QJLQHHU3URMHFW0DQDJHU6DIHW\0DQDJHU4$4&0DQDJHUDQG7UXFN7RWDOV
5HGXFHG&RQVWUXFWLRQ)HHWR
. 7RWDO&RQWUDFW$PRXQW
*HQHUDO&RQGLWLRQV([FOXGLQJ%RQGVDQG,QVXUDQFH
3D\PHQWDQG3HUIRUPDQFH%RQGV
,QVXUDQFH
&RQVWUXFWLRQ)HH2YHUKHDG	3URILW
, 'LUHFW	,QGLUHFW&RVW3OXV6DOHV7D[
&216758&7,216(59,&(6
*036800$5<6+((75(9
3URMHFW1XPEHU
$SU
*OHQGDOH3KRHQL[:DWHU6XSSO\,QWHUFRQQHFWV

1R
'HVFULSWLRQ
4XDQWLW\
8QLW
7RWDO$OORZDQFH

$GGLWLRQDO7UDIILF&RQWURO$OORZDQFH

/6



/DQGVFDSH5HVWRUDWLRQ$OORZDQFH3\UDPLG3HDN6LWH

/6



/DQGVFDSH5HVWRUDWLRQ$OORZDQFHVW	7RQRSDK6LWH

/6



+DUG'LJ$OORZDQFH

/6



$VSKDOW6WULSLQJ$OORZDQFH

/6



*UDWLQJ0RGLILFDWLRQ$OORZDQFH#0HWHULQJ6WUXFWXUH

/6



3LSH6XSSRUW'HVLJQ$OORZDQFH

/6



&RQWUDFWRU
V&RQWLQJHQF\

/6




*OHQGDOH3KRHQL[:DWHU6XSSO\,QWHUFRQQHFWV*035(9
$OORZDQFH%UHDNGRZQ
%727$/*03$//2:$1&(

dŚĞŝƚLJŽĨ'ůĞŶĚĂůĞͲ'DWϭWƌŽƉŽƐĂů±'ůĞŶĚĂůĞͬ WŚŽĞŶŝdž/ŶƚĞƌĐŽŶŶĞĐƚƐͲWƌŽũĞĐƚEŽ͘ ϮϭϮϮϯϴ͘ Ϯ













































7$%
&2672)&216758&7,21
6&+('8/(2)9$/8(6

&%6
3RVLWLRQ&RGH
'HVFULSWLRQ
)RUHFDVW
724XDQWLW\
8QLWRI
0HDVXUH
8QLW&RVW
7RWDO&RVW
)RUHFDVW
/DERU7RWDO&RVW
0DQ+RXUV
7RWDO
QHG(TXLSPHQW7RWDOXEFRQWUDFW7RWDO&RV6XSSOLHV7RWDO&RVDWHULDOV7RWDO&RHQWHG(TXLSPHQW7RWDO&R)HHV7RWDO&RV7/&DWHJRU\7RWDO&RV
&LW\RI*OHQGDOH3KRHQL[:DWHU6XSSO\,QWHUFRQQHFW*03
 /XPS6XP











3ULPH%RQG
 /XPS6XP










*/,QVXUDQFH
 /XPS6XP










%XLOGHUV5LVN,QVXUDQFH
 /XPS6XP










6PDOO7RROV/DERU
 /XPS6XP










6DIHW\/DERU
 /XPS6XP










3URMHFW([HFXWLYH7;
 /XPS6XP










*HQHUDO6XSHU7;
 /XPS6XP










6DOHV7D[&LW\
 /XPS6XP










*HQHUDO([SHQVH
 /XPS6XP












*(1(5$/&21',7,216
 (DFK












3URMHFW6WDII
 (DFK












3URMHFW0DQDJHU
 :HHN












3URMHFW6XSHULQWHQGHQW
 :HHN












3URMHFW(QJLQHHU
 :HHN












4$4&0DQDJHU
 :HHN












6DIHW\0DQDJHU
 :HHN












/LJKW'XW\3LFNXS
 :HHN












+HDY\'XW\3LFNXS
 :HHN












*HQHUDO6XSHULQWHQGHQW
 :HHN












3URMHFW'LUHFWRU
 :HHN












*(1(5$/5(48,5(0(176
 (DFK












&RQWUDFWRU)LHOG2IILFH
 0RQWK















0*&6&23('85$7,21


 :HHN












6HWXS7DNHGRZQ&RQVWUXFWLRQ<DUG
 ($












7HPSRUDU\(OHFWULFLW\
 0RQWK












)LHOG2IILFH3ULQWHU
 0RQWK












)LHOG2IILFH6XSSOLHV
 0RQWK












,QWHUQHW
 0RQWK












,7&RVWV
 0RQWK












2IILFH7UDLOHU5HQWDO
 0RQWK












*HQHUDO5HTXLUHPHQWV
 0RQWK












0RE	'HPRE
 /6












*(1(5$/5(48,5(0(176
 (DFK












&RQWUDFWRU)LHOG2IILFH
 0RQWK















0*&6&23('85$7,21


 :HHN












6HWXS7DNHGRZQ&RQVWUXFWLRQ<DUG
 ($












7HPSRUDU\(OHFWULFLW\
 0RQWK












)LHOG2IILFH3ULQWHU
 0RQWK












)LHOG2IILFH6XSSOLHV
 0RQWK












,QWHUQHW
 0RQWK












,7&RVWV
 0RQWK












2IILFH7UDLOHU5HQWDO
 0RQWK












*HQHUDO5HTXLUHPHQWV
 0RQWK












0RE	'HPRE
 /6












*(1(5$/&21',7,216
 (DFK












3URMHFW6WDII
 (DFK












3URMHFW0DQDJHU
 :HHN












3URMHFW6XSHULQWHQGHQW
 :HHN












3URMHFW(QJLQHHU
 :HHN












4$4&0DQDJHU
 :HHN












6DIHW\0DQDJHU
 :HHN












/LJKW'XW\3LFNXS
 :HHN












+HDY\'XW\3LFNXS
 :HHN












*HQHUDO6XSHULQWHQGHQW
 :HHN












3URMHFW'LUHFWRU
 :HHN












*(1(5$/5(48,5(0(176
 (DFK












&RQWUDFWRU)LHOG2IILFH
 0RQWK















0*&6&23('85$7,21


 :HHN












6HWXS7DNHGRZQ&RQVWUXFWLRQ<DUG
 ($












7HPSRUDU\(OHFWULFLW\
 0RQWK












)LHOG2IILFH3ULQWHU
 0RQWK












)LHOG2IILFH6XSSOLHV
 0RQWK












,QWHUQHW
 0RQWK












,7&RVWV
 0RQWK












2IILFH7UDLOHU5HQWDO
 0RQWK












*HQHUDO5HTXLUHPHQWV
 0RQWK












0RE	'HPRE
 /6












*(1(5$/5(48,5(0(176
 (DFK












&RQWUDFWRU)LHOG2IILFH
 0RQWK















0*&6&23('85$7,21


 :HHN












6HWXS7DNHGRZQ&RQVWUXFWLRQ<DUG
 ($












7HPSRUDU\(OHFWULFLW\
 0RQWK












)LHOG2IILFH3ULQWHU
 0RQWK












)LHOG2IILFH6XSSOLHV
 0RQWK












,QWHUQHW
 0RQWK












,7&RVWV
 0RQWK












2IILFH7UDLOHU5HQWDO
 0RQWK












*HQHUDO5HTXLUHPHQWV
 0RQWK












0RE	'HPRE
 /6












*HQHUDO6XSHULQWHQGHQW
 :HHN












3URMHFW'LUHFWRU
 :HHN












*(1(5$/5(48,5(0(176
 (DFK












&RQWUDFWRU)LHOG2IILFH
 0RQWK















0*&6&23('85$7,21


 :HHN












6HWXS7DNHGRZQ&RQVWUXFWLRQ<DUG
 ($












7HPSRUDU\(OHFWULFLW\
 0RQWK












)LHOG2IILFH3ULQWHU
 0RQWK












)LHOG2IILFH6XSSOLHV
 0RQWK












*(1(5$/5(48,5(0(176
 (DFK












&RQWUDFWRU)LHOG2IILFH
 0RQWK















0*&6&23('85$7,21


 :HHN












6HWXS7DNHGRZQ&RQVWUXFWLRQ<DUG
 ($












7HPSRUDU\(OHFWULFLW\
 0RQWK












)LHOG2IILFH3ULQWHU
 0RQWK












)LHOG2IILFH6XSSOLHV
 0RQWK












,QWHUQHW
 0RQWK












,7&RVWV
 0RQWK












,7&RVWV
 0RQWK












2IILFH7UDLOHU5HQWDO
 0RQWK












*HQHUDO5HTXLUHPHQWV
 0RQWK












0RE	'HPRE
 /6












*HQHUDO5HTXLUHPHQWV
 0RQWK












0RE	'HPRE
 /6












&%6
3RVLWLRQ&RGH
'HVFULSWLRQ
)RUHFDVW
724XDQWLW\
8QLWRI
0HDVXUH
8QLW&RVW
7RWDO&RVW
)RUHFDVW
/DERU7RWDO&RVW
0DQ+RXUV
7RWDO
QHG(TXLSPHQW7RWDOXEFRQWUDFW7RWDO&RV6XSSOLHV7RWDO&RVDWHULDOV7RWDO&RHQWHG(TXLSPHQW7RWDO&R)HHV7RWDO&RV7/&DWHJRU\7RWDO&RV

(TXLSPHQW0RE)UHLJKWRI3LHFHV
 (DFK












(TXLSPHQW'HPRE)UHLJKWRI3LHFHV
 (DFK












&RQVWUXFWLRQ<DUG
 /6












&RQVWUXFWLRQ:DWHU0RQWKO\8VDJH)HHV
 0RQWK












&RQVWUXFWLRQ:DWHU+\GUDQW0HWHU6HWXS)HHV
 (DFK












--RQ
V
 0RQWK












+DQGZDVK6WDWLRQV
 0RQWK












&RQVWUXFWLRQ)HQFH5HQW7HPSRUDU\&KDLQ/LQN
 /)












&RQVWUXFWLRQ)HQFH6HWXS7HPSRUDU\&KDLQ/LQN
 /)












&RQQH[%R[
 0RQWK












6LWH6HFXULW\&DPHUDV
 0RQWK












5ROO2II'XPSVWHULQFOGXPSIHHV
 0RQWK












3URMHFW,GHQWLILFDWLRQ
 ($












,FH	:DWHU
 0RQWK












2	03UHS&RQWUDFW&ORVHRXW
 :HHN












3RWKROH8WLOLWLHV
 'D\












3URMHFW3KRWRV
 0RQWK












6DIHW\6XSSOLHV	7UDLQLQJRI7RWDO/DERU&RVW
 /6












0DWHULDO7HVWLQJ	6SHFLDO,QVSHFWLRQV
 /6












3<5$0,'3($.6,7(
 (DFK












6,7(:25.3<5$0,'3($.
 (DFK












&UDIW6XSHUYLVLRQ6LWH:RUN
 :HHN












&RQVXPDEOH&RQVWUXFWLRQ6XSSOLHV6LWH:RUNRI&UDIW/DERU&RVW
 /6












3ROH7UXFN6WDELOL]H3RZHU3ROH#3\UDPLG3HDN6LWH
 (DFK












6LWH'HPROLWLRQ
 (DFK












6DZFXW68%
 /)












6DZFXW([LVWLQJ&RQFUHWH&KDQQHO
 /)












6DZFXW([LVWLQJ&XUERI&XWV
 (DFK












6DZFXW([LVWLQJ$VSKDOW3DYHPHQWIRU'HPR
 /)












6DZFXW([LVWLQJ$VSKDOW3DYHPHQW3DWFK%DFN
 /)












+DXO2II68%
 (DFK












+DXO2II&RQFUHWH'HEULV&RQFUHWH&KDQQHO
 (DFK












+DXO2II&RQFUHWH'HEULV&RQFUHWH6LGHZDON
 (DFK












&%6
3RVLWLRQ&RGH
'HVFULSWLRQ
)RUHFDVW
724XDQWLW\
8QLWRI
0HDVXUH
8QLW&RVW
7RWDO&RVW
)RUHFDVW
/DERU7RWDO&RVW
0DQ+RXUV
7RWDO
QHG(TXLSPHQW7RWDOXEFRQWUDFW7RWDO&RV6XSSOLHV7RWDO&RVDWHULDOV7RWDO&RHQWHG(TXLSPHQW7RWDO&R)HHV7RWDO&RV7/&DWHJRU\7RWDO&RV

+DXO2II&RQFUHWH'HEULV&RQFUHWH&XUE
 (DFK












+DXO2II$VSKDOW'HEULV3\UDPLG3HDN3DUNZD\
 (DFK












+DPPHU	/RDGRXW'HPR
G&RQFUHWH&RQFUHWH&KDQQHO#3\UDPLG3H
 &<












5HPRYH	/RDGRXW&RQFUHWH&XUE3\UDPLG3HDN3DUNZD\
 /)












5HPRYH&RQFUHWH6LGHZDON3DQHO	/RDGRXW&RQFUHWH3\UDPLG3HDN3
 (DFK












+DPPHU	/RDGRXW'HPR
G$VSKDOW3DYHPHQW3\UDPLG3HDN3DUNZD\
 6)












(DUWKZRUNVIRU&RQFUHWH
 (DFK












3XUFKDVH6XEEDVH%DFNILOO0DWHULDOV
 7RQ












7UXFNLQJ6XE+DXO2II6SRLOV
 ($












(DUWKZRUNVIRU%DFNIORZ3UHYHQWRU6ODE
 /6












([FDYDWHWR6XEJUDGH%DFNIORZ3UHYHQWRU6ODE
 &<












3ODFHDQG&RPSDFW$%&6XEEDVH%DFNIORZ3UHYHQWRU6ODE
 7RQ












)LQH*UDGH%DFNIORZ3UHYHQWRU6ODE6XEEDVH
 6)












/RDG2XW6SRLOV%DFNIORZ3UHYHQWRU6ODE6XEEDVH
 &<












(DUWKZRUNVIRU(OHFWULFDO(TXLSPHQW3DGV
 /6












([FDYDWHWR6XEJUDGH(OHFWULFDO(TXLSPHQW3DGV
 &<












3ODFH	&RPSDFW$%&6XEEDVH(OHFWULFDO(TXLSPHQW3DGV
 7RQ












/RDG2XW6SRLOV(OHFWULFDO(TXLSPHQW3DGV
 &<












6LWH&RQFUHWH
 &<












3XUFKDVH5HDG\0L[0DWHULDOV
 &<












36,&RQFUHWH
 &<












5HDG\0L[)XHO)HH
 ($












5HDG\0L[(QYLURQPHQWDO)HH
 ($












5HDG\0L[,FH	1LWUR)HH
 &<












5HDG\0L[6KRUW/RDG)HH
 ($












3XUFKDVH)RUPZRUN0DWHULDOV
 6)












)366ODE2Q*UDGHV
7KLFN
 &<












%DFNIORZ3UHYHQWRU6ODE
 &<












)RUP	6WULS%DFNIORZ3UHYHQWRU62*
 6)












3XUFKDVH5HEDU%DFNIORZ3UHYHQWRU62*
 /6












,QVWDOO5HEDU%DFNIORZ3UHYHQWRU62*
 /6












3ODFH	)LQLVK%DFNIORZ3UHYHQWRU62*
 &<












&XUH&RQFUHWH%DFNIORZ3UHYHQWRU62*
 6)












&%6
3RVLWLRQ&RGH
'HVFULSWLRQ
)RUHFDVW
724XDQWLW\
8QLWRI
0HDVXUH
8QLW&RVW
7RWDO&RVW
)RUHFDVW
/DERU7RWDO&RVW
0DQ+RXUV
7RWDO
QHG(TXLSPHQW7RWDOXEFRQWUDFW7RWDO&RV6XSSOLHV7RWDO&RVDWHULDOV7RWDO&RHQWHG(TXLSPHQW7RWDO&R)HHV7RWDO&RV7/&DWHJRU\7RWDO&RV

(OHFWULFDO(TXLSPHQW3DGV
 &<












3XUFKDVH5HEDU(OHF(TXLSPHQW3DGV
 /6












/&33/&($&(OHFWULFDO(TXLSPHQW3DG
[
[
 &<












)RUP	6WULS/&33/&($&(OHFWULFDO(TXLSPHQW3DG
 6)












,QVWDOO5HEDU/&33/&($&(OHFWULFDO(TXLSPHQW3DG
 /6












3ODFH	)LQLVK/&33/&($&(OHFWULFDO(TXLSPHQW3DG
 &<












&XUH&RQFUHWH/&33/&($&(OHFWULFDO(TXLSPHQW3DG
 6)












31/&7(OHFWULFDO(TXLSPHQW3DG
[
[
 &<












)RUP	6WULS31/&7(OHFWULFDO(TXLSPHQW3DG
 6)












,QVWDOO5HEDU31/&7(OHFWULFDO(TXLSPHQW3DG
 /6












3ODFH	)LQLVK31/&7(OHFWULFDO(TXLSPHQW3DG
 &<












&XUH&RQFUHWH31/&7(OHFWULFDO(TXLSPHQW3DG
 6)












)36&RQFUHWH&KDQQHO
 &<












)RUP	6WULS&RQFUHWH&KDQQHO6XSHU6ODEV($
[
[
 6)












3ODFH	)LQLVK&RQFUHWH&KDQQHO6XSHU6ODEV($
 &<












)RUP	6WULS&RQFUHWH&KDQQHO%RWWRP6ODE
[
[
 6)












'RZHO,QWR([LVWLQJ&KDQQHO%RWK6LGHV
 ($












,QVWDOO:HOGHG:LUH)DEULF&RQFUHWH&KDQQHO%RWWRP6ODE
[
[
 6)












3ODFH	)LQLVK&RQFUHWH&KDQQHO%RWWRP6ODE
 &<












,QVWDOO:HOGHG:LUH)DEULF&RQFUHWH&KDQQHO6ORSHV
 6)












3ODFH	)LQLVK&RQFUHWH&KDQQHO6ORSHV
 &<












)36$QWHQQD3ROH%DVH
 &<












'ULOOIRU$QWHQQD3ROH%DVH
 (DFK












3XUFKDVH5HEDU$QWHQQD%DVH3ROH
 /6












)RUP	6WULS$QWHQQD3ROH%DVH
 6)












3ODFH	)LQLVK$QWHQQD3ROH%DVH
 &<












0HWDOV
 /6












3LSH%ROODUGV
 (DFK












3XUFKDVH3LSH%ROODUGV
 (DFK












,QVWDOO3LSH%ROODUGV
 (DFK












$VSKDOW3DYLQJ6OXUU\6HDO6WULSLQJ
 (DFK












68%$VSKDOW3DYLQJ
 6<












([SRVH([LVWLQJ8WLOLWLHV
 'D\












&%6
3RVLWLRQ&RGH
'HVFULSWLRQ
)RUHFDVW
724XDQWLW\
8QLWRI
0HDVXUH
8QLW&RVW
7RWDO&RVW
)RUHFDVW
/DERU7RWDO&RVW
0DQ+RXUV
7RWDO
QHG(TXLSPHQW7RWDOXEFRQWUDFW7RWDO&RV6XSSOLHV7RWDO&RVDWHULDOV7RWDO&RHQWHG(TXLSPHQW7RWDO&R)HHV7RWDO&RV7/&DWHJRU\7RWDO&RV

352&(663,3,1*3<5$0,'3($.
 (DFK












&UDIW6XSHUYLVLRQ3URFHVV3LSLQJ
 :HHN












&RQVXPDEOH&RQVWUXFWLRQ6XSSOLHV3URFHVV3LSLQJRI&UDIW/DERU
 /6












%XULHG3LSH	9DOYHV
 /)












3XUFKDVH%XULHG3LSH	9DOYHV3\UDPLG3HDN6LWH
 /6












3XUFKDVH%XULHG3LSH7UHQFK%DFNILOO0DWHULDOV
 /6












$%&%XULHG7UHQFK%DFNILOO
 7RQ












6DQG%XULHG7UHQFK%DFNILOO
 7RQ












&/60%XULHG7UHQFK%DFNILOO
 &<












7UXFNLQJ6XE+DXO2II%XULHG3LSH7UHQFK6SRLOV
 (DFK












5HQW7UHQFK6KRULQJ%XULHG3LSH	9DOYHV
 :HHN












8QORDG	+DQGOH%XULHG3LSH	9DOYHV
 /)












7HVW%XULHG3LSH	9DOYHV
 /)












'LVLQIHFW%XULHG3LSH	9DOYHV
 /)












'/%3:/LQH
'HHS
 /)












&RPSOHWH3:7DSSLQJ6OHHYH	9DOYH%R[
 ($












+RW7DS3:/LQH
 ($












'/%)OXVKLQJ/LQHIURP%DFNIORZ3UHYHQWRUWR&RQFUHWH&KDQQHO
 /)












5HSODFH([LVWLQJ)LUH)ORZ0HWHU
 (DFK












5HPRYH([LVWLQJ)LUH)ORZ0HWHU
 (DFK












,QVWDOO1HZ)LUH)ORZ0HWHU
 (DFK












6OXUU\%DFNILOO3:8QGHU0DVRQU\:DOO
 /6












7HPSRUDU\6XSSRUWRI0DVRQU\:DOO)RRWHU
 /6












3XUFKDVH&/60%DFNILOO
 &<












6DFN&/606OXUU\
 &<












5HDG\0L[)XHO)HH
 ($












5HDG\0L[(QYLURQPHQWDO)HH
 ($












3ODFH&/60%DFNILOO8QGHU0DVRQU\:DOO)RRWHU
3DVW(DFKVLGHRI
 &<












$ERYH*URXQG3LSH	9DOYHV
 (DFK












3XUFKDVH$ERYH*URXQG3LSH	9DOYHV3\UDPLG3HDN6LWH
 /6












8QORDG	+DQGOH$ERYH*URXQG3LSH	9DOYHV
 /)












7HVW$ERYH*URXQG3LSH	9DOYHV
 /)












'LVLQIHFW$ERYH*URXQG3LSH	9DOYHV
 /)












&%6
3RVLWLRQ&RGH
'HVFULSWLRQ
)RUHFDVW
724XDQWLW\
8QLWRI
0HDVXUH
8QLW&RVW
7RWDO&RVW
)RUHFDVW
/DERU7RWDO&RVW
0DQ+RXUV
7RWDO
QHG(TXLSPHQW7RWDOXEFRQWUDFW7RWDO&RV6XSSOLHV7RWDO&RVDWHULDOV7RWDO&RHQWHG(TXLSPHQW7RWDO&R)HHV7RWDO&RV7/&DWHJRU\7RWDO&RV

%DFNIORZ3UHYHQWHU3LSH	9DOYHV
 /)












7ULPWR)LW%DFNIORZ3UHYHQWHU3LSH	9DOYHV
 /)












,QVWDOO%DFNIORZ3UHYHQWHU3LSH	9DOYHV
 /)












5HVHUYRLU0HWHULQJ6WUXFWXUH3LSH	9DOYHV
 /)












7ULPWR)LW5HVHUYRLU0HWHULQJ6WUXFWXUH3LSH	9DOYHV
 /)












,QVWDOO5HVHUYRLU0HWHULQJ6WUXFWXUH3LSH	9DOYHV
 /)












68%&RPSOHWH:HOG2Q7DSSLQJ6OHHYH
 /6












3DLQW	&RDWLQJV3\UDPLG3HDN6LWH
 /6












75$)),&&21752/3<5$0,'3($.
 (DFK












7UDIILF&RQWURO68%3\UDPLG3HDN
 :HHN












(/(&75,&$/3<5$0,'3($.
 (DFK












&UDIW6XSHUYLVLRQ(OHFWULFDO6XE6SSRUW
 :HHN












(OHFWULFDO68%3<5$0,'3($.(;&/8',1*/21*/($'352&85(0(17
 (DFK












0*&6XE6XSSRUW
 (DFK












(OHFWULFDO'XFWEDQN
 /)












3XUFKDVH'XFWEDQN%DFNILOO0DWHULDOV
 &<












36,&RQFUHWH
 &<












5HDG\0L[)XHO)HH
 ($












5HDG\0L[(QYLURQPHQWDO)HH
 ($












5HDG\0L[,FH	1LWUR)HH
 &<












8WLOLW\5HG&RORU
 &<












&RORU:DVKRXW&KDUJH
 ($












'LJ	%DFNILOO(OHFWULFDO'XFWEDQNV
 /)












+DXO2II'XFWEDQN6SRLOV
 ($












67	72123$+6,7(
 (DFK












6,7(:25.VW	72123$+
 (DFK












&UDIW6XSHUYLVLRQ6LWH:RUN
 :HHN












&RQVXPDEOH&RQVWUXFWLRQ6XSSOLHV6LWH:RUNRI&UDIW/DERU&RVW
 /6












6LWH'HPROLWLRQ
 (DFK












'HPROLVK([LVWLQJ3LSLQJ,QVLGH9DXOW
 /6












([SRVH	5HPRYH8QGHUJURXQG3LSHDW(DVWVLGHRI9DXOW
 /6












([SRVH	5HPRYH8QGHUJURXQG3LSHDW:HVWVLGHRI9DXOW
 /6












3RWKROH([LVWLQJ8WLOLWLHV
 'D\












&%6
3RVLWLRQ&RGH
'HVFULSWLRQ
)RUHFDVW
724XDQWLW\
8QLWRI
0HDVXUH
8QLW&RVW
7RWDO&RVW
)RUHFDVW
/DERU7RWDO&RVW
0DQ+RXUV
7RWDO
QHG(TXLSPHQW7RWDOXEFRQWUDFW7RWDO&RV6XSSOLHV7RWDO&RVDWHULDOV7RWDO&RHQWHG(TXLSPHQW7RWDO&R)HHV7RWDO&RV7/&DWHJRU\7RWDO&RV

(DUWKZRUNVIRU&RQFUHWH
 /6












3XUFKDVH6XEEDVH%DFNILOO0DWHULDOV
 7RQ












7UXFNLQJ6XE+DXO2II6SRLOV
 ($












(DUWKZRUNVIRU1HZ(OHFWULFDO(TXLSPHQW3DG
 /6












([FDYDWHWR6XEJUDGH1HZ(OHFWULFDO(TXLSPHQW3DG
 &<












3ODFHDQG&RPSDFW$%&6XEEDVH1HZ(OHFWULFDO(TXLSPHQW3DG
 7RQ












)LQH*UDGH1HZ(OHFWULFDO(TXLSPHQW3DG
 6)












/RDG2XW6SRLOV1HZ(OHFWULFDO(TXLSPHQW3DG
 ($












6LWH&RQFUHWH
 &<












3XUFKDVH5HDG\0L[0DWHULDOV
 &<












36,&RQFUHWH
 &<












5HDG\0L[)XHO)HH
 ($












5HDG\0L[(QYLURQPHQWDO)HH
 ($












5HDG\0L[,FH	1LWUR)HH
 &<












5HDG\0L[6KRUW/RDG)HH
 ($












3XUFKDVH)RUPZRUN0DWHULDOV
 6)












1HZ(OHFWULFDO(TXLSPHQW3DG
 &<












)RUP	6WULS1HZ(OHFWULFDO(TXLSPHQW3DG
 6)












3XUFKDVH5HEDU1HZ(OHFWULFDO(TXLSPHQW3DG
 &<












,QVWDOO5HEDU1HZ(OHFWULFDO(TXLSPHQW3DG
 /6












3ODFH	)LQLVK1HZ(OHFWULFDO(TXLSPHQW3DG
 &<












&XUH&RQFUHWH1HZ(OHFWULFDO(TXLSPHQW3DG
 6)












352&(663,3,1*67	72123$+
 (DFK












&UDIW6XSHUYLVLRQ3URFHVV3LSH
 :HHN












&RQVXPDEOH&RQVWUXFWLRQ6XSSOLHV3URFHVV3LSLQJRI&UDIW/DERU
 /6












%XULHG3LSH	9DOYHV
 (DFK












3XUFKDVH%XULHG3LSH	9DOYHVVW	7RQRSDK6LWH
 /6












3XUFKDVHG%XULHG3LSH7UHQFK%DFNILOO0DWHULDOV(DVW	:HVWVLGH
 7RQ












$%&%XULHG7UHQFK%DFNILOO(DVW	:HVWVLGH
 7RQ












6DQG%XULHG7UHQFK%DFNILOO(DVW	:HVWVLGH
 7RQ












7UXFNLQJ6XE+DXO2II%XULHG3LSH7UHQFK6SRLOV(DVW	:HVWVLGH
 (DFK












5HQW7UHQFK6KRULQJ%XULHG3LSH	9DOYHV
 :HHN












8QORDG	+DQGOH%XULHG3LSH	9DOYHV
 /)












&%6
3RVLWLRQ&RGH
'HVFULSWLRQ
)RUHFDVW
724XDQWLW\
8QLWRI
0HDVXUH
8QLW&RVW
7RWDO&RVW
)RUHFDVW
/DERU7RWDO&RVW
0DQ+RXUV
7RWDO
QHG(TXLSPHQW7RWDOXEFRQWUDFW7RWDO&RV6XSSOLHV7RWDO&RVDWHULDOV7RWDO&RHQWHG(TXLSPHQW7RWDO&R)HHV7RWDO&RV7/&DWHJRU\7RWDO&RV

7HVW%XULHG3LSH	9DOYHV
 /)












'LVLQIHFW%XULHG3LSH	9DOYHV
 /)












'/%',3IURP%)3WR9DXOW(DVWVLGH
 /)












'/%',3IURP9DXOW&XWDQG&DS:HVWVLGH
 /)












&RUH%RWK6LGHVRI9DXOWWR
 (DFK












$ERYH*URXQG3LSH	9DOYHV
 (DFK












3XUFKDVH$ERYH*URXQG3LSH	9DOYHVVW	7RQRSDK6LWH
 /6












8QORDG	+DQGOH$*3LSH	9DOYHV
 /)












7HVW$*3LSH	9DOYHV
 /)












'LVLQIHFW$*3LSH	9DOYHV
 /)












%)3/LQH
 /6












7ULPWR)LW%)3/LQH
 /6












,QVWDOO%)3/LQH
 /6












	',3,QVLGH9DXOW
 /)












7ULPWR)LW	',3,QVLGH9DXOW
 /)












,QVWDOO	',3,QVLGH9DXOW
 /)












3DLQW	&RDWLQJVVW	7RQRSDK
 /6












(/(&75,&$/67	72123$+
 (DFK












&UDIW6XSHUYLVLRQ(OHFWULFDO6XE6XSSRUW
 :HHN












(,	&6XEVW	7RQRSDK(;&/8',1*/21*/($'352&85(0(17
 (DFK












0*&6XE6XSSRUW
 (DFK












(OHFWULFDO'XFWEDQN
 /)












3XUFKDVH'XFWEDQN%DFNILOO0DWHULDOV
 &<












36,&RQFUHWH
 &<












5HDG\0L[)XHO)HH
 ($












5HDG\0L[(QYLURQPHQWDO)HH
 ($












5HDG\0L[,FH	1LWUR)HH
 &<












8WLOLW\5HG&RORU
 &<












&RORU:DVKRXW&KDUJH
 ($












'LJ	%DFNILOO(OHFWULFDO'XFWEDQNV
 /)












+DXO2II'XFWEDQN6SRLOV
 ($












$//2:$1&(6&217,1*(1&<
 (DFK












$GGLWLRQDO7UDIILF&RQWURO$OORZDQFH
 (DFK












&%6
3RVLWLRQ&RGH
'HVFULSWLRQ
)RUHFDVW
724XDQWLW\
8QLWRI
0HDVXUH
8QLW&RVW
7RWDO&RVW
)RUHFDVW
/DERU7RWDO&RVW
0DQ+RXUV
7RWDO
QHG(TXLSPHQW7RWDOXEFRQWUDFW7RWDO&RV6XSSOLHV7RWDO&RVDWHULDOV7RWDO&RHQWHG(TXLSPHQW7RWDO&R)HHV7RWDO&RV7/&DWHJRU\7RWDO&RV

/DQGVFDSH5HVWRUDWLRQ$OORZDQFH3\UDPLG3HDN6LWH
 (DFK












/DQGVFDSH5HVWRUDWLRQ$OORZDQFHVW	7RQRSDK6LWH
 (DFK












+DUG'LJ$OORZDQFH
 (DFK












$VSKDOW6WULSLQJ$OORZDQFH
 (DFK












*UDWLQJ0RGLILFDWLRQ$OORZDQFH#3\UDPLG3HDN
 (DFK












3LSH6XSSRUW'HVLJQ$OORZDQFH
 (DFK












&RQWUDFWRU
V&RQWLQJHQF\
 (DFK























City of Glendale Standard Form Agreement Between Owner and CM@Risk (January 28, 2025) 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
T H I S P A G E I S B L A N K

City of Glendale Standard Form Agreement Between Owner and CM@Risk (January 28, 2025) 
 
 
EXHIBIT E 
Construction Documents necessary to define Scope of Work and Deliverables for the 
Construction Phase Services, including plans, designs, drawings, specifications and other 
required Contract Documents 
 
(15 pages - To be Incorporated by Amendment) 
 
See attached

ÍŜĖŜϙĺċϙ(ŜťĖıÍťôϙϯϙ@a„ϙ
@ôIJôŘÍīϙIIJċĺŘıÍťĖĺIJϙ
„ŘĺĤôèťϙIIJċĺŘıÍťĖĺIJϙ
“ēĖŜϙ@a„ϙĖŜϙċĺŘϙťēôϙĖťƅϙĺċϙ@īôIJîÍīôϱ„ēĺôIJĖƄϙ®ÍťôŘϙ‹ŪŕŕīƅϙIIJťôŘèĺIJIJôèťŜϙ„ŘĺĤôèťϠϙſēĖèēϙĖŜϙīĺèÍťôîϙ
ÍťϙıŪīťĖŕīôϙŜĖťôŜϙīĖŜťôîϙĖIJϙťēôϙŕŘĺĤôèťϙîĺèŪıôIJťŜϟϙϙϙϙϙ
iſIJôŘϡϙϙϙ
ϙ
Ėťƅϙĺċϙ@īôIJîÍīôϙ
(IJČĖIJôôŘϡϙϙϙ
ϙ
īÍèħϙÍIJîϙ«ôÍťèēϙ
a‡ϡϙϙϙ
ϙ
a@ϙĺIJťŘÍèťĺŘŜϙ
iſIJôŘϙĺIJťŘÍèťϙbĺϡϙϙ͑͐͑͑͒͗
ϟ͑ ϙ
„ŘĺĤôèťϙ‹èĺŕôϙ"ôŜèŘĖŕťĖĺIJϙ
“ēĖŜϙŕŘĺĤôèťϙſĖīīϙèĺıŕīƅϙſĖťēϙ(„ϙČŘÍIJťϙŘôŗŪĖŘôıôIJťŜϙŜŪèēϙÍŜϙťēôϙ"ÍŽĖŜϙÍèĺIJϙèťϙÍIJîϙϙſēôŘôϙ
ŕĺŜŜĖæīôϟϙ“ēĖŜϙŕŘĺĤôèťϙĖIJèīŪîôŜϙŪŕČŘÍîôŜϙÍIJîϙÍîîĖťĖĺIJŜϙťĺϙťēôϙ„ƅŘÍıĖîϙ„ôÍħϙÍIJîϙ“ĺIJĺŕÍēϙ«ÍŪīťϙ
īĺèÍťĖĺIJŜϙÍŜϙIJĺťôîϙæôīĺſϡϙϙϙ
‹Ėťôϙ͐ ϙϱϙ„ƅŘÍıĖîϙ„ôÍħϙ„ÍŘħſÍƅϙÍIJîϙ„ĖIJIJÍèīôϙ«ĖŜťÍϙ"ŘĖŽôϙϼ„ƅŘÍıĖîϙÍIJîϙ„ĖIJIJÍèīôϽϡϙ‹Ėťôϙ͐ ϙĖŜϙ
īĺèÍťôîϙĖIJϙťēôϙŜĺŪťēſôŜťϙèĺŘIJôŘϙĺċϙťēôϙĖťƅЍŜϙ„ƅŘÍıĖîϙ„ôÍħϙ®ÍťôŘϙ“ŘôÍťıôIJťϙ„īÍIJťϙϼ®“„ϽϠϙīĺèÍťôîϙÍťϙ͑͗͐͏͐
ϙbϟϙ͕͒
Řîϙ"ŘĖŽôϠϙ„ēĺôIJĖƄϠϙ¾ϠϙſĖťēĖIJϙťēôϙĖťƅϙĺċϙ„ēĺôIJĖƄϙıŪIJĖèĖŕÍīϙèĖťƅϙīĖıĖťŜϟϙ“ēĖŜϙŕŘĺĤôèťϙ
ĖIJèīŪîôŜϙťēôϙĖIJŜťÍīīÍťĖĺIJϙĺċϙÍŕŕŘĺƄĖıÍťôīƅϙ͕͐͏
ϙċťϟϙĺċϙIJôſϙ͐͑
ϱĖIJèēϙſÍťôŘīĖIJôϠϙſēĖèēϙſĖīīϙèĺIJIJôèťϙťĺϙÍIJϙ
ôƄĖŜťĖIJČϙĖťƅϙĺċϙ„ēĺôIJĖƄϙťŘÍIJŜıĖŜŜĖĺIJϙīĖIJôϙĖIJϙ„ƅŘÍıĖîϙ„ôÍħϙ„ÍŘħſÍƅϙϼſĖťēĖIJϙ„ēĺôIJĖƄϙŘĖČēťϱĺċϱſÍƅϽϟϙ
“ēôϙIJôſϙ͐͑
ϱĖIJèēϙſÍťôŘīĖIJôϙſĖīīϙæôϙŘĺŪťôîϙæôīĺſϙČŘÍîôϙťĺϙèĺIJIJôèťϙťĺϙťēôϙ„ƅŘÍıĖîϙ„ôÍħϙ®“„ϙ͕͒
ϱĖIJèēϙ
îĖŜťŘĖæŪťĖĺIJϙīĖIJôϙīĺèÍťôîϙĺIJϙťēôϙ®“„ϙŕŘĺŕôŘťƅϟϙťϙťēôϙŕĺĖIJťϙĺċϙèĺIJIJôèťĖĺIJϠϙťēôϙIJôſϙſÍťôŘīĖIJôϙſĖīīϙ
èĺIJIJôèťϙÍæĺŽôϙČŘÍîôϙťĺϙÍϙIJôſϙŕĖŕĖIJČϙÍŜŜôıæīƅϙèĺIJŜĖŜťĖIJČϙĺċϙÍϙæÍèħċīĺſϙŕŘôŽôIJťôŘϠϙċīĺſϙıôťôŘϠϙċīĺſϙ
èĺIJťŘĺīϙŽÍīŽôϠϙÍIJîϙÍϙĖťƅϙĺċϙ„ēĺôIJĖƄϙĖŜĺīÍťĖĺIJϙŽÍīŽôϟϙ>ĖIJÍīīƅϠϙťēôϙÍæĺŽôϙČŘÍîôϙŕĖŕĖIJČϙÍŜŜôıæīƅϙſĖīīϙ
ŕŘĺŽĖîôϙÍϙťôôϙèĺIJIJôèťĖĺIJϙťĺϙÍϙIJôſϙ͕ ϱĖIJèēϙċīŪŜēĖIJČϯîĖŜèēÍŘČôϙŕĖŕôϙťĺϙÍIJϙôƄĖŜťĖIJČϙĺIJϱŜĖťôϙèĺIJèŘôťôϙ
ŜſÍīôϙæôċĺŘôϙĖťϙèĺIJťĖIJŪôŜϙĖIJťĺϙťēôϙ„ƅŘÍıĖîϙ„ôÍħϙ®“„ϙîĖŜťŘĖæŪťĖĺIJϙŽÍŪīťϙÍIJîϙèĺIJIJôèťŜϙťĺϙťēôϙ͕͒
ϱĖIJèēϙ
îĖŜťŘĖæŪťĖĺIJϙīĖIJôϟϙ“ēôϙIJôſϙŕĖŕĖIJČϙÍŜŜôıæīƅϙſĖīīϙŘôŗŪĖŘôϙťēôϙĖIJŜťÍīīÍťĖĺIJϙĺċϙIJôſϙôīôèťŘĖèÍīϙŕÍIJôīŜϠϙ
ÍŕŕŘĺƄĖıÍťôīƅϙ͕͑͏
ϙ[ϟ>ϙĺċϙ͐ ϱĖIJèēϙÍIJîϙ͑ ϱĖIJèēϙôīôèťŘĖèÍīϙèĺIJîŪĖťϙÍIJîϙſĖŘĖIJČϠϙÍIJîϙÍIJϙÍIJťôIJIJÍϙſĖťēĖIJϙťēôϙ
ŕīÍIJťϙŜĖťôϙċôIJèôϟϙ
ϙ‹Ėťôϙ͑ ϙϳϙ͔͐
ŜťϙŽôIJŪôϙЭϙ“ĺIJĺŕÍēϙ"ŘĖŽôϙϼ͔͐
ŜťϙЭϙ“ĺIJĺŕÍēϽϡϙ
‹Ėťôϙ͑ ϙĖŜϙīĺèÍťôîϙĺIJϙťēôϙŜĺŪťēôÍŜťϙèĺŘIJôŘϙĺċϙbϟϙ͔͐
ŜťϙŽôIJŪôϙÍIJîϙ®ϟϙ“ĺIJĺŕÍēϙ"ŘĖŽôϟϙ“ēĖŜϙŕŘĺĤôèťϙ
ŘôŗŪĖŘôŜϙÍϙIJôſϙ͐͑
ϱĖIJèēϙæÍèħċīĺſϙŕŘôŽôIJťôŘϙťĺϙÍīīĺſϙċīĺſϙĖIJϙťēôϙĺŕŕĺŜĖťôϙîĖŘôèťĖĺIJϙÍIJîϙÍIJϙ
ÍîîĖťĖĺIJÍīϙĖťƅϙĺċϙ„ēĺôIJĖƄϙĖŜĺīÍťĖĺIJϙŽÍīŽôϙŪŕŜťŘôÍıϙĺċϙťēôϙæÍèħċīĺſϙŕŘôŽôIJťôŘϟϙ“ēôϙôƄĖŜťĖIJČϙ
ŜŪæŜŪŘċÍèôϙèĺIJèŘôťôϙŽÍŪīťϙſĖīīϙæôϙŘôŪŜôîϠϙÍIJîϙťēôϙŕĖŕĖIJČϙſĖīīϙæôϙıĺîĖċĖôîϟϙ“ēôϙÍŘôÍŜϙĺIJϙæĺťēϙ
ŜĖîôŜϙĺċϙťēôϙŽÍŪīťϙſĖīīϙæôϙôƄèÍŽÍťôîϠϙÍIJîϙťēôϙôƄĖŜťĖIJČϙ͗ ϱĖIJèēϙŕĖŕĖIJČϠϙĖIJèīŪîĖIJČϙ͗ Ƅ͐͑
ϙŘôîŪèôŘŜϠϙſĖīīϙ
æôϙŘôıĺŽôîϙÍIJîϙŘôŕīÍèôîϙſĖťēϙIJôſϙ͐͑
ϱĖIJèēϙŕĖŕĖIJČϟϙ“ēôϙôƄĖŜťĖIJČϙ͗ ϱĖIJèēϙċīĺſϙıôťôŘϙſĖťēĖIJϙťēôϙ
ŽÍŪīťϙſĖīīϙæôϙŘôŕīÍèôîϙſĖťēϙÍϙIJôſϙ͐͑
ЋϙċīĺſϙıôťôŘϟϙϙIJôſϙċīĺſϙèĺIJťŘĺīϙŽÍīŽôϙſĖīīϙæôϙÍîîôîϙťĺϙťēôϙ
ŕĖŕĖIJČϙèĺIJċĖČŪŘÍťĖĺIJϙſĖťēĖIJϙťēôϙIJôſϙŽÍŪīťϟϙϙϙIJôſϙÍIJťôIJIJÍϙÍIJîϙôīôèťŘĖèÍīϙŕÍIJôīϙſĖīīϙæôϙĖIJŜťÍīīôîϙ

ĺIJϙťēôϙŜĖťôДŜϙŜĺŪťēϙŜĖîôϙťĺϙŕŘĺŽĖîôϙÍîîĖťĖĺIJÍīϙèĺııŪIJĖèÍťĖĺIJϙťĺϙťēôϙĖťƅϙĺċϙ@īôIJîÍīôϙÍIJîϙťēôϙ
Ėťƅϙĺċϙ„ēĺôIJĖƄϟϙ
(ŜťĖıÍťĖIJČϙaôťēĺîĺīĺČƅϙϙ
“ēôϙŕŘĖıÍŘƅϙôŜťĖıÍťĖIJČϙıôťēĺîĺīĺČƅϙŪŜôîϙťĺϙŕŘôŕÍŘôϙťēôϙ@a„ϙĖŜϙæÍŜôîϙĺIJϙťēôϙèŪŘŘôIJťϙ͐͏͏҇
ϙŕīÍIJŜϙ
ċĺŘϙ„ƅŘÍıĖîϙ„ôÍħϠϙťēôϙèŪŘŘôIJťϙ͐͏͏҇
ϙŕīÍIJŜϙŕôIJîĖIJČϙèĖťƅϙÍŕŕŘĺŽÍīϙċĺŘϙ“ĺIJĺŕÍēϠϙÍIJîϙ͐͏͏҇
ϙ
ŜŕôèĖċĖèÍťĖĺIJŜϙĖŜŜŪôîϙæƅϙīÍèħϙÍIJîϙ«ôÍťèēϟϙϙ“ēôϙŕŘĖèĖIJČϙĖIJèīŪîôîϙſĖťēϙťēĖŜϙ@a„ϙſÍŜϙîôŽôīĺŕôîϙſĖťēϙ
ťēôϙŜħĖīīϙÍIJîϙèÍŘôϙôƄôŘèĖŜôîϙæƅϙÍϙŘôÍŜĺIJÍæīôϙèĺIJťŘÍèťĺŘЍŜϙŜħĖīīϠϙôƄŕôŘťĖŜôϠϙÍIJîϙôƄŕôŘĖôIJèôϙŪIJîôŘϙ
IJĺŘıÍīϙıÍŘħôťϙèĺIJîĖťĖĺIJŜϟϙϙϙ
@a„ϙ͐ ϙĖŜϙŕŘôŕÍŘôîϙÍIJîϙŜŪæıĖťťôîϙťĺϙÍīīĺſϙċĺŘϙÍIJϙÍèèŪŘÍťôϙèĺŜťϙôŽÍīŪÍťĖĺIJϙĺċϙŕŘĺĤôèťϙèĺıŕĺIJôIJťŜϟϙϙ
“ēĖŜϙ@a„ϙèĺŽôŘŜϙæĺťēϙ„ƅŘÍıĖîϙ„ôÍħϙÍIJîϙ“ĺIJĺŕÍēϙ«ÍŪīťϙīĺèÍťĖĺIJŜϟϙa@ϙēÍŜϙÍIJϙÍŕŕŘĺŽôîϙ
„ŘôèĺIJŜťŘŪèťĖĺIJϙĺIJťŘÍèťϙťēÍťϙèĺŽôŘŜϙ‹ťÍċċϙÍIJîϙīĺIJČϱīôÍîϙıÍťôŘĖÍīϙèĺŜťŜϟϙ“ēĖŜϙſĖīīϙæôϙôƄôèŪťôîϙŽĖÍϙ
ťēôϙīīĺſÍIJèôϙ˜ŜôϙŪťēĺŘĖƏÍťĖĺIJϙŕŘĺèôŜŜϟϙ
®‹ϡϙ“ĺϙÍèèŪŘÍťôīƅϙŕŘĖèôϙÍīīϙŜèĺŕôŜϙċĺŘϙťēôϙ@a„Ϡϙa@ϙĺIJťŘÍèťĺŘŜϙſĖīīϙîĖŽĖîôϙťēôϙŕŘĺĤôèťϙĖIJťĺϙÍIJϙ
ÍŘôÍϱŜŕôèĖċĖèϙſĺŘħϙæŘôÍħîĺſIJϙŜťŘŪèťŪŘôϙèĺIJŜĖŜťĖIJČϙĺċϙťēôϙċĺīīĺſĖIJČϡϙ
•͏͑
ϙϳϙ@ôIJôŘÍīϙ‡ôŗŪĖŘôıôIJťŜϙϙ
•͏͒
ϙϳϙ„ƅŘÍıĖîϙ„ôÍħϙ‹Ėťôϙϙ
•͏͓
ϙϳϙ͔͐
ŜťϙÍIJîϙ“ĺIJĺŕÍēϙ‹ĖťôŜϙ
a@ϙĺIJťŘÍèťĺŘŜϙſĖīīϙîôŽôīĺŕϙťēĖŜϙ®‹ϙťĺϙıÍťèēϙťēôϙŕŘĺĤôèťϙîŘÍſĖIJČŜϙÍIJîϙŜŕôèĖċĖèÍťĖĺIJŜϠϙÍīīĺſĖIJČϙ
ŜťÍħôēĺīîôŘŜϙťĺϙèĺıŕÍŘôϙÍIJîϙŘôŽĖôſϙťēôıϙôÍŜĖīƅϟϙa@ϙſĖīīϙŪŜôϙťēôϙŜÍıôϙŜťŘŪèťŪŘôϙċĺŘϙÍīīϙôŜťĖıÍťôŜϙ
ÍIJîϙŜèēôîŪīôŜϙċĺŘϙŪIJĖċĺŘıĖťƅϟϙϙϙ
"ôŜĖČIJϙÍŜĖŜϙ
“ēôϙŘôċôŘôIJèôϙîĺèŪıôIJťŜϙÍŘôϙÍŜϙċĺīīĺſŜϡϙ"ŘÍſĖIJČŜϡϙ"ŘÍſĖIJČŜϠϙŜŕôèĖċĖèÍťĖĺIJŜϠϙŜŕôèĖċĖèÍťĖĺIJŜϠϙÍIJîϙ
îÍťôϟϙϙϙ
•
„ƅŘÍıĖîϙ„ôÍħϙ®ÍťôŘϙ‹ŪŕŕīƅϙIIJťôŘèĺIJIJôèťϙϳϙ„ēĺôIJĖƄϡϙ“ôèēIJĖèÍīϙ‹ŕôèĖċĖèÍťĖĺIJŜϙ͐͏͏҇
ϙ
‹ŪæıĖťťÍīϢϙ"Íťôîϙ"ôèôıæôŘϙ͑͏͓͑
ϙ
•͔͐
ŜťϙÍIJîϙ“ĺIJĺŕÍēϙIIJťôŘèĺIJIJôèťϙϳϙ„ēĺôIJĖƄϯ@īôIJîÍīôϡϙ“ôèēIJĖèÍīϙ‹ŕôèĖċĖèÍťĖĺIJŜϙ͐͏͏҇
ϙ
‹ŪæıĖťťÍīϢϙ"Íťôîϙ‹ôŕťôıæôŘϙ͑͏͓͑
ϙϙ
•
„ƅŘÍıĖîϙ„ôÍħϙ®ÍťôŘϙ‹ŪŕŕīƅϙIIJťôŘèĺIJIJôèťϙϳϙ„ēĺôIJĖƄϡϙ„īÍIJϙ‹ôťϙ͐͏͏҇
ϙ‹ŪæıĖťťôîϢϙ"Íťôîϙ
bĺŽôıæôŘϙ͑͐
Ϡϙ͑͏͑͑
ϙ
•͔͐
ŜťϙÍIJîϙ“ĺIJĺŕÍēϙIIJťôŘèĺIJIJôèťϙϳϙ„ēĺôIJĖƄϯ@īôIJîÍīôϡϙ„īÍIJϙ‹ôťϙ͐͏͏҇
ϙ‹ŪæıĖťťôîϙϼŕôIJîĖIJČϙèĖťƅϙ
ÍŕŕŘĺŽÍīϽϢϙ"Íťôîϙ‹ôŕťôıæôŘϙ͐͐
Ϡϙ͑͏͓͑
ϙ
„īÍIJIJĖIJČϙÍŜĖŜϙ
“ēôϙĖťôıŜϙŕŘĺŽĖîôîϙÍŘôϙťēôϙÍŜŜŪıôîϙſĺŘħϙſôôħϠϙſēĖèēϙſĖīīϙĖIJèīŪîôϙa@ЍŜϙŕīÍIJIJôîϙŪŜôϙĺċϙ
ĺŽôŘťĖıôϠϙĺŽôŘIJĖČēťϠϙĺŘϙſôôħôIJîϙſĺŘħϙϼĖċϙŘôŗŪĖŘôîϽϟϙ"ŪŘĖIJČϙťēôϙôŜťĖıÍťôϙŕŘĺèôŜŜϠϙa@ϙôIJČÍČôîϙ
īĺèÍīϙŜŪæèĺIJťŘÍèťĺŘŜϙÍIJîϙŜŪŕŕīĖôŘŜϙĖIJϙĺŘîôŘϙťĺϙŕŘĺŽĖîôϙæôIJôċĖèĖÍīϙıÍŘħôťϙèĺŜťϟϙ
“ēôϙŜèēôîŪīĖIJČϙÍŜŜŪıŕťĖĺIJŜϙŪŜôîϙĖIJϙŕŘôŕÍŘĖIJČϙťēôϙŜèēôîŪīôϙÍIJîϙôŜťĖıÍťôϙĖIJèīŪîôϡϙ

•
“ēôϙôŜťĖıÍťôϙÍIJîϙŜèēôîŪīôϙÍŘôϙèŪŘŘôIJťīƅϙæÍŜôîϙĺIJϙ͔ ôÍϙ͗ ϱēĺŪŘϙŜēĖċťŜϟ
ĺŜťϙIîôIJťĖċĖèÍťĖĺIJϙ
“ēôϙċĺīīĺſĖIJČϙèĺŜťϙæÍŜĖŜϠϙċÍèťĺŘŜϠϙÍIJîϙŕŘĖèĖIJČϙŜĺŪŘèôŜϙſôŘôϙŪŜôîϡϙ
[ÍæĺŘϙÍIJîϙĺIJŜťŘŪèťĖĺIJϙ(ŗŪĖŕıôIJťϙ‡ÍťôŜϡϙϙ
•
[ÍæĺŘϙēÍŜϙæôôIJϙĖIJèīŪîôîϙÍèèĺŘîĖIJČϙťĺϙŕŘôŽÍĖīĖIJČϙſÍČôϙŘÍťôŜϙÍŕŕīĖèÍæīôϙÍťϙťēôϙťĖıôϙĺċϙťēô
ôŜťĖıÍťôϟϙϙ‡ÍťôŜϙĖIJèīŪîôϙÍīīϙÍŕŕīĖèÍæīôϙæÍŜôϙŕÍƅϠϙťÍƄôŜϠϙÍIJîϙċŘĖIJČôŜϟ
•
(ŗŪĖŕıôIJťϙŘÍťôŜϙſôŘôϙæÍŜôîϙĺIJϙĖIJťôŘIJÍīϙŘÍťôŜϙîôťôŘıĖIJôîϙæƅϙa@ϙĺIJťŘÍèťĺŘŜДϙôŗŪĖŕıôIJť
ŜôŘŽĖèôŜϙîôŕÍŘťıôIJťϟ
•
“ēôϙſôôħīƅϙŪIJĖťϙèĺŜťϙċĺŘϙôÍèēϙĖIJîĖŽĖîŪÍīϙĖIJèīŪîôŜϙťēôĖŘϙīÍæĺŘϙÍIJîϙæŪŘîôIJϙèĺŜťŜϠϙĖIJèīŪîĖIJČϙÍ
ťĺĺīϙħĖťϙťēÍťϙĖIJèīŪîôŜϙÍϙèĺıŕŪťôŘϙÍIJîϙèôīīϙŕēĺIJôϟ
[ÍæĺŘϙ„ŘĺîŪèťĖŽĖťƅϡϙ
•
a@ϙēÍŜϙŪŜôîϙÍϙèĺıæĖIJÍťĖĺIJϙĺċϙēĖŜťĺŘĖèÍīϙŕŘĺîŪèťĖĺIJŜϙċŘĺıϙŜĖıĖīÍŘϙŕŘĺĤôèťŜϙÍIJîϙĖIJîŪŜťŘƅ
ŜťÍIJîÍŘîŜϟ
IIJîĖŘôèťϙĺŜťŜϠϙIIJŜŪŘÍIJèôŜϠϙÍIJîϙ>ôôŜϡϙ
•
a@ϙēÍŜϙĖIJèīŪîôîϙĖIJîĖŘôèťϙèĺŜťŜϠϙĖIJèīŪîĖIJČϙĖťŜϙŜŪŕôŘŽĖŜĖĺIJϙŜťÍċċϙÍIJîϙôƄŕôIJŜôŜϙċĺŘϙťēôϙŜťÍċċЍŜ
ſĺŘħĖIJČϙÍèèĺııĺîÍťĖĺIJŜϠϙŜŪèēϙÍŜϙťŘÍĖīôŘŜϠϙĺċċĖèôϙŜŪŕŕīĖôŜϠϙŜÍċôťƅϙĖťôıŜϠϙôťèϟϙ“ēôŜô
èĺıŕĺIJôIJťŜϙÍŘôϙŕŘĖıÍŘĖīƅϙīĖŜťôîϙŪIJîôŘϙťēôϙ@ôIJôŘÍīϙ‡ôŗŪĖŘôıôIJťŜϙŜôèťĖĺIJϙĺċϙťēĖŜϙ@a„
ŜŪæıĖŜŜĖĺIJДŜϙîôťÍĖīôîϙĺŕôIJϙæĺĺħϙôŜťĖıÍťôϟ
•
a@ϙēÍŜϙĖIJèīŪîôîϙĖIJŜŪŘÍIJèôŜϠϙæĺIJîŜϠϙÍIJîϙċôôŜϙÍŜϙŕÍŘťϙĺċϙťēĖŜϙ@a„ϟ
“ÍƄôŜϙÍIJîϙ"ŪťĖôŜϡϙa@ϙĺIJťŘÍèťĺŘŜϙēÍŜϙĖIJèīŪîôîϙťÍƄôŜϙÍŜϙħIJĺſIJϙÍIJîϙôIJÍèťôîϙĖIJťĺϙīÍſϙÍŜϙĺċϙťēôϙ
îÍťôϙĺċϙa@ДŜϙĺŘĖČĖIJÍīϙŕŘĺŕĺŜÍīϟϙIJƅϙIJôſϙťÍƄϙôIJÍèťôîϙĖIJťĺϙīÍſϙÍċťôŘϙŜŪæıĖŜŜĖĺIJϙĺċϙťēĖŜϙ@a„ϙſĖīīϙæôϙ
ÍîîôîϙŽĖÍϙŪŕîÍťôîϙ@a„ϙĺŘϙèēÍIJČôϙĺŘîôŘϟϙ
(ŜèÍīÍťĖĺIJϡϙ“ēĖŜϙôŜťĖıÍťôϙĖŜϙæÍŜôîϙĺIJϙЊťĺîÍƅЍŜϙîĺīīÍŘŜЋϟϙ
īīĺſÍIJèôŜϙ
īīĺſÍIJèôŜϙēÍŽôϙæôôIJϙĖîôIJťĖċĖôîϙÍIJîϙĖIJèīŪîôîϙĖIJϙťēĖŜϙ@a„ϟϙ“ēôϙôŜťĖıÍťôϙĖîôIJťĖċĖôŜϙÍīīϙÍīīĺſÍIJèôŜϙ
ÍŜϙÍīīĺſÍIJèôŜϟϙ
“ēôϙċĺīīĺſĖIJČϙÍīīĺſÍIJèôŜϙēÍŽôϙæôôIJϙĖIJèīŪîôîϡϙ

îîĖťĖĺIJÍīϙ“ŘÍċċĖèϙĺIJťŘĺīϙīīĺſÍIJèôϙѱϙщ͔͐
Ϡ͏͏͏

[ÍIJîŜèÍŕôϙ‡ôŜťĺŘÍťĖĺIJϙīīĺſÍIJèôϙϱϙ„ƅŘÍıĖîϙ„ôÍħϙ‹Ėťôϙѱϙщ͓͏
Ϡ͏͏͏

[ÍIJîŜèÍŕôϙ‡ôŜťĺŘÍťĖĺIJϙīīĺſÍIJèôϙϱϙ͔͐
ŜťϙЭϙ“ĺIJĺŕÍēϙ‹Ėťôϙѱϙ
щ͐͏
Ϡ͏͏͏

FÍŘîϙ"ĖČϙīīĺſÍIJèôϙѱϙщ͔͏
Ϡ͏͏͏

ŜŕēÍīťϙ‹ťŘĖŕĖIJČϙīīĺſÍIJèôϙѱϙщ͔͐
Ϡ͏͏͏

@ŘÍťĖIJČϙaĺîĖċĖèÍťĖĺIJϙīīĺſÍIJèôϙЬϙıôťôŘĖIJČϙŜťŘŪèťŪŘôϙѱϙщ͔͑
Ϡ͏͏͏

„Ėŕôϙ‹ŪŕŕĺŘťϙ"ôŜĖČIJϙīīĺſÍIJèôϙѱϙщ͐͏
Ϡ͏͏͏

ĺIJťŘÍèťĺŘДŜϙĺIJťĖIJČôIJèƅϙѱϙщ͔͏
Ϡ͏͏͏
“ĺťÍīϙŽÍīŪôϙĺċϙÍīīϙīīĺſÍIJèôŜϙѱϙщ͔͑͐
Ϡ͏͏͏
īīĺſÍIJèôŜϙÍŘôϙťĺťÍīϙīŪıŕϙŜŪıŜϠϙĖIJèīŪîĖIJČϙĖIJîĖŘôèťϙèĺŜťŜϙŜŪèēϙÍŜϙæĺIJîŜϠϙĖIJŜŪŘÍIJèôϠϙÍIJîϙ
a‡ϙċôôŜϟ

CITY OF GLENDALE
5850 WEST GLENDALE AVENUE
SUITE 315
GLENDALE, AZ 85301
MARTY SOMA
(623) 930-3630
VICINITY  MAP
JOMAX
63RD
51ST AVE
T 
HAPPY VALLEY ROAD
PINNACLE PEAK ROAD
BLACK CANYON FREEWAY
N
ROAD
AVE
ROAD
67TH AVE
59TH AVE
51ST AVE
43RD AVE
35TH AVE
BEARDSLEY ROAD
BELL ROAD
 
GREENWAY ROAD
Y 
RHODES
63RD AVE
HEDGEPETH
H
ROAD
LEY
DEER
VAL
59TH AVENUE
Y
TH
E
HE
ET
GEP
EPE
PE
EDG
EDG
HE
H
PINNACLE
THUNDERBIRD
H
PARKSIDE
LANE
PARK
A K
RK
R
AR
A
67TH
PILCHER
HE
HE
HILL
H
CH
CH
CH
IL
IL H R
ER
HE
D
51ST
HAPPY
LUDDEN
AVENUE
ROAD
JOMAX
D
UD
UDDE
D
MOUNTAIN
O NTAI
AIN
U
OU
IN
I
EN
NTA
TA
MO
MO
EN
PROJECT SITE
AVENUE
VALLEY
43RD
PEAK
AVENUE
DEEMS
E
DEE
HILLS
LS
L
IL
IL
H
PEAK
HAYDEN
TURNOUT
CAP
EA
EAK
AK
PYRAMID
YR M D
I
KEY MAP
I-17
AQUEDUCT (CAP)
AP)
AQUEDUCT
C
HAYDEN
NO SCALE
NO SCALE
28101 N. 63RD AVE
VE
VE
PHOENIX, ARIZONA
A
ED
HAYD
HA
HA
PYRAMID PEAK WTP
PROJECT BENCHMARK
BRASS TAG AT SOUTH 1/4 CORNER OF SECTION 31 WITH
ELEVATION OF 1502.65 (CITY OF GLENDALE DATUM)
DATE
MCESD No.
MARICOPA COUNTY ENVIRONMENT SERVICES DEPARTMENT
(MCESD)
I HEREBY CERTIFY THAT ALL UTILITY COMPANIES WITH FACILITIES IN THE AREA OF
THIS PROJECT HAVE BEEN CONTACTED AND THE DATA PROVIDED IS SHOWN ON THIS PLAN.
I AGREE TO INDEMNIFY, DEFEND, SAVE AND HOLD HARMLESS THE CITY OF PHOENIX, ITS
OFFICERS, AGENTS, EMPLOYEES AND VOLUNTEERS FROM ANY AND ALL CLAIMS, DEMANDS,
ACTIONS, LIABILITIES, DAMAGES, LOSSES, OR EXPENSES INCURRED FOR ANY UTILITY
CONFLICTS THAT MAY ARISE.
ONSITE QUANTITIES
8" DIP CLASS 350: 140 LF
AGGREGATE BASE COURSE MATERIAL: 55 CY
OFFSITE QUANTITIES
8" DIP CLASS 350: 65 LF
ASPHALT RESTORATION: 206 SY
ASPHALT PAVEMENT: 3.5 SY
VERTICAL CONCRETE CURB ( 1 FULL LENGTH): 10 LF
CONCRETE SIDEWALK (ONE FULL PANEL):  10 SF
AGGREGATE BASE COURSE MATERIAL: 36 CY
REGISTERED ENGINEER
AS-BUILT CERTIFICATION
REGISTRATION NUMBER
DATE
PROFESSIONAL ENGINEER'S SIGNATURE AND SEAL
DATE
MICHAEL CARUSO
PROJECT MANAGER
2231 E CAMELBACK RD. #250
PHONE (602) 381-4400
GLENDALE INTERCONNECT WATER SUPPLY PIPELINE
THE PROJECT INCLUDES INSTALLING A NEW 12 INCH DUCTILE IRON PIPELINES
FOR EMERGENCY WATER SUPPLY FOR CITY OF GLENDALE'S DISTRIBUTION SYSTEM.
THE EXISTING CITY OF PHOENIX 16" TRANSMISSION LINE WILL BE HOT TAPPED
AND PROVIDED WITH A GATE VALVE, FLOW METER, ISOLATION VALVE AND
BACKFLOW PREVENTER. THE TERMINATION CONNECTION WILL BE MADE ONSITE AT
THE EXISTING GLENDALE DISTRIBUTION LINE LOCATED ON THE WATER TREATMENT
PLANT SITE.
I HEREBY CERTIFY THAT THE "RECORD DRAWING" MEASUREMENTS AS SHOWN HEREON
WERE MADE UNDER MY SUPERVISION OR AS NOTED AND ARE CORRECT TO THE BEST
OF MY KNOWLEDGE AND BELIEF.
FD169535
WATER SUPPLY INTERCONNECTS - PHOENIX
COVER SHEET/ VICINITY MAP / SHEET LIST
G-0-001
CLF
HVT
JMW
212238





1014
100% ISSUED FOR CONSTRUCTION



OF
SHT.




GLENDALE, ARIZONA 85301 (623) 930-3630
5850 W. GLENDALE AVE.
ENGINEERING DEPARTMENT
CITY OF GLENDALE




(
)
(
)
XREF 1:
XREF 2:
XREF 2:
XREF 1:
D412186
USER:
DRAWING VER.:





IF THIS BAR DOES NOT
MEASURE 1" THEN DRAWING IS
NOT TO FULL SCALE
1/2
0
1
GENERAL
G-0-001
COVER SHEET / VICINITY MAP / SHEET LIST
G-0-002
GENERAL NOTES AND LEGEND
G-0-003
ABBREVIATIONS
G-0-004
OVERALL SITE PLAN
CIVIL
C-Y-101
CIVIL SITE SHEET AREA G-01
C-Y-501
GENERAL - YARD & DRAINAGE DETAILS 1
MECHANICAL PROCESS
M-V-101
RESERVOIR METERING STRUCTURE PLAN & SECTIONS
ELECTRICAL
E-0-001
ELECTRICAL LEGEND
E-0-002
ELECTRICAL ABBREVIATIONS AND NOTES
E-0-501
ELECTRICAL GENERAL  DETAILS 1
E-0-601
SCHEDULE & ONE-LINE DIAGRAMS & SCHEMATICS
E-0-602
RTU AND PLC ONE-LINE DIAGRAM
E-Y-101
ELECTRICAL SITE PLAN
E-Y-601
DUCT BANK SCHEDULE & SECTIONS
INSTRUMENTATION
I-0-001
LEGEND & ABBREVIATIONS SHEET 1 OF 4
I-0-002
LEGEND & ABBREVIATIONS SHEET 2 OF 4
I-0-003
LEGEND & ABBREVIATIONS SHEET 3 OF 4
I-0-004
LEGEND & ABBREVIATIONS SHEET 4 OF 4
I-0-501
INSTRUMENTATION DETAILS 1
I-0-502
INSTRUMENTATION DETAILS 2
I-0-503
INSTRUMENTATION DETAILS 3
I-0-504
PHOENIX PLC SCHEMATIC
I-0-505
PHOENIX CONTROL PANEL & SOLAR SHIELD DETAILS
I-0-506
GLENDALE SERVICE WATER PLC CONTROL PANEL DETAILS
I-0-601
PHOENIX CONTROL BLOCK DIAGRAM
I-0-602
GLENDALE CONTROL BLOCK DIAGRAM
I-V-602
EXISTING FIRE WATER INTERCONNECTION
I-V-603
EXISTING RESERVOIR 1 & 2 & EFFLUENT FLOW METER
I-V-604
PHOENIX WATER INTERCONNECTION
KIVA: 004879
SDEV: 0002755
CPFL: 1808123
QS: 50-14
1
100% ISSUED FOR CONSTRUCTION
11/22

CITY OF GLENDALE
5850 WEST GLENDALE AVENUE
SUITE 315
GLENDALE, AZ 85301
MARTY SOMA
(623) 930-3630
VICINITY MAP
KEY MAP
NO SCALE
NO SCALE
WITHIN THE SOUTHWEST QUARTER OF THE SOUTHWEST QUARTER OF THE
SOUTHWEST QUARTER OF SECTION 21, T. 4 N., R. 2 E. OF GILA
AND SALT RIVER BASE AND MERIDIAN, MARICOPA COUNTY, ARIZONA
REGISTERED ENGINEER
REGISTRATION NUMBER
DATE
MICHAEL CARUSO
PROJECT MANAGER
2231 E CAMELBACK RD. #250
PHONE (602) 381-4400
I CERTIFY THAT THE LOCATIONS, ELEVATIONS, DEPTHS, AND RECORD DRAWING
COMMENTS ACCURATELY REFLECT THE EXISTING FIELD CONDITIONS AND
MATERIALS ACTUALLY USED DURING CONSTRUCTION. THIS CERTIFICATION IS
BASED ON PERIODIC FIELD OBSERVATIONS AND THE CONTRACTOR'S
REPRESENTATIONS OF THE FACILITIES AS CONSTRUCTED.
PINNACLE PEAK RD.
DEER VALLEY RD.
BEARDSLEY RD.
UNION HILLS RD.
BELLY RD.
GREENWAY RD.
THUNDERBIRD RD.
CATCUS RD.
PEORIA AVE.
OLIVA AVE.
NORTHERN AVE.
GLADEN AVE.
BETHANY HOME RD.
CAMELBACK RD.
115TH
107TH
99TH
91ST
83RD
75TH
67TH
59TH
51ST
43RD
51ST AVE.
43RD AVE.
DEER VALLEY RD.
BEARDSLEY RD.
MOHAWK LN.
TONOPAH DR.
PROJECT
SITE
ASSUMED S 00°42'30"E, PER ADOT RIGHT-OF-WAY MAP NO. D-7-T-796,
ALONG THE WEST LINE OF SECTION 21, TOWNSHIP 4 NORTH, RANGE 2 EAST,
OF THE GILA AND SALT RIVER BASE AND MERIDIAN, MARICOPA COUNTY,
ARIZONA, SAID LINE ALSO BEING THE MONUMENT LINE OF 51ST AVENUE.
THE PROJECT INCLUDES REVERSING THE FLOW THROUGH EXISTING PIPING FOR
EMERGENCY WATER SUPPLY FOR CITY OF GLENDALE'S DISTRIBUTION SYSTEM.
THE EXISTING BACKFLOW PREVENTER WILL BE REUSED, AND FLOW FROM CITY
OF PHOENIX WILL CONTINUE THROUGH AN 8" PIPELINE, FLOW METER AND FLOW
CONTROL VALVE FOR CITY OF GLENDALE'S USE.
8" DIP CLASS 350: 10 LF
AGGREGATE BASE COURSE: 10 CY
I HEREBY CERTIFY THAT THIS DESIGN IS BASED ON A SITE VISIT OR ACCURATE
FIELD DATA WHICH HAS BEEN CHECKED IN THE FIELD WITHIN 180 DAYS PRIOR TO
SUBMISSION FOR CITY APPROVAL.
BY:___________________________________ DATE:________________
THE CITY OF GLENDALE ACCEPTS THESE PLANS FOR CONSTRUCTION, AS BEING IN
GENERAL COMPLIANCE WITH PLANS FOR CONSTRUCTION, AS BEING IN GENERAL
COMPLIANCE WITH PLAN PREPARATION REQUIREMENTS OF THE CITY.
RESPONSIBILITY FOR THE COMPLETENESS AND ACCURACY OF THE PLANS AND
RELATED DESIGNS RESIDES WITH THE ENGINEER AND THE ENGINEERING FIRM OF
RECORD
CITY ENGINEER 
DATE
PURSUANT TO CHAPTER 32.5 OF THE GLENDALE CITY CODE, ALL
NEW AND EXISTING UTILITIES WITHIN OR CONTIGUOUS TO THIS SITE
SHALL BE PLACED UNDERGROUND IN CONDUIT.
RECORD DRAWING
QUANTITIES
GLENDALE INTERCONNECT WATER SUPPLY PIPELINE SCOPE
PLANS ACCEPTANCE
BASIS OF BEARINGS
PROJECT BENCHMARK
DATE
MCESD No.
MARICOPA COUNTY ENVIRONMENT SERVICES DEPARTMENT
(MCESD)
FD169535
COVER SHEET/ VICINITY MAP / SHEET LIST
G-0-051
CK
HVT
JMW
212238






1014
100% ISSUED FOR CONSTRUCTION



OF
SHT.




GLENDALE, ARIZONA 85301 (623) 930-3630
5850 W. GLENDALE AVE.
ENGINEERING DEPARTMENT
CITY OF GLENDALE




XREF 1:
XREF 2:
XREF 2:
XREF 1:
D412186
USER:
DRAWING VER.:





IF THIS BAR DOES NOT
MEASURE 1" THEN DRAWING IS
NOT TO FULL SCALE
1/2
0
1
GENERAL
G-0-051
COVER SHEET / VICINITY MAP / SHEET LIST
G-0-052
GENERAL NOTES AND LEGEND
G-0-053
ABBREVIATIONS
CIVIL
C-Y-151
CIVIL SITE SHEET AREA G-01
C-Y-551
GENERAL - YARD & DRAINAGE DETAILS 1
C-Y-552
GENERAL - YARD & DRAINAGE DETAILS 2
ELECTRICAL
E-0-051
ELECTRICAL LEGEND
E-0-052
ELECTRICAL ABBREVIATIONS AND NOTES
E-0-551
ELECTRICAL GENERAL  DETAILS
E-0-651
SCHEDULE & ONE-LINE DIAGRAMS & SCHEMATICS
E-0-652
RTU AND PLC'S ONE-LINE DIAGRAM
E-Y-151
ELECTRICAL SITE PLAN
E-Y-651
UNDERGROUND CONDUIT SCHEDULE & SECTIONS
INSTRUMENTATION
I-0-051
LEGEND & ABBREVIATIONS SHEET 1 OF 4
I-0-052
LEGEND & ABBREVIATIONS SHEET 2 OF 4
I-0-053
LEGEND & ABBREVIATIONS SHEET 3 OF 4
I-0-054
LEGEND & ABBREVIATIONS SHEET 4 OF 4
I-0-551
INSTRUMENTATION DETAILS 1
I-0-552
INSTRUMENTATION DETAILS 2
I-0-553
PHOENIX PLC SCHEMATIC
I-0-554
PHOENIX CONTROL PANEL & SOLAR SHIELD DETAILS
I-0-555
GLENDALE CONTROL PANEL DETAILS
I-0-651
PHOENIX CONTROL BLOCK DIAGRAM
I-0-652
GLENDALE CONTROL BLOCK DIAGRAM
I-J-651
PHOENIX WATER INTERCONNECTION
1
25


9/11/2024
DSC # 232457

City of Glendale 
Glendale Phoenix Interconnect
Pyramid & Pinnacle  
TECHNICAL SPECIFICATIONS 
DIVISIONS 01 – 48 
ISSUED FOR CONSTRUCTION 
December 2022 
City Project No. 212238 
B&V Project No. 412186 
Prepared by


&LW\RI*OHQGDOH$=
L
,668(')25&216758&7,21
*OHQGDOH3KRHQL[,QWHUFRQQHFW3\UDPLG	3LQQDFOH 
'HFHPEHU
%	93URMHFW1R


&LW\RI*OHQGDOH
*OHQGDOH3KRHQL[,QWHUFRQQHFW3\UDPLG	3LQQDFOH

'HFHPEHU

7KHVHFRQWUDFWGRFXPHQWVKDYHEHHQSUHSDUHGXQGHUWKHJHQHUDOVXSHUYLVLRQDQGGLUHFWLRQRIWKH
IROORZLQJSURIHVVLRQDOVOLFHQVHGLQWKH6WDWHRI$UL]RQD







0LNH&DUXVR±3URMHFW0DQDJHU



-XOLH:RRGZRUWK±(QJLQHHULQJ
0DQDJHU&LYLO

6KDZQ5RKU±,	&















3HUR9UFHOM±(OHFWULFDO










6WUXFWXUDO±1$













Table of Contents  
City of Glendale, AZ 
00 0110 - 1 
ISSUED FOR CONSTRUCTION 
Glendale Phoenix Interconnect Pyramid & Pinnacle  
December 2022 
B&V Project No. 412186 
 
 
SECTION 00 0110 
TABLE OF CONTENTS 
SECTIONS 
PAGES 
DIVISION 00 — PROCUREMENT AND CONTRACTING REQUIREMENTS 
NOT USED 
DIVISION 01 — GENERAL REQUIREMENTS 
01 1113 - Work Covered by Contract Documents  .......................................................... 7 
01 3200 - Construction Progress Documentation  ........................................................... 1 
01 3233 - Photographic Documentation  ......................................................................... 1 
01 3300 - Submittal Procedures  ..................................................................................... 7 
01 3300 F1 - F1 Submittal Identification and Contractor's Approval Statement  ............. 1 
01 4213 - Abbreviations and Acronyms  .......................................................................... 6 
01080 - Coordination with Owner's Operations ............................................................... 6 
01 4500 - Quality Control  ............................................................................................... 2 
01 5000 - Temporary Facilities and Controls  .................................................................. 6 
01 6100 - General Equipment Stipulations  ..................................................................... 4 
01 6500 - Product Delivery Requirements  ...................................................................... 1 
01 6600 - Product Storage and Handling Requirements  ................................................ 2 
01 6700.3 - Meteorological and Seismic Design Criteria (IBC 2018) .............................. 5 
01 6800 - Equipment and Valve Identification  ................................................................ 3 
01 7319 - Equipment Installation  .................................................................................... 3 
01 7700 - Closeout Procedures  ...................................................................................... 5 
01 7900 - Demonstration and Training  ........................................................................... 3 
DIVISION 02 — EXISTING CONDITIONS 
NOT USED 
DIVISION 03 — CONCRETE 
NOT USED 
DIVISION 04 — MASONRY 
NOT USED 
DIVISION 05 — METALS 
05 8100 - Anchorage in Concrete and Masonry  ............................................................. 7 
DIVISION 06 — WOOD, PLASTICS, AND COMPOSITES 
NOT USED 
DIVISION 07 — THERMAL AND MOISTURE PROTECTION 
NOT USED 
DIVISION 08 — OPENINGS 
NOT USED 
DIVISION 09 — FINISHES 
09 9611 - Protective Coatings  ...................................................................................... 14

Table of Contents  
City of Glendale, AZ 
00 0110 - 2 
ISSUED FOR CONSTRUCTION 
Glendale Phoenix Interconnect Pyramid & Pinnacle  
December 2022 
B&V Project No. 412186 
 
 
DIVISION 10 — SPECIALTIES 
NOT USED 
DIVISION 11 — EQUIPMENT 
NOT USED 
DIVISION 12 — FURNISHINGS 
NOT USED 
DIVISION 13 — SPECIAL CONSTRUCTION 
NOT USED 
DIVISION 14 — CONVEYING EQUIPMENT 
NOT USED 
DIVISION 21 — FIRE SUPPRESSION 
NOT USED 
DIVISION 22 — PLUMBING 
NOT USED 
DIVISION 23 — HEATING VENTILATING AND AIR CONDITIONING 
NOT USED 
DIVISION 25 — INTEGRATED AUTOMATION 
NOT USED 
DIVISION 26 — ELECTRICAL 
26 0511 - Electrical ....................................................................................................... 19 
DIVISION 27 — COMMUNICATIONS 
NOT USED 
DIVISION 28 — ELECTRONIC SAFETY AND SECURITY 
NOT USED 
DIVISION 31 — EARTHWORK 
31 2333 - Trenching and Backfilling  ............................................................................. 10 
31 2333 F1 - Temporary Excavation Design Certificate - 1  ............................................ 1 
DIVISION 32 — EXTERIOR IMPROVEMENTS 
NOT USED 
DIVISION 33 — UTILITIES 
33 0514 - Manhole and Vault Covers and Accessories  .................................................. 2 
33 1313 - Cleaning and Disinfection of Water Pipelines  ................................................. 4 
33 1400 - Pipeline Pressure and Leakage Testing  ......................................................... 5 
DIVISION 34 — TRANSPORTATION 
NOT USED 
DIVISION 35 — WATERWAY AND MARINE 
NOT USED 
DIVISION 40 — PROCESS INTERCONNECTIONS 
NOT USED

Table of Contents  
City of Glendale, AZ 
00 0110 - 3 
ISSUED FOR CONSTRUCTION 
Glendale Phoenix Interconnect Pyramid & Pinnacle  
December 2022 
B&V Project No. 412186 
 
 
DIVISION 40 — PROCESS INTEGRATION 
40 0505.11 - Miscellaneous Piping and Accessories Installation  ................................... 5 
40 0517.13 - Pipe Supports  ............................................................................................ 6 
40 0517.13 F1A - Hangers and Supports (A)  ................................................................. 1 
40 0517.13 F1B - Hangers and Supports (B)  ................................................................. 1 
40 0519 - Ductile Iron Pipe  ........................................................................................... 17 
40 0551.13 - Valve Installation  ....................................................................................... 3 
40 0557 - Valve and Gate Actuators  .............................................................................. 9 
40 0561.23 - Resilient Seated Gate Valves  .................................................................... 5 
40 0564.11 - AWWA Butterfly Valves  ............................................................................. 7 
15099A - Pilot-Controlled Globe Valves .......................................................................... 4 
40 0586 - Air Valves  ....................................................................................................... 3 
40 6111 - Instrumentation and Control System  ............................................................ 14 
40 6111A - City of Glendale Instrument Device Schedule ............................................... 1 
40 6400 - PLCs - Software and Programming ................................................................. 4 
40 6400A - City of Glendale Input / Output List ............................................................... 1 
40 6711 - Panels, Consoles, and Appurtenances ........................................................... 6 
40 6883 - Software Control Block Descriptions  .............................................................. 8 
40 7100 - Flow Instruments ............................................................................................. 4 
40 7200 - Pressure Instruments ...................................................................................... 4 
40 7800 - Panel Mounted Instruments  ........................................................................... 4 
17226 - Process Control System I O List ........................................................................ 1 
17226A - City of Phoenix Input / Output List ................................................................... 1 
17240 - Radio and Antenna Cable Installation and Testing ............................................ 5 
17260 - Control Panels .................................................................................................. 27 
17262 - PLCs - Software and Programming .................................................................. 11 
17340 - Monopole Antenna Towers ................................................................................ 4 
DIVISION 41 — MATERIAL PROCESSING AND HANDLING EQUIPMENT 
NOT USED 
DIVISION 42 — PROCESS HEATING, COOLING, AND DRYING EQUIPMENT 
NOT USED 
DIVISION 43 — PROCESS GAS AND LIQUID HANDLING, PURIFICATION AND 
STORAGE EQUIPMENT 
NOT USED 
DIVISION 44 — POLLUTION AND WASTE CONTROL EQUIPMENT 
NOT USED 
DIVISION 45 — INDUSTRY-SPECIFIC MANUFACTURING EQUIPMENT 
NOT USED 
DIVISION 46 — WATER AND WASTEWATER EQUIPMENT 
NOT USED 
DIVISION 48 — ELECTRICAL POWER GENERATION 
NOT USED

City of Glendale 
 
 
 
Glendale Phoenix Interconnects 
 
 
TECHNICAL SPECIFICATIONS 
 
DIVISIONS 01 – 48 
 
51st & Tonopah 
100% ISSUED FOR CONSTRUCTION  
 
 
 
September 2024 
 
 
City Project No. 212238 
B&V Project No. 419344 
 
 
 
 
Prepared by

City of Glendale, AZ 
i 
B&V Project No. 419344 
Glendale Phoenix Interconnects 
100% ISSUED FOR CONSTRUCTION 
September 2024
City of Glendale 
Glendale Phoenix Interconnects 
51st & Tonopah 
September 2024 
These contract documents have been prepared under the general supervision and direction of the 
following professionals, licensed in the State of Arizona. 
Mike Caruso – Project Manager
Julie Woodworth – Engineering 
Manager/Civil/Mechanical 
Pero VUcelj – Electrical/I&C 
09/11/24
/2024
9/11
9/11/2024

Table of Contents 
City of Glendale, AZ 
00 0110 - 1 
B&V Project No. 419344  
Glendale Phoenix Interconnect 51st & Tonopah 
 
100% ISSUED FOR CONSTRUCTION 
 
 
September 2024 
SECTION 00 0110 
TABLE OF CONTENTS 
SECTIONS 
PAGES 
DIVISION 00 — PROCUREMENT AND CONTRACTING REQUIREMENTS 
NOT USED 
DIVISION 01 — GENERAL REQUIREMENTS 
01 1113 - Work Covered by Contract Documents  .......................................................... 7 
01 3200 - Construction Progress Documentation  ........................................................... 1 
01 3233 - Photographic Documentation  ......................................................................... 1 
01 3300 - Submittal Procedures  ..................................................................................... 6 
01 3300 - F1 Submittal Identification and Contractor's Approval Statement  .................. 1 
01 3300 - F2 Submittal Identification and Contractor's Approval Statement ................... 1 
01 4213 - Abbreviations and Acronyms  .......................................................................... 6 
01080 - Coordination with Owner's Operations  .............................................................. 5 
01 4500 - Quality Control  ............................................................................................... 2 
01 5000 - Temporary Facilities and Controls  .................................................................. 5 
01 6100 - General Equipment Stipulations  ..................................................................... 4 
01 6500 - Product Delivery Requirements  ...................................................................... 1 
01 6600 - Product Storage and Handling Requirements  ................................................ 2 
01 6700.2 - Meteorological and Seismic Design Criteria (IBC 2018)  ............................. 5 
01 6800 - Equipment and Valve Identification  ................................................................ 3 
01 7319 - Equipment Installation  .................................................................................... 3 
01 7700 - Closeout Procedures  ...................................................................................... 4 
01 7900 - Demonstration and Training  ........................................................................... 3 
DIVISION 02 — EXISTING CONDITIONS 
NOT USED 
DIVISION 03 — CONCRETE 
NOT USED 
DIVISION 04 — MASONRY 
NOT USED 
DIVISION 05 — METALS 
05 8100 - Anchorage in Concrete and Masonry .............................................................. 6  
DIVISION 06 — WOOD, PLASTICS, AND COMPOSITES 
NOT USED 
DIVISION 07 — THERMAL AND MOISTURE PROTECTION 
NOT USED 
DIVISION 08 — OPENINGS 
NOT USED 
DIVISION 09 — FINISHES 
09 9611 - Protective Coatings ....................................................................................... 14

Table of Contents 
City of Glendale, AZ 
00 0110 - 2 
B&V Project No. 419344  
Glendale Phoenix Interconnect 51st & Tonopah 
 
100% ISSUED FOR CONSTRUCTION 
 
 
September 2024 
DIVISION 10 — SPECIALTIES 
NOT USED 
DIVISION 11 — EQUIPMENT 
NOT USED 
DIVISION 12 — FURNISHINGS 
NOT USED 
DIVISION 13 — SPECIAL CONSTRUCTION 
NOT USED 
DIVISION 14 — CONVEYING EQUIPMENT 
NOT USED 
DIVISION 21 — FIRE SUPPRESSION 
NOT USED 
DIVISION 22 — PLUMBING 
NOT USED 
DIVISION 23 — HEATING VENTILATING AND AIR CONDITIONING 
NOT USED 
DIVISION 25 — INTEGRATED AUTOMATION 
NOT USED 
DIVISION 26 — ELECTRICAL 
26 0511 - Electrical ....................................................................................................... 18 
DIVISION 27 — COMMUNICATIONS 
NOT USED 
DIVISION 28 — ELECTRONIC SAFETY AND SECURITY 
NOT USED 
DIVISION 31 — EARTHWORK 
31 2333 - Trenching and Backfilling  ............................................................................. 10 
31 2333-F1 - Embedments for Conduits   ....................................................................... 1 
31 2333-F2 - Temporary Excavation Design Certificate   ................................................ 1 
DIVISION 32 — EXTERIOR IMPROVEMENTS 
NOT USED 
DIVISION 33 — UTILITIES 
33 1313 - Cleaning and Disinfection of Water Pipelines  ................................................. 4 
33 1400 - Pipeline Pressure and Leakage Testing  ......................................................... 5 
DIVISION 34 — TRANSPORTATION 
NOT USED 
DIVISION 35 — WATERWAY AND MARINE 
NOT USED

Table of Contents 
City of Glendale, AZ 
00 0110 - 3 
B&V Project No. 419344  
Glendale Phoenix Interconnect 51st & Tonopah 
 
100% ISSUED FOR CONSTRUCTION 
 
 
September 2024 
DIVISION 40 — PROCESS INTERCONNECTIONS 
40 0505.11 - Miscellaneous Piping and Accessories Installation  ................................... 5 
40 0517.13 - Pipe Supports  ............................................................................................ 6 
40 0517.13 F1A - Hangers and Supports (A)  ................................................................. 1 
40 0517.13 F1B - Hangers and Supports (B)  ................................................................. 1 
40 0519 - Ductile Iron Pipe  ........................................................................................... 17 
40 0551.13 - Valve Installation  ....................................................................................... 3 
40 0557 - Valve and Gate Actuators  .............................................................................. 6 
40 0564.11 - AWWA Butterfly Valves  ............................................................................. 7 
40 0586 - Air Valves  ....................................................................................................... 5 
40 6111 - Instrumentation and Control System  ............................................................ 14 
40 6111A - City of Glendale Instrument Device Schedule ............................................... 1 
40 6400 - Programmable Logic Controllers  .................................................................... 4 
40 6400A - City of Glendale Input / Output List ............................................................... 1 
40 6711 - Panels, Consoles, and Appurtenances  .......................................................... 8 
40 6883 - Software Control Block Descriptions  .............................................................. 8 
40 7100 - Flow Instruments  ............................................................................................ 4 
40 7200 - Pressure Instruments  ..................................................................................... 4 
40 7800 - Panel Mounted Instruments  ........................................................................... 3 
17226 - Process Control System I O List ........................................................................ 1 
17226A - City of Phoenix Input / Output List ................................................................... 1 
17240 - Radio and Antenna Cable Installation ................................................................ 5 
17260 - Control Panels .................................................................................................. 27 
17262 - PLCs - Software and Programming .................................................................. 10 
17340 - Monopole Antenna Towers ................................................................................ 4 
DIVISION 40 — PROCESS INTEGRATION 
DIVISION 41 — MATERIAL PROCESSING AND HANDLING EQUIPMENT 
NOT USED 
DIVISION 42 — PROCESS HEATING, COOLING, AND DRYING EQUIPMENT 
NOT USED 
DIVISION 43 — PROCESS GAS AND LIQUID HANDLING, PURIFICATION AND 
STORAGE EQUIPMENT 
NOT USED 
DIVISION 44 — POLLUTION AND WASTE CONTROL EQUIPMENT 
NOT USED 
DIVISION 45 — INDUSTRY-SPECIFIC MANUFACTURING EQUIPMENT 
NOT USED 
DIVISION 46 — WATER AND WASTEWATER EQUIPMENT 
NOT USED 
DIVISION 48 — ELECTRICAL POWER GENERATION 
NOT USED

City of Glendale Standard Form Agreement Between Owner and CM@Risk (January 28, 2025) 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
T H I S P A G E I S B L A N K

City of Glendale Standard Form Agreement Between Owner and CM@Risk (January 28, 2025) 
 
 
EXHIBIT F 
Statement of All Clarifications and Assumptions (if any) 
 
(3 pages - To be Incorporated by Amendment) 
 
See attached

ŜŜŪıŕťĖĺIJŜϠϙIIJèīŪîĖIJČϙ"ĖŘôèťϙĺŜťϙīÍŘĖċĖèÍťĖĺIJŜ
@ôIJôŘÍīϡϙ͐
ϟ
[ÍæĺŘϙēÍŜϙæôôIJϙĖIJèīŪîôîϙÍèèĺŘîĖIJČϙťĺϙŕŘôŽÍĖīĖIJČϙſÍČôϙŘÍťôŜϙÍŕŕīĖèÍæīôϙÍťϙťēôϙťĖıôϙĺċϙťēô
ôŜťĖıÍťôϟ͑
ϟ
„ŘĖèĖIJČϙÍŜŜŪıôŜϙťēÍťϙťēôϙĺſIJôŘϙſĖīīϙŕŘĺŽĖîôϙÍīīϙÍèèôŜŜϙÍIJîϙôÍŜôıôIJťŜϙÍŜϙŘôŗŪĖŘôîϙťĺ
èĺıŕīôťôϙťēôϙſĺŘħϟ͒
ϟ
„ŘĖèĖIJČϙĖŜϙæÍŜôîϙĺIJϙťēôϙèŪŘŘôIJťϙîĺèŪıôIJťŜϙŕŘĺŽĖîôîϙæƅϙťēôϙ(IJČĖIJôôŘϠϙſēĖèēϙŘôŕŘôŜôIJťϙťēô
ŕŘĺĤôèťДŜϙŕŘĺČŘôŜŜϙťĺϙîÍťôϟ͓
ϟ
a@ϙĺIJťŘÍèťĺŘŜϙôƄèīŪîôŜϙŘôıĺŽÍīϙÍIJîϙēÍIJîīĖIJČϙĺċϙēÍƏÍŘîĺŪŜϙıÍťôŘĖÍīŜϟϙϙ“ēôϙiſIJôŘϙſĖīī
æôϙèĺIJŜĖîôŘôîϙťēôϙČôIJôŘÍťĺŘϙċĺŘϙÍIJƅϙŕŘôϱôƄĖŜťĖIJČϙēÍƏÍŘîĺŪŜϙèĺIJîĖťĖĺIJϙôIJèĺŪIJťôŘôîϙîŪŘĖIJČ
ťēôϙſĺŘħϟ͔
ϟ
„ôŘıĖťŜϙĺťēôŘϙťēÍIJϙîŪŜťϙèĺIJťŘĺīϙÍIJîϙ‹®„„„ϙēÍŽôϙæôôIJϙôƄèīŪîôîϟϙ“ēôϙôIJČĖIJôôŘϙſĖīī
ĖIJèĺŘŕĺŘÍťôϙŕôŘıĖťϙŘôŗŪĖŘôıôIJťŜϙťēÍťϙèĺIJċīĖèťϙſĖťēϙĺŘϙèĺıŕīôıôIJťϙťēôϙťôèēIJĖèÍīϙîŘÍſĖIJČŜ
ÍIJîϙŜŕôèĖċĖèÍťĖĺIJŜϙĖIJťĺϙťēôϙċĖIJÍīϙîôŜĖČIJϙîĺèŪıôIJťŜϠϙÍIJîϙÍŕŕŘĺŕŘĖÍťôϙèĺŜťϙÍîĤŪŜťıôIJťŜϙſĖīī
æôϙŕŘĺŽĖîôîϙťĺϙa@ϙĺIJťŘÍèťĺŘŜϟ
@ôIJôŘÍīϙĺIJîĖťĖĺIJŜϙЭϙ@ôIJôŘÍīϙ‡ôŗŪĖŘôıôIJťŜϡϙ͐
ϟ
bĺϙèēôıĖèÍīϙèĺŜťϙĖŜϙŘôŗŪĖŘôîϙċĺŘϙŜťÍŘťŪŕϯťôŜťĖIJČϙċĺŘϙťēĖŜϙŕŘĺĤôèťϟ͑
ϟ
"ôŽôīĺŕıôIJťϙÍIJîϙĖıŕÍèťϙċôôŜϙċŘĺıϙťēôϙŕĺſôŘϙŪťĖīĖťƅϙÍŘôϙIJĺťϙôƄŕôèťôîϙċĺŘϙťēĖŜϙŕŘĺĤôèťϟ
îîĖťĖĺIJÍīīƅϠϙťēôϙĺſIJôŘϙĖŜϙÍŜŜŪıôîϙťĺϙŕÍƅϙċĺŘϙŕôŘıÍIJôIJťϙŕĺſôŘϙèĺIJŜŪıŕťĖĺIJϙèĺŜťŜϙċĺŘ
ŜťÍŘťŪŕϠϙťôŜťĖIJČϠϙÍIJîϙèĺııĖŜŜĖĺIJĖIJČϙċŘĺıϙťēôϙôīôèťŘĖèϙŪťĖīĖťƅϟ͒
ϟ
ĺIJŜťŘŪèťĖĺIJϙſÍťôŘϙēÍŜϙæôôIJϙÍŜŜŪıôîϙťĺϙæôϙÍŽÍĖīÍæīôϙĺIJŜĖťôϙÍIJîϙŕŘĺŽĖîôîϙæƅϙi@
ċĺīīĺſĖIJČϙťēôϙôŜťÍæīĖŜēôîϙŕŘĺèôîŪŘôŜϟϙ“ēĖŜϙÍîîôîϙèĺŜťϙĖŜϙĖIJèīŪîôîϙĖIJϙťēôϙ@a„ϟ
‹ĖťôſĺŘħϯ´ÍŘîϙ„ĖŕĖIJČϡϙ͐
ϟ
īīϙŜĖťôſĺŘħϯƅÍŘîϙŕĖŕĖIJČϙĖŜϙĖIJèīŪîôîϙĖIJϙťēĖŜϙ@a„ϟϙîîĖťĖĺIJÍīīƅϠϙa@ϙſĖīīϙæôϙŘôŜŕĺIJŜĖæīôϙċĺŘ
ŜťĺŘĖIJČϙÍīīϙŕŘĺĤôèťϱŘôīÍťôîϙıÍťôŘĖÍīŜϙîŪŘĖIJČϙťēôϙŕŘĺĤôèťДŜϙèĺIJŜťŘŪèťĖĺIJϙŕēÍŜôϟ͑
ϟ
a@ϙÍŜŜŪıôŜϙťēÍťϙÍīīϙôƄèôŜŜϙŜŕĺĖīŜϙèÍIJϙæôϙŜťĺèħŕĖīôîϙĺIJŜĖťôϟ
ĺIJèŘôťôϡϙ͐
ϟ
IJƅϙèĺIJèŘôťôϙŘôŗŪĖŘôıôIJťŜϙÍŘôϙĖIJèīŪîôîϙĖIJϙťēôϙ@a„ϙÍIJîϙſĖīīϙæôϙŜŪæıĖťťôîϙċĺŘϙÍŕŕŘĺŽÍīϟ
(ŗŪĖŕıôIJťϡϙ͐
ϟ
„ŘĺèôŜŜϙôŗŪĖŕıôIJťϙèĺŜťϙĖŜϙæÍŜôîϙŪŕĺIJϙťēôϙ"ôŜĖČIJϙ„īÍIJŜϠϙŕŘĺŕĺŜÍīŜϠϙÍŜŜŪıŕťĖĺIJŜϠϙÍIJî
ŜŕôèĖċĖèÍťĖĺIJŜϙıÍîôϙæƅϙťēôϙôŗŪĖŕıôIJťϙıÍIJŪċÍèťŪŘôŘŜϙÍIJîϙŕŘĺŽĖîôîϙċĺŘϙťēôϙîôŽôīĺŕıôIJťϙĺċ
ťēôϙ@a„ϟϙ„īôÍŜôϙŜôôϙťēôϙŜŪæıĖťťÍīŜϙċĺŘϙÍîîĖťĖĺIJÍīϙĖIJċĺŘıÍťĖĺIJϟ
aôèēÍIJĖèÍīϙ͐
ϟ
IJƅϙıôèēÍIJĖèÍīϙŘôŗŪĖŘôıôIJťŜϙÍŘôϙĖIJèīŪîôîϙĖIJϙťēôϙ@a„ϟϙ„īôÍŜôϙŜôôϙťēôϙŜèēôîŪīôϙċĺŘϙıĺŘô
îôťÍĖīŜϟ

(īôèťŘĖèÍīϙ͐
ϟ IJƅϙôīôèťŘĖèÍīϙŘôŗŪĖŘôıôIJťŜϙÍŘôϙĖIJèīŪîôîϙĖIJϙťēôϙ@a„ϠϙÍIJîϙÍīīϙôīôèťŘĖèÍīϙèĺıŕĺIJôIJťŜϙſĖīīϙæôϙ
ŜŪæıĖťťôîϙċĺŘϙÍŕŕŘĺŽÍīϟϙ
îîϱiIJŜϙϙ
a@ϙĺIJťŘÍèťĺŘŜϙîĺôŜϙIJĺťϙĖIJèīŪîôϙÍIJƅϙÍîîϱĺIJŜϙĺťēôŘϙťēÍIJϙſēÍťϙēÍŜϙæôôIJϙIJĺťôîϙÍæĺŽôϟϙ
(ƄèīŪŜĖĺIJŜϙ
(ƄèīŪîôîϙĖťôıŜϙēÍŽôϙæôôIJϙĖîôIJťĖċĖôîϙſĖťēĖIJϙťēôϙŜèĺŕôϙĺċϙſĺŘħϙèīÍŘĖċĖèÍťĖĺIJŜϙÍIJîϙÍŜŜŪıŕťĖĺIJŜϙÍIJîϙĖIJϙ
ťēôϙiſIJôŘϙĺŜťŜϙŜôèťĖĺIJϙÍæĺŽôϟϙ
‡ĖŜħŜϙÍIJîϙiŕŕĺŘťŪIJĖťĖôŜϙϙ
•
“ŘÍċċĖèϙ„īÍIJϙèĺĺŘîĖIJÍťĖĺIJϙſĖīīϙæôϙŘôŗŪĖŘôîϙϙ
•
“ēôϙ"i“Ŝϙϙ͐͏͐
ϙŕŘĺĤôèťϙŜèēôîŪīôϙèĺŪīîϙĖıŕÍèťϙťēôϙĖIJťôŘèĺIJIJôèťϙŕŘĺĤôèťϟϙ®ĺŘħĖIJČϙèīĺŜôīƅϙ
ſĖťēϙťēôıϙſĖīīϙæôϙÍIJϙĺŕŕĺŘťŪIJĖťƅϙťĺϙċĺŜťôŘϙÍϙŽÍīŪôîϙŕÍŘťIJôŘŜēĖŕϟϙϙϙ
•
bĺϙŜĺĖīϙŘôŕĺŘťŜϙēÍŽôϙæôôIJϙŕŘĺŽĖîôîϙċĺŘϙťēôϙIJôſϙĖIJťôŘèĺIJIJôèťϙÍīĖČIJıôIJťϟϙa@ϙÍŜŜŪıôŜϙťēĖŜϙ
ťĺϙæôϙēÍŘîϱîĖČϙèĺIJîĖťĖĺIJŜϙÍIJîϙĖIJèīŪîôŜϙÍIJϙÍīīĺſÍIJèôϙċĺŘϙťēĖŜϙſĺŘħϟϙϙîîĖťĖĺIJÍīϙŜĺĖīϙŜÍıŕīĖIJČϙ
ÍIJîϙťôŜťϙîĖČŜϙèÍIJϙŕŘĺŽĖîôϙÍIJϙĺŕŕĺŘťŪIJĖťƅϙťĺϙŜĺīĖîĖċƅϙťēĖŜϙèĺŜťϟϙ
ĺIJťĖIJČôIJèĖôŜϙ
•
a‡ϙ ĺIJťĖIJČôIJèƅϡϙ ϙ a‡ϙ èĺIJťĖIJČôIJèƅϙ ĺċϙ щ͔͏
Ϡ͏͏͏
ϙ ēÍŜϙ æôôIJϙ Íîîôîϙ ťĺϙ ťēôϙ ÍīīĺſÍIJèôϙ
æŘôÍħîĺſIJϟϙϙϙϙ
•
"ôŜĖČIJϙĺIJťĖIJČôIJèƅϡϙbĺϙ"ôŜĖČIJϙĺIJťĖIJČôIJèƅϙēÍŜϙæôôIJϙÍîîôîϙťĺϙťēĖŜϙ@a„ϟϙ
•
a‡ϙ>ôôϡϙϙ>ĖƄôîϙċôôϙĺċϙ͗ ϟ͔͏҇
ϙēÍŜϙæôôIJϙĖIJèīŪîôîϙĺIJϙťēôϙťĺťÍīϙèĺIJťŘÍèťϙÍıĺŪIJťϟϙϙϙ
a‡ϙIIJŜŪŘÍIJèôŜϡϙ
•
‹ŪæèĺIJťŘÍèťĺŘϟ ĺIJîĖIJČϡϙ ‹ŪæèĺIJťŘÍèťĺŘϙ æĺIJîŜϙ ÍŘôϙ IJĺťϙ ĖIJèīŪîôîϙ ĖIJϙ ťēĖŜϙ @a„ϟϙ ‹ēĺŪīîϙ Íϙ
‹ŪæèĺIJťŘÍèťĺŘϙ îôċÍŪīťϙ ĺŘϙ ċÍĖīϙ ťĺϙ ıôôťϙ ŕôŘċĺŘıÍIJèôϙ ŘôŗŪĖŘôıôIJťŜϠϙ a@ϙ ſĖīīϙ ŜŪæıĖťϙ Íϙ
èĺIJťĖIJČôIJèƅϙŪŜôϙÍŪťēĺŘĖƏÍťĖĺIJϟϙ
•
@ôIJôŘÍīϙ[ĖÍæĖīĖťƅϡϙIIJèīŪîôîϙťĺϙÍèèĺŪIJťϙċĺŘϙıĖIJĖıŪıϙèĺŽôŘÍČôϙŘôŗŪĖŘôîϙæƅϙťēôϙ„ŘĖıôϙ
ČŘôôıôIJťϟϟ
(ŜťĖıÍťôϙ†ŪÍīĖťƅϙŜŜŪŘÍIJèôϙ
•
ϙèĺıŕīôťôϙôŜťĖıÍťôϙŘôŽĖôſϙſÍŜϙèĺIJîŪèťôîϙťēôϙſôôħϙĺċϙVÍIJŪÍŘƅϙ͐͏
ťēϠϙ͑͏͔͑
ϟϙϙ
•
ϙċĖIJÍīϙôŜťĖıÍťôϙŘôŽĖôſϙſÍŜϙèĺIJîŪèťôîϙĺIJϙVÍIJŪÍŘƅϙ͖͐
ťēϠϙ͑͏͔͑
ϟϙϙ
•
IJϙôƄôèŪťĖŽôϙôŜťĖıÍťôϙŘôŽĖôſϙſÍŜϙèĺIJîŪèťôîϙĺIJϙVÍIJŪÍŘƅϙ͓͑
ťēϠϙ͑͏͔͑
ϟϙ
(ŜťĖıÍťĖIJČϙ“ôÍıϙ
bÍıôϙ
“Ėťīôϙ
„ēĖīϙ[īĺƅîϙ
„ŘĺĤôèťϙ(ŜťĖıÍťĺŘϙ
‹èĺťťϙ®ēĖťīôƅϙ
‹Řϟϙ„ŘĺĤôèťϙaÍIJÍČôŘϙ
ŪæŘôƅϙ‡ĺŪıĺϙϙ
@ôIJôŘÍīϙaÍIJÍČôŘϙ

@ŘôČϙôôťôıϙ
(ƄôèŪťĖŽôϙ«Ėèôϙ„ŘôŜĖîôIJťϙ
ϙ
ĺIJŜťŘŪèťĖĺIJϙaÍIJÍČôıôIJťϙ
ĺIJŜťŘŪèťĖĺIJϙıÍIJÍČôıôIJťϙŜŪŕôŘŽĖŜĖĺIJϙŜťÍċċϙĖŜϙæÍŜôîϙĺIJϙťēôϙŕŘĺŕĺŜôîϙŜèĺŕôϙĺċϙſĺŘħϙÍIJîϙ
ÍIJťĖèĖŕÍťôîϙèĺIJŜťŘŪèťĖĺIJϙŜèēôîŪīôϟϙϙĺŜťŜϙċĺŘϙÍîıĖIJĖŜťŘÍťĖĺIJϠϙČôIJôŘÍīϙèĺIJîĖťĖĺIJŜϠϙČôIJôŘÍīϙ
ŘôŗŪĖŘôıôIJťŜϠϙŗŪÍīĖťƅϙèĺIJťŘĺīϠϙťôıŕĺŘÍŘƅϙċÍèĖīĖťĖôŜϠϙŜÍċôťƅϠϙŜťÍŘťŪŕϠϙÍIJîϙèĺııĖŜŜĖĺIJĖIJČϙēÍŽôϙæôôIJϙ
ĖIJèīŪîôîϙċĺŘϙťēĖŜϙŕôŘĖĺîϟϙϙ‡ôċôŘϙťĺϙťēôϙČôIJôŘÍīϙèĺIJîĖťĖĺIJŜϙŜôèťĖĺIJϙĺċϙťēĖŜϙ@a„ϙċĺŘϙÍîîĖťĖĺIJÍīϙ
ĖIJċĺŘıÍťĖĺIJϙÍIJîϙîôťÍĖīŜϙĺIJϙťēôϙèĺIJŜťŘŪèťĖĺIJϙıÍIJÍČôıôIJťϙċĖôīîϙŜťÍċċϟϙ
iſIJôŘŜϙĺŜťŜϙ
“ēĖŜϙôŜťĖıÍťôϙîĺôŜϙIJĺťϙĖIJèīŪîôϙÍIJƅϙèĺŜťϙċĺŘϙťēôϙċĺīīĺſĖIJČϠϙſēĖèēϙÍŘôϙÍŜŜŪıôîϙťĺϙæôϙŕŘĺŽĖîôîϙæƅϙťēôϙ
iſIJôŘϟϙ
•
"ôŜĖČIJϙ‹ôŘŽĖèôŜϙЭϙ(IJČĖIJôôŘĖIJČϙ
•
‹ŕôèĖÍīϙIIJŜŕôèťĖĺIJŜϙſĖīīϙŘôŗŪĖŘôϙÍīīĺſÍIJèôϙŪŜôϙÍŕŕŘĺŽÍīϟϙ“ēĖŜϙĖŜϙIJĺťϙĖIJèīŪîôîϙĖIJϙťēôϙĺŽôŘÍīīϙ
@a„ϙèĺŜťϙÍIJîϙĖŜϙIJĺťϙôƄŕôèťôîϙċĺŘϙťēĖŜϙŕŘĺĤôèťϟϙϙ
•
„ôŘıĖťŜϙĺťēôŘϙťēÍIJϙťŘÍċċĖèϙϼi„ϽϠϙîŪŜťϙèĺIJťŘĺīϠϙÍIJîϙ‹®„„„ϙÍŘôϙIJĺťϙĖIJèīŪîôîϙĖIJϙťēĖŜϙ@a„ϟϙϙ

City of Glendale Standard Form Agreement Between Owner and CM@Risk (January 28, 2025) 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
T H I S P A G E I S B L A N K

City of Glendale Standard Form Agreement Between Owner and CM@Risk (January 28, 2025) 
 
 
EXHIBIT G 
Schedule of Major Milestones 
 
(3 pages - To be Incorporated by Amendment) 
 
See attached

Activity ID
Activity Name
OD
RD Start
Finish
Total
Float
Longest
Path
City of Glen
City of Glendale Interconnect
City of Glendale Interconnect
City of Glendale Interconnect
City of Glendale Interconnect
City of Glendale Interconnect
City of Glendale Interconnect
City of Glendale Interconnect
Project Mi
Project Milestones
Project Milestones
Project Milestones
Project Milestones
Project Milestones
Project Milestones
Project Milestones
A1000
Notice to Proceed
0
0
04-21-2
0
A1010
Substantial Completion
0
0
09-18-25
0
A1022
Demobilize
3
3 09-19-25
09-23-25
0
A1020
Final Completion
0
0
09-23-25
0
Submittals
Submittals
Submittals
Submittals
Submittals
Submittals
Submittals
Submittals
S101
Prepare and Transmit Misc. Submittals
1
1 04-21-25
04-21-25
50
S105
Prepare & Submit Electrical Gear
5
5 04-21-25
04-25-25
0
S103
Prepare & Submit Manifold Flow Meter
5
5 04-21-25
04-25-25
44
S104
Prepare & Submit Fire Flow Meter
5
5 04-21-25
04-25-25
56
S106
Submital Review by Client
8
8 04-22-25
05-01-25
50
S110
Review and Approve Radio Study
10
10 04-21-25
05-02-25
25
S108
Submitals / Drawings Approved
0
0
05-02-25
50
S107
Review & Approve Electrical Gear
10
10 04-28-25
05-09-25
0
Fab and D
Fab and Deliver
Fab and Deliver
Fab and Deliver
Fab and Deliver
Fab and Deliver
Fab and Deliver
Fab and Deliver
F108
Fab & Deliver Radio Mast
20
20 05-05-25
06-02-25
25
F110
Fab & Deliver Manifold Flow Meter
40
40 04-28-25
06-23-25
44
F106
Fab & Deliver Fire Flow Meter
40
40 04-28-25
06-23-25
56
F112
Fab & Deliver Electrical Gear
80
80 05-12-25
09-03-25
0
Construct
Construction Phase Pyramid Peak
Construction Phase Pyramid Peak
Construction Phase Pyramid Peak
Construction Phase Pyramid Peak
Construction Phase Pyramid Peak
Construction Phase Pyramid Peak
Construction Phase Pyramid Peak
Civil
Civil
Civil
Civil
Civil
Civil
Civil
Civil
G203
Mobilize to Site
3
3 06-10-25
06-12-25
25
G204
Pothole Utilities Pyramid Peak Pkwy Tie In
2
2 06-11-25
06-12-25
25
G205
Excavate and Shore Tie in Location
2
2 06-12-25
06-13-25
25
G208
Excavate 12" Line to Masonry Wall
3
3 06-23-25
06-25-25
25
G209
Place Slurry at Masonry Wall
1
1 06-26-25
06-26-25
25
G102
Demo Channel
1
1 06-27-25
06-27-25
25
G103
Excavate 12" Line to Metering Piping
5
5 06-30-25
07-07-25
25
r
May
Jun
Jul
Aug
Sep
Oct
2025
Finish On or After, 03-03-25, , Notice to Proceed
Substantial Com
Demobilize
Final Complet
Prepare and Transmit Misc. Submittals
Prepare & Submit Electrical Gear
Prepare & Submit Manifold Flow Meter
Prepare & Submit Fire Flow Meter
Submital Review by Client
Review and Approve Radio Study
Submitals / Drawings Approved
Review & Approve Electrical Gear
Fab & Deliver Radio Mast
Fab & Deliver Manifold Flow Meter
Fab & Deliver Fire Flow Meter
Fab & Deliver Electrical G
Mobilize to Site
Pothole Utilities Pyramid Peak Pkwy Tie In
Excavate and Shore Tie in Location
Excavate 12" Line to Masonry Wall
Place Slurry at Masonry Wall
Demo Channel
Excavate 12" Line to Metering Piping
Actual Work
Remaining Work
Critical Float
Longest Path
Remaining Level of Effort
City of Glendale Water Supply Interconnect
MGC Contractors, Inc.
Preliminary Schedule
Page 1 of 3  Report Run Date: 03-14-25
Layout: - Glendale Interconnect
Filter: TASK filter: All Activities
Proj ID: 24479  DD=04-21-25 / Current Project Finish Date:09-
23-25
NTP and completion dates will be updated
based upon actual City approval and NTP

Activity ID
Activity Name
OD
RD Start
Finish
Total
Float
Longest
Path
G107
Vertical Curb restoration
5
5 07-08-25
07-14-25
25
G106
Sidewalk Restoration
5
5 07-08-25
07-14-25
25
G105
Concrete Channel Restoration
5
5 07-08-25
07-14-25
25
G104
Concrete Pad for Metering Piping
5
5 07-08-25
07-14-25
25
Mechanica
Mechanical
Mechanical
Mechanical
Mechanical
Mechanical
Mechanical
Mechanical
G206
Install 16x12 Tapping Sleeve and Valve - Test
4
4 06-16-25
06-19-25
25
G207
Pipeline Services Tap Main Line
1
1 06-20-25
06-20-25
25
G110
Install Metering Pipe Above Ground
5
5 07-15-25
07-21-25
25
G116
Install Manifold Flow Meter
1
1 07-22-25
07-22-25
25
G111
6" Pump to Waste
2
2 07-23-25
07-24-25
25
G109
12" Vertical Piping to Manifold Piping
3
3 07-25-25
07-29-25
25
G112
Hydrostatic Testing
5
5 07-30-25
08-05-25
25
G113
Chlorination
3
3 08-04-25
08-06-25
25
G114
Pipe Coating Sub
5
5 08-07-25
08-13-25
25
Electrical
Electrical
Electrical
Electrical
Electrical
Electrical
Electrical
Electrical
E100
Produce Radio Study
3
3 05-05-25
05-07-25
87
E101
Erect Radio Mast
3
3 06-03-25
06-05-25
70
E108
Replace Fire Flow Meter
2
2 06-24-25
06-25-25
56
E102
Electrical Duct Banks
6
6 07-08-25
07-15-25
29
E103
Backfill Duct Banks
2
2 07-16-25
07-17-25
29
E104
Misc Electrical Slabs
5
5 07-17-25
07-23-25
29
E105
Electrical Cabinets - Gear
3
3 09-04-25
09-08-25
0
E106
Terminations
5
5 09-09-25
09-15-25
0
E107
Startup
3
3 09-16-25
09-18-25
0
Construct
Construction Phase Tonopah
Construction Phase Tonopah
Construction Phase Tonopah
Construction Phase Tonopah
Construction Phase Tonopah
Construction Phase Tonopah
Construction Phase Tonopah
Civil & Me
Civil & Mechanical
Civil & Mechanical
Civil & Mechanical
Civil & Mechanical
Civil & Mechanical
Civil & Mechanical
Civil & Mechanical
A1024
Pothole Utilities
1
1 04-21-25
04-21-25
41
A1026
Excavate & Demo 4" Piping
2
2 04-22-25
04-23-25
41
A1028
Remove & Replace 12" Backflow
2
2 04-24-25
04-25-25
41
A1030
Demo 4" Piping in Vault & Cap Existing
2
2 04-28-25
04-29-25
41
r
May
Jun
Jul
Aug
Sep
Oct
2025
Vertical Curb restoration
Sidewalk Restoration
Concrete Channel Restoration
Concrete Pad for Metering Piping
Install 16x12 Tapping Sleeve and Valve - Test
Pipeline Services Tap Main Line
Install Metering Pipe Above Ground
Install Manifold Flow Meter
6" Pump to Waste
12" Vertical Piping to Manifold Piping
Hydrostatic Testing
Chlorination
Pipe Coating Sub
Produce Radio Study
Erect Radio Mast
Replace Fire Flow Meter
Electrical Duct Banks
Backfill Duct Banks
Misc Electrical Slabs
Electrical Cabinets - G
Terminations
Startup
Pothole Utilities
Excavate & Demo 4" Piping
Remove & Replace 12" Backflow
Demo 4" Piping in Vault & Cap Existing
Actual Work
Remaining Work
Critical Float
Longest Path
Remaining Level of Effort
City of Glendale Water Supply Interconnect
MGC Contractors, Inc.
Preliminary Schedule
Page 2 of 3  Report Run Date: 03-14-25
Layout: - Glendale Interconnect
Filter: TASK filter: All Activities
Proj ID: 24479  DD=04-21-25 / Current Project Finish Date:09-
23-25

Activity ID
Activity Name
OD
RD Start
Finish
Total
Float
Longest
Path
A1032
Excavate 12"x8" Connection
1
1 04-30-25
04-30-25
41
A1034
Remove 12"x8" Connection & Demo 8" Piping
2
2 05-01-25
05-02-25
41
A1036
Core Drill Vault
1
1 05-05-25
05-05-25
41
A1038
Install 12" Piping
2
2 05-06-25
05-07-25
41
A1040
Backfill
2
2 05-08-25
05-09-25
41
A1042
Pipe Tap & Pipe Support
2
2 05-12-25
05-13-25
41
A1044
Restore Landscape & Cleanup
2
2 06-06-25
06-09-25
25
Electrical
Electrical
Electrical
Electrical
Electrical
Electrical
Electrical
Electrical
E112
Electrical Duct Banks
2
2 04-24-25
04-25-25
87
E116
Backfill Duct Banks
1
1 04-28-25
04-28-25
87
E118
Misc Electrical Slabs
5
5 04-29-25
05-05-25
87
E110
Produce Radio Study
3
3 05-05-25
05-07-25
42
E122
Electrical Cabinets - Gear
3
3 05-06-25
05-08-25
87
E124
Terminations
5
5 05-09-25
05-15-25
87
E114
Erect Radio Mast
3
3 06-03-25
06-05-25
25
E126
Startup
3
3 06-06-25
06-10-25
73
r
May
Jun
Jul
Aug
Sep
Oct
2025
Excavate 12"x8" Connection
Remove 12"x8" Connection & Demo 8" Piping
Core Drill Vault
Install 12" Piping
Backfill
Pipe Tap & Pipe Support
Restore Landscape & Cleanup
Electrical Duct Banks
Backfill Duct Banks
Misc Electrical Slabs
Produce Radio Study
Electrical Cabinets - Gear
Terminations
Erect Radio Mast
Startup
Actual Work
Remaining Work
Critical Float
Longest Path
Remaining Level of Effort
City of Glendale Water Supply Interconnect
MGC Contractors, Inc.
Preliminary Schedule
Page 3 of 3  Report Run Date: 03-14-25
Layout: - Glendale Interconnect
Filter: TASK filter: All Activities
Proj ID: 24479  DD=04-21-25 / Current Project Finish Date:09-
23-25

City of Glendale Standard Form Agreement Between Owner and CM@Risk (January 28, 2025) 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
T H I S P A G E I S B L A N K

City of Glendale Standard Form Agreement Between Owner and CM@Risk (January 28, 2025) 
 
 
EXHIBIT H 
Dispute Resolution Procedures 
 
1. 
Disputes. 
1.1 
Each Dispute arising out of or related to this Agreement (including Disputes 
regarding any alleged breaches of this Agreement) shall be initiated and decided 
under the provisions of this Exhibit. 
1.2 
CMAR and City shall each designate in writing to the other party, from time to 
time, a member of senior management who shall be authorized to attempt to 
expeditiously resolve any Dispute relating to the subject matter of this Agreement 
in an equitable manner. 
1.3 
A party shall initiate a Dispute by delivery of written notice to the members of 
management designated by the respective parties under Section 1.2 of this Exhibit.   
1.4 
The parties must:   
(A) 
Attempt to resolve all Disputes promptly, equitably and in a good faith 
manner; and  
(B) 
Provide each other with reasonable access during normal business hours to 
any and all non-privileged records, information and data pertaining to any 
such Dispute. 
1.5 
With respect to matters concerning modification of the GMP or any schedule, 
CMAR must first follow the provisions of any Claim procedure established by the 
Design-Build Agreement before seeking relief under these Procedures. 
2. 
Emergency Arbitration. 
2.1 
If the parties are unable to accomplish resolution of a Dispute, the expedited 
resolution of which either party considers necessary to prevent or mitigate a 
material delay to the critical path of the Services (a "Time Sensitive Dispute") 
within two days after the Time Sensitive Dispute has been initiated by a party, either 
party may thereafter seek emergency relief before an emergency arbitrator (the 
"Emergency Arbitrator") appointed as follows:   
(A) 
The parties will exercise best efforts to pre-select an Emergency Arbitrator 
within 20 days after entering into this Agreement;  
(B) 
If the Emergency Arbitrator has not been selected at the time a party delivers 
Notice of a Time Sensitive Dispute, the parties will each select a 
representative within one day after the Notice is delivered and the two 
representatives will then select the Emergency Arbitrator by the third day 
following delivery of the Notice. 
(C) 
The Emergency Arbitrator shall be an attorney with at least ten (10) years’ 
experience with commercial construction legal matters in Maricopa County, 
Arizona, be independent, impartial, and not have engaged in any business 
for or adverse to either party for at least ten (10) years.   
2.2 
The Emergency Arbitrator will conduct a hearing and render a written 
determination on the Dispute to both parties within five business days of the matter 
being referred to him or her, all in accordance with Rules O-1 to O-8 of the

City of Glendale Standard Form Agreement Between Owner and CM@Risk (January 28, 2025) 
 
 
American Arbitration Association ("AAA") Commercial Rules-Optional Rules for 
Emergency Protection Commercial Rules ("AAA Emergency Rules"). 
2.3 
Although the hearing will be conducted using AAA rules, unless both parties agree 
otherwise, this dispute process will not be administered by the AAA but will be 
conducted by the parties in accordance with these procedures.  
2.4 
If, however, an Emergency Arbitrator has not selected within three days after 
delivery of the Notice, either party may upon three days additional notice, thereafter 
seek emergency relief before the AAA, in accordance with the AAA Emergency 
Rules, provided that the Emergency Arbitrator meets the qualifications set forth 
above.   
2.5 
All proceedings to arbitrate Time Sensitive Disputes shall be conducted in 
Glendale, Arizona.   
2.6 
Presentation, request for determination (i.e., a party’s prayer), and the Emergency 
Arbitrators decision will adhere to the procedures required in Section 3.6 of this 
Exhibit. 
2.7 
The finding of the Emergency Arbitrator with respect to any Time Sensitive 
Dispute will be binding upon the parties on an interim basis during progress of the 
Services, subject to review de novo by arbitration after the Project Substantial 
Completion Date. 
2.8 
The time and extent of discovery will be as determined by the Emergency 
Arbitrator. 
(A) 
 Discovery orders of the Emergency Arbitrator will consider the time 
sensitivity of the matter and the parties desire to resolve the issue in the 
most time and costs efficient manner; 
(B) 
The parties are obligated to cooperate fully and completely in the provision 
of documents and other information, including joint interviews of 
individuals with knowledge such that the matter moves toward resolution 
in the most time and costs efficient manner and the Emergency Arbitrator 
is empowered to fashion any equitable penalty against a party that fail to 
meet this obligation. 
3. 
Non-Emergency Arbitration. 
3.1 
Except as provided in Section 5 of this Exhibit, any Dispute that is either a non-
emergency Dispute that has not been resolved by negotiation, or a de novo review 
of an AAA emergency arbitration will be decided by binding arbitration by a panel 
of three arbitrators in accordance with, but not necessarily administered by, the 
Construction Industry Rules of the AAA.   
(A) 
The parties shall each select an arbitrator within 15 days after notice that a 
party desires to resolve a dispute by arbitration.   
(B) 
The two arbitrators shall then each select a third arbitrator.  If an arbitrator 
is not selected within any such 15 day period, then the arbitrator shall be 
appointed by the AAA.   
3.2 
The arbitrator(s) shall meet the qualifications of Emergency Arbitrators as provided 
in Section 2 of this Exhibit.

City of Glendale Standard Form Agreement Between Owner and CM@Risk (January 28, 2025) 
 
 
3.3 
The arbitrators do not have the authority to consider or award punitive damages as 
part of the arbitrators' award.   
3.4 
In connection with such arbitration, each party shall be entitled to conduct up to 
five depositions, and, no less than 90 days prior to the date of the arbitration hearing, 
each party shall deliver to the other party copies of all documents in the delivering 
party's possession that are relevant to the dispute.   
3.5 
The arbitration hearing shall be held within 150 days of the appointment of the 
arbitrators. 
3.6 
At the arbitration hearing, each party will argue its position to the arbitrators in 
support of one proposed resolution to the dispute (a “Proposed Resolution”).   
(A) 
Each party’s Proposed Resolution must be fully dispositive of the dispute.   
(B) 
The arbitrators must select one Proposed Resolution by majority consent 
and are not free to fashion any alternative resolutions. 
(C) 
The parties must submit their proposed resolution of the matter to the 
arbitrators and the other party 15 days prior to the date set for 
commencement of the arbitration proceeding. 
(D) 
The decision of the arbitrators will be forwarded to the parties within 15 
days after the conclusion of the arbitration hearing. 
(E) 
The decision of the arbitration panel is final and binding on the parties and 
may be entered in any court of competent jurisdiction for the purpose of 
securing an enforceable judgment.   
(F) 
All costs and expenses associated with the arbitration, including the 
reasonable legal fees and costs incurred by the prevailing party, must be 
paid by the party whose position was not selected by the arbitrators. 
4. 
Continuing Work.  Unless otherwise agreed to in writing, CMAR must continue to 
perform and maintain progress of the Work during any Dispute Resolution or arbitration 
proceedings, and City will continue to make payment to CMAR in accordance with the 
Agreement. 
5. 
Exceptions. 
5.1 
Neither City nor CMAR are required to arbitrate any third-party claim, cross-claim, 
counter claim, or other claim or defenses in any action that is commenced by a 
third-party who is not obligated by contract to arbitrate disputes with City and 
CMAR. 
5.2 
City or CMAR may commence and prosecute a civil action to contest a lien or stop 
notice, or enforce any lien or stop notice (but only to the extent the lien or stop 
notice the party seeks to enforce is enforceable under Arizona law), including, 
without limitation, an action under A.R.S. § 33-420, without the necessity of 
initiating or exhausting the procedures of this Exhibit. 
5.3 
This Exhibit does not apply to, and may not be construed to require arbitration of, 
any claims, actions or other process undertaken, filed, or issued by the City of 
Glendale Building Safety Department, Code Compliance Department, Police 
Department, Fire Department, or any other agency of City acting in its

City of Glendale Standard Form Agreement Between Owner and CM@Risk (January 28, 2025) 
 
 
governmental permitting, for the benefit of public health, safety, and welfare, or 
other regulatory capacity. 
5.4 
In connection with any arbitration, the arbitrators do not have the authority to, and 
may not enforce, any provision of the Federal or Arizona Rules of Civil Procedure.