Extracted text (via ocr_local)
57778 characters
CONSTRUCTION CONTRACT - STIPULATED SUM
(DESIGN-BID BUILD PROJECT)
South East Justice Courts and Adult Probation
Office of Procurement Services
Serial # 200095-DBB
Contract # 200095-DBB
C-
Project # 2895-19-0005
Facilities Management
MARICOPA COUNTY, ARIZONA
CONTRACT AGREEMENT
THIS AGREEMENT, is made and entered into this 19th day of August, 2020, by and between
MARICOPA COUNTY, hereinafter called the COUNTY, acting by and through its BOARD OF
SUPERVISORS, and
Johnson Carlier, LLC _ hereinafter referred to as CONTRACTOR.
The CONTRACTOR, for and in the consideration of the sum of
Twenty-seven million, four hundred seventy-five thousand dollars and 00/100 ($27,475,000.00)
Unit prices, if any, are as follows:
Base Bid: $26,200,000
_Bid Alternate One: $1,210,000
_Bid Alternate Two: $65,000
to be paid to him by the COUNTY, in the manner and at the times hereinafter provided, and in consideration
of the other covenants and agreements herein contained, hereby agrees for itself, its heirs, executors,
administrators, successors, and assigns as follows:
ARTICLE I - SCOPE OF WORK: CONTRACTOR shall construct, and complete in a workmanlike
manner and to the satisfaction of the Facilities Management Director, a project for the Maricopa County
Facilities Management, designated as Serial # 200095-DBB, South East Justice Courts and Adult
Probation, and furnish at its own cost and expense all necessary machinery, equipment, tools, apparatus,
materials, and labor to complete the work in the most workmanlike manner according to the Plans and
Specifications on file with the Maricopa County Facilities Management, and listed herein, together with
modifications of the same and other directions that may be made by the Maricopa County Facilities
Management as provided herein.
ARTICLE II - CONTRACT DOCUMENTS: The Contract Documents (Invitation to Bid, Plans,
Construction Special Provisions , Addenda issued prior to the execution of this Agreement, if any, General
Conditions, General Requirements, Specifications, Maricopa Association of Governments (MAG) Standard
Specifications and Uniform Standard Details, and the latest revisions thereto, Maricopa County Supplement
to M.A.G. Uniform Standard Specifications for Public Works Construction, Bid, Affidavits, Performance
Bond, Payment Bond, Certificates of Insurance, and Change Orders, if any,) are by this reference made a
part of this Contract and shall have the same effect as though all of the same were fully inserted herein.
This Contract, including the Contract Documents, represents the entire and integrated agreement between
the parties and supersedes any prior negotiations, representations, or agreements, either written or oral.
All amendments to this Contract shall be in writing and approved/signed by both parties.
ARTICLE III - TIME FOR COMPLETION: CONTRACTOR further covenants and agrees at its own
cost and expense, to do all work as aforesaid for the construction of said improvements and to completely
construct the same and install the material therein, as called for by this agreement free and clear of ail
claims, liens, and charges whatsoever, in the manner and under the conditions specified and within the time,
or times, stated in the Bid pamphlet and this Contract. The date for the commencement of the work will be
set by a Notice to Proceed issued by the Owner. The time for completion will be measured from the date
of commencement.
ARTICLE IV - SUBSTANTIAL COMPLETION: The CONTRACTOR shall achieve Substantial
Completion of the work not later than 540 days from the date of commencement subject to adjustments to
South East Justice Courts and Adult Probation Serial # 200095-DBB
Request for Bids - Design Bid Build Pg. #2
the Contract Time as provided for herein. Final Completion shall be achieved in 30 days after Substantial
Completion, subject to adjustments to the Contract Time as provided for herein.
ARTICLE V - PAYMENTS: For and in consideration of the satisfactory performance of the work as set
forth in the Contract Documents, which are a part hereof, and in accordance with the directions of the
COUNTY, through its Design Professional, the COUNTY agrees to pay the said CONTRACTOR the
amount earned, (and, if unit prices are applicable the sum due as computed from actual quantities of work
performed and accepted, or materials furnished at the unit bid price on the Bid made a part hereof) and to
make’ such payment in accordance with the requirements of A.R.S. § 34-221, as amended.
CONTRACTOR agrees to discharge its obligations and to make payments to its subcontractors and
suppliers in accordance with A.R.S. § 32-1129, the Prompt Pay Act.
ARTICLE VI - LIQUIDATED DAMAGES: Liquidated damages are provided for in this Contract, as
explained in the General Conditions to this Contract.
Upon failure of Contractor to substantially complete the Project within the specified period of time, plus
approved time extensions, Contractor shall pay to OWNER the maximum sum of four thousand five
hundred sixty seven dollars and 00/100 Dollars ($4,567.00) for each calendar day after the time specified
in Article IV above. The actual liquidated damages cost, including back-up will be forwarded to the
Contractor. In any case the actual liquidated damages amount shall not exceed the maximum sum indicated
above. After Substantial Completion, should Contractor fail to complete the remaining work within the
time specified in Article IV above, plus approved time extensions thereof, for completion and readiness for
Final Completion, Contractor shall pay to OWNER the maximum sum of four thousand five hundred
sixty seven dollars and 00/100 Dollars ($4,567.00) for each calendar day after the time specified in Article
IV above. The actual liquidated damages cost, including back-up will be forwarded to the Contractor. In
any case the actual liquidated damages amount shall not exceed the maximum sum indicated above. These
amounts are not penalties but are liquidated damages to OWNER for its inability to obtain full beneficial
occupancy of the Project.
ARTICLE VII - TERMINATION: The COUNTY hereby gives notice that pursuant to A.R.S. § 38-511
A, this contract may be canceled without penalty or further obligation within three years after execution if
any person significantly involved in initiation, negotiation, securing, drafting or creating the contract on
behalf of the COUNTY is, at any time while the contract or any extension of the contract is in effect, an
employee or agent of any other party to the contract in any capacity or a Contractor to any other party of
the contract with respect to the subject matter of the contract. Cancellation under this section shall be
effective when written notice from the COUNTY is received by all of the parties to the contract. In
addition, the COUNTY may recoup any fee or commission paid or due to any person significantly involved
in initiation, negotiation, securing, drafting or creating the contract on behalf of the COUNTY from any
other party to the contract arising as a result of the contract.
ARTICLE VIII - TERMINATION FOR DEFAULT: If the CONTRACTOR should be adjudged
bankrupt or should make a general assignment for the benefit of its creditors, or if a receiver should be
appointed on account of its insolvency, the COUNTY may terminate the Contract. If the CONTRACTOR
should repeatedly refuse or should fail, except in cases for which extension of time is provided, to provide
enough properly skilled workers or proper materials, or repeatedly disregard laws and ordinances, or fail to
meet deadlines or not proceed with work, or otherwise be guilty of a material breach of any provision of
this Contract, then the COUNTY may terminate the Contract. Prior to termination of the Contract, the
COUNTY shall give the Contractor fourteen (14) calendar day’s written notice. Upon receipt of such
termination notice, the Contractor shall be allowed fourteen (14) calendar days to cure such deficiencies.
In the event of termination under this paragraph, all documents, data, and reports prepared by the
CONTRACTOR under this Contract shall become the property of and be delivered to the COUNTY upon
demand. Sums claimed due by the CONTRACTOR shall not be paid until the Work has been completed
and such payment shall only be made after deduction damages caused by the default. In the event a
termination for default is determined to be without cause, it shall be deemed to be a termination for
convenience.
South East Justice Courts and Adult Probation Serial # 200095-DBB
Request for Bids - Design Bid Build Pg. #3
ARTICLE IX - TERMINATION FOR CONVENIENCE: The COUNTY reserves the right to terminate
the Contract, in whole or in part at any time, when in the best interests of the COUNTY without penalty or
recourse. Upon receipt of the written notice, the CONTRACTOR shall immediately stop all work, as
directed in the notice, notify all subcontractors of the effective date of the termination and minimize all
further costs to the COUNTY. In the event of termination under this paragraph, all documents, data and
reports prepared by the CONTRACTOR under the Contract shall become the property of and be delivered
to the COUNTY upon demand. The CONTRACTOR shall be entitled to receive just and equitable
compensation for work in progress, work completed and materials accepted before the effective date of the
termination. No lost “future profits” will be paid to the CONTRACTOR.
ARTICLE X - SUSPENSION OF WORK: The Owner may order the CONTRACTOR, in writing, to
suspend, delay, or interrupt all or any part of the work of this Contract for the period of time that the Owner
determines appropriate for the convenience of the COUNTY.
If the performance of all or any part of the work is, for an unreasonable period of time, suspended, delayed,
or interrupted (1) by an act of the Owner in the administration of this Contract, or (2) by the Owner’s failure
to act within the time specified in this Contract (or within a reasonable time if not specified), an adjustment
shall be made for any increase in the cost of performance of the Contract (excluding profit) caused by the
unreasonable suspension, delay, or interruption, and the contract will be modified in writing accordingly.
However, no adjustment shall be made under this provision for any suspension, delay, or interruption to the
extent that performance would have been so suspended, delayed, or interrupted by any other cause,
including the fault of negligence of the Contractor, or for which an equitable adjustment is provided (or
excluded) under any other term or condition of this Contract.
A claim under this provision shall not be allowed:
For any costs incurred more than 14 days before the CONTRACTOR has notified the Owner in writing of
the act or failure to act involved (but this requirement shall not apply as to a claim resulting from a
suspension order); and unless the claim, in an amount stated, is made in writing as soon as practicable after
the termination of the suspension, delay, or interruption, but not later than the date of final payment under
the Contract.
ARTICLE XI - NEGOTIATION CLAUSE: Recovery of damages related to expenses incurred by
CONTRACTOR for a delay for which the COUNTY is responsible, which is unreasonable under the
circumstances and which was not within the contemplation of the parties to the contract, shall be negotiated
between CONTRACTOR and the COUNTY. This provision shall be construed so as to give full effect
to any provision in the contract which requires notice of delays, provides for neutral evaluation and
arbitration or other procedure for settlement, or provides for liquidated damages.
ARTICLE XII - COMPLIANCE WITH LAWS: CONTRACTOR is required to comply with all
Federal, State and local ordinances and regulations. CONTRACTOR'S signature on this contract certifies
compliance with the provisions of the I-9 requirements of the Immigration Reform Control Act of 1986 for
all personnel that CONTRACTOR and any subcontractors employ to complete this project. The
COUNTY will perform in accordance with the provisions of the Maricopa County Procurement Code.
The CONTRACTOR warrants that it is in compliance with A.R.S. §41-4401 (regarding immigration) and
further acknowledges:
(1) The CONTRACTOR and its sub-contractors, if any, warrant their compliance with all
federal immigration laws and regulations that relate to their employees and their
compliance with A.R.S. §23-214, subsection A; (on e-verification, etc.). After December
31, 2007, every employer, after hiring an employee, shall verify the employment eligibility
of the employee through the e-verify program and shall keep a record of the verification
for the duration of the employee’s employment or at least three years, whichever is longer.
(2) A breach of a warranty under subsection 1 above, shall be deemed a material breach of the
contract that is subject to penalties up to and including termination of the Contract:
South East Justice Courts and Adult Probation Serial # 200095-DBB
Request for Bids - Design Bid Build Pg. #4
(3) The COUNTY retains the legal right to inspect the papers of ary CONTRACTOR or sub-
contractor employee who works on the contract to ensure that the CONTRACTOR or sub-
contractor is complying with the warranty provided under subsection 1 above and that the
CONTRACTOR agrees to make all papers and employment records of said employee(s)
available during normal working hours in order to facilitate such an inspection.
(4) Nothing herein shall make any CONTRACTOR or sub-contractor an agent or employee
of the COUNTY.
ARTICLE XIII - SBE PROGRAM: It is Maricopa County’s policy to endeavor to ensure in every way
possible that small business participation firms shall have the opportunity to provide professional services,
materials, and contractual services to the County in a nondiscriminatory manner.
ARTICLE XIV — SBE PARTICIPATION PAY FORM: This form (copy attached) is to be submitted
with each pay application or invoice. Any pay application or invoice without this form attached is subject
to rejection as not being a completed pay application or invoice pursuant to the terms of the contract.
ARTICLE XV - ANTI-DISCRIMINATION PROVISION: CONTRACTOR agrees not to
discriminate against any employee or applicant for employment because of race, age, color, religion, sex,
disability, or national origin, and further agrees not to engage in any unlawful employment practices.
CONTRACTOR further agrees to insert the foregoing provision in all subcontracts hereunder.
CONTRACTOR agrees to comply with all provisions and requirements of Arizona Executive Order 2009-
09 including flow down of all provisions and requirements to any subcontractors. Executive Order 2009-
09 supersedes Executive order 99-4 and amends Executive order 75-5 and may be viewed and downloaded
at the Governor of the State of Arizona’s website
http://www.azgovernor.gov/dms/upload/EO_2009_09.pdf which is hereby incorporated into this contract
as if set forth in full herein. During the performance of this contract, CONTRACTOR shall not discriminate
against any employee, client or any or any other individual in any way because of that person’s age, race,
creed, color, religion, sex, disability or national origin.
ARTICLE XVI- INFLUENCE: As prescribed in MC1-1202 of the Maricopa County Procurement Code,
any effort to influence an employee or agent to breach the Maricopa County Ethical Code of Conduct, or
any unethical conduct, may be grounds for Disbarment or Suspension under MC1-902.
An attempt to influence includes, but is not limited to:
(1) A Person offering or providing a gratuity, gift, tip, present, donation, money, entertainment
or educational passes or tickets, or any type valuable contribution or subsidy;
(2) That is offered or given with the intent to influence a decision, obtain a contract, garner
favorable treatment, or gain favorable consideration of any kind.
If a Person attempts to influence any employee or agent of Maricopa County, the Chief Procurement
Officer, or his designee, reserves the right to seek any remedy provided by the Maricopa County
Procurement Code, any remedy in equity or in the law, or any remedy provided by this contract.
ARTICLE XVII - AMENDMENTS: All amendments to this Contract shall be in writing and
approved/signed by both parties. Maricopa County Office of Procurement Services shall be responsible for
approving all amendments for Maricopa County.
South East Justice Courts and Adult Probation Serial # 200095-DBB
Request for Bids - Design Bid Build Pg. #5
ARTICLE XVIII- ALTERNATIVE DISPUTE RESOLUTION
See Exhibit A for Alternative Dispute Resolution.
ARTICLE XIX UNIFORM ADMINISTRATIVE REQUIREMENTS:
When applicable and by entering into this Contract the Contractor agrees to comply with all applicable
provisions of Title 2, Subtitle: A, Chapter II, PART 200—UNIFORM ADMINISTRATIVE
REQUIREMENTS, COST PRINCIPLES, AND AUDIT REQUIREMENTS FOR FEDERAL AWARDS
contained in Title 2 C.F.R. § 200 et seq.
South East Justice Courts and Adult Probation Serial # 200095-DBB
Request for Bids - Design Bid Build Pg. #6
IN WITNESS WHEREOF, the parties hereto have executed this Agreement on the day and date first
above written, in counterparts, each of which shall, without proof or accounting for the other
counterparts, be deemed an original contract.
South East Justice Courts and Adult Probation
200095-DBB
“hale (Signature)
Johnson Carlier, LLC Tyler Wilson
Printed Name
July 29, 2020
Date
26-3193570
Federal Tax Identification Number
Vice President 249426
Title Arizona Contractor’s License Number
909-22
Vendor Terms NIGP Commodity Code (Advantage)
COUNTY OF MARICOPA, ARIZONA
RECOMMENDED By: ACCEPTED AND APPROVED:
gay oe vee
Dicom wee ote
Rich Wegele Szxvsate 7/29/20
Department Head Date Chairman, Board of Supervisors — Date
ATTEST:
Clerk of the Board Date
LEGAL REVIEW
Approved as to form and within the powers and
authority granted under the laws of the State of
Arizona to Maricopa County.
Deputy County Attomey
pate: _[|.Ay BO, 2020
6) 0d y
South East Justice Courts and Adult Probation
Request for Bids - Design Bid Build
Serial # 200095-DBB-
Pg. #7
1.1
1.2
1.3
1.4
1.5
EXHIBIT A - ALTERNATIVE DISPUTE RESOLUTION
Scope. Notwithstanding anything to the contrary provided elsewhere in the Contract, the
alternative dispute resolution (“ADR”) process provided herein shall be the exclusive means for
resolution of claims or disputes arising under or related to the Contract, the interpretation thereof
or the performance or breach by any party thereto, including but not limited to original claims or
disputes asserted as cross claims, counterclaims, third party claims or claims for indemnity or
subrogation, in any threatened or ongoing litigation or arbitration with third parties, if such disputes
involve parties to contracts containing this ADR provision. No changes can be made to this process
without the mutual assent of the County and the claimant. The parties have structured this
procedure with the goal of providing for the prompt, efficient and final resolution of all disputes
falling within the purview of this ADR process.
Meeting of Principals. When a claim is made or a dispute (hereafter “dispute”) as described in
Paragraph 1.2 arises, senior representatives of the County and the claimant will meet personally
within ten (10) business days to discuss the dispute and attempt to resolve it. If, after good faith
efforts, resolution is not achieved, the dispute will proceed to mediation.
Qualifications of Mediator and Arbitrators. Any person selected as mediator or arbitrator, either
as single arbitrator as a member or Chair of the arbitration panel, shall be a member of the State
Bar of Arizona and have experience in construction law.
Mediation. If the parties have been unable to resolve the dispute after a meeting of principals, the
parties may enter into mediation. The parties shall jointly select a mediator. The parties may
mutually agree to waive mediation and proceed directly to arbitration. If the mediation process is
requested by either party, the mediation period shall be informal and shall not exceed sixty (60)
calendar days from the selection of the mediator. During the mediation process either party may
terminate mediation on written notice to the other party and the mediator.
Binding Arbitration Procedure. The following binding arbitration procedure shall serve as the
exclusive method to resolve a dispute if mediation is unsuccessful, if mediation has been waived
by the parties, or if a party requests arbitration during the mediation process. Except as provided
in Section 1.7.5 and 1.7.9, the decision of the arbitrator or arbitrator panel is final and binding on
the parties and not subject to further judicial review.
1.5.1 A party requesting binding arbitration shall notify the other party of their demand for
arbitration in writing within seven (7) calendar days of (1) the failure of mediation; (2)
waiver of mediation; or (3) of the party’s demand to terminate mediation.
1.5.2 If the Contractor requests arbitration it shall post a cash bond with the arbitrator in an
amount agreed upon by the parties or, in the event of no agreement, the arbitrator shall
establish the amount of the cash bond to defray the cost of the arbitration and the proceeds
from the bond shall be allocated in accordance with paragraph 1.7.7. The bond must be in
the full amount agreed upon or as established by the Arbitrator to pay the potential cost of
the full arbitration proceeding. The bond must be posted with and received by the arbitrator
within five (5) calendar days after the demand for arbitration.
1.5.3. Disputes involving less than $200,000 shall be heard by one single arbitrator chosen by
agreement of the parties. If the parties cannot agree on the single arbitrator, then the parties
South East Justice Courts and Adult Probation Serial # 200095-DBB
Request for Bids - Design Bid Build Pg. #8
shall each submit two names to a Judge designated by Maricopa County who shall select
the single arbitrator.
1.5.4 For disputes in excess of $200,000, the arbitration panel shall consist of three arbitrators:
the County's appointed arbitrator, the Contractor's appointed arbitrator and a third arbitrator
who shall be selected by the parties' arbitrators.and serve as the Chair of the arbitration
panel.
1.5.5 The arbitration is to be convened and administered under the Revised Uniform Arbitration
Act (“RUAA”) (A.R.S. § 12-3001 ef seq.) and the American Arbitration Association
Construction Rules shall serve as a guideline for proceedings, thus as a supplement to the
RUAA.
1.6 Expedited Hearing. Any party can request the single arbitrator or the Chair of the arbitration panel
to set an expedited hearing. If the single arbitrator or the Chair of the arbitration panel determines
that the circumstances justify it, the single arbitrator or the Chair of the arbitration panel will
arrange for scheduling of the arbitration at the earliest possible date. In any event, the hearing of
any dispute not expedited will commence as soon as practical but in no event later than thirty (30)
calendar days after notification of request for arbitration having been received. This deadline can
be extended only with the consent of all the parties to the dispute, or by decision of the single
arbitrator or the Chair of the arbitration panel upon a showing of good cause.
1.7 Procedure. The single arbitrator or the arbitration panel will conduct the hearing in such a manner
that will resolve disputes in a prompt, cost efficient manner giving regard to the rights of all parties.
Each party shall supply to the single arbitrator or arbitration panel a written pre-hearing statement
which shall contain a brief statement of the nature of the claim or defense, a list of witnesses and
exhibits, a brief description of the subject matter of the testimony of each witness who will be called
to testify, and an estimate as to the length of time that will be required for the arbitration hearing.
The single arbitrator or the Chair of the arbitration panel shall determine the nature and scope of
discovery, if any, and the manner of presentation of relevant evidence consistent with deadlines
provided herein, and the parties’ objective that disputes be resolved in a prompt and efficient
manner. No discovery may be had of any materials or information for which a privilege is
recognized by Arizona law. The single arbitrator or the Chair upon proper application shall issue
such orders as may be necessary and permissible under law to protect confidential, proprietary or
sensitive materials or information from public disclosure or other misuse. Any party may make
application to the Maricopa County Superior Court to have a protective order entered as may be
appropriate to confirm or enforce such orders of the Chair.
1.7.1 Hearing Days. In order to effectuate parties’ goals, the hearing once commenced, will
proceed from working day to working day until concluded, absent a showing of good cause.
1.7.2. Award. The single arbitrator shall within ten (10) calendar days of the conclusion of a
hearing issue an award. The arbitration panel shall, within ten (10) calendar days from the
conclusion of any hearing, by majority vote, issue its award. The award shall include an
allocation of fees and costs pursuant to 1.7.7 herein. The award is to be in accordance with
the Contract and the law of the State of Arizona.
1.7.3 Scope of Award. Regardless of the provisions of the RUAA, the arbitration panel shall be
without authority to award punitive damages, and any such punitive damage award shall
be void. If an award is made against any party in excess of one hundred thousand dollars
($100,000), exclusive of interest, arbitration fees, costs and attorneys’ fees, it shall be
South East Justice Courts and Adult Probation Serial # 200095-DBB
Request for Bids - Design Bid Build Pg. #9
1.7.4
1.7.5
1.7.6
1.7.7
1.7.8
supported by written findings of fact, conclusions of law anda statement as to how damages
were calculated.
Jurisdiction. The arbitration panel shall not be bound for jurisdictional purposes by the
amount asserted in any party’s claim, but shall conduct a preliminary hearing into the
question of jurisdiction over the claim as regards its amount upon application of any party
at the earliest convenient time, but not later than the commencement of the arbitration
hearing. If the dispute is determined to involve less than $200,000, the arbitration shall
continue before the Neutral Arbitrator as a single arbitrator, with the party appointed
arbitrators being excused.
Entry of Judgment. As provided in the RUAA, any party can make application to the
Maricopa County Superior Court for confirmation of an award, and for entry of judgment
on it.
Severance and Joinder. To reduce the possibility of inconsistent adjudications, the
Mediator or the single arbitrator or arbitration panel, may: (i) at the request of any party,
join and/or sever parties, and/or claims arising under other contracts containing this ADR
provision, and (ii) the Mediator, on his own authority, or the single arbitrator or arbitration
panel may, on its own authority, join or sever parties and/or claims subject to this ADR
process as deemed necessary for a just resolution of the dispute, consistent with the parties’
goal of the prompt and efficient resolution of disputes, provided; however, that the A/E,
Owner and Project Professionals shall not be joined as a party to any claim made by a
Contractor. Nothing herein shall create the right by any party to assert claims against
another party not arising under or related to the Contract or not recognized under the
substantive law as applicable to the dispute. Neither the Mediator nor the single arbitrator
or arbitration panel is authorized to join to the proceeding parties not in privity with the
County. The CONTRACTOR cannot be joined to any pending arbitration proceeding,
without CONTRACTOR’s express written consent and unless CONTRACTOR is given
the opportunity to participate in the selection of the single arbitrator or non-County
appointed arbitrator.
Fees and Costs. Each party shall bear its own fees and costs in connection with any
informal hearing before the mediation. All fees and costs associated with any arbitration
before the single panel or arbitration panel, including without limitation the arbitrator fees,
and the prevailing party’s reasonable attorneys’ fees, expert witness fees and costs, will be
paid by the non-prevailing party, except as provided for herein. In the event that
CONTRACTOR is the non-prevailing party, all fees and costs as noted above shall first be
paid out of the bond posted with the arbitrator. In no event shall the CONTRACTOR’s
obligation to pay fees and costs be limited to the amount of the bond posted herein. In no
event shall any arbitrator’s hourly fees be awarded in an amount in excess of $250 per hour
and (i) costs shall not include any travel expenses in excess of mileage at the rate paid by
Maricopa County, not to exceed a one way trip of 150 miles, and (ii) all travel expenses,
including meals, shall be reimbursed pursuant to the travel policy of Maricopa County in
effect at the time of the hearing. The determination of prevailing and non-prevailing
parties, and the appropriate allocation of fees and costs, will be included in the award by
the single arbitrator or arbitration panel.
Confidentiality. Any proceeding initiated under this ADR provision shall be deemed
confidential to the maximum extent allowed by Arizona law and, except for disclosures to
a party’s attorneys or accountants, no party shall make any disclosure related to the
South East Justice Courts and Adult Probation Serial # 200095-DBB
Request for Bids - Design Bid Build Pg. #10
disputed matter or to the outcome of any proceeding except to the extent required by law,
or to seek interim equitable relief, or to enforce an agreement reached by the parties or an
award made hereunder. This provision does not affect the County’s right to inform the
County Supervisors of the dispute.
1.7.9. Equitable Litigation. Notwithstanding any other provision of ADR to the contrary, any
party can petition the Maricopa County Superior Court for interim equitable relief as may
become necessary to preserve the status quo and prevent immediate and irreparable harm
to a party or to the Project pending resolution of a dispute pursuant to ADR provided herein.
No court may order any permanent injunctive relief except as may be necessary to enforce
an order entered by the arbitration panel. The fees and costs incurred in connection with
any such equitable proceeding shall be determined and assessed in ADR.
1.7.10 Change Order. Any award in favor of the CONTRACTOR against the County or in favor
of the County against the CONTRACTOR shall be reduced to a Change Order and
executed by the parties in accordance with the award and the provisions of the Contract or
a settlement agreement as appropriate.
1.7.11 Merger and Bar. Any claim asserted pursuant to this ADR process shall be deemed to
include all claims, demands, and requests for compensation for costs and losses or other
relief, including the extension of the Contract performance period which reasonably should
or could have been brought against any party that was or could have been brought into this
ADR process, with respect to the subject claim. The arbitration panel shall apply legal
principles commonly known as merger and bar to deny any claim or claims against any
party regarding which claim or claims recovery has been sought or should have been sought
in a previously adjudicated claim for an alleged cost, loss, breach, error, or omission.
1.8 Inclusion in Other Contracts. The CONTRACTOR shall cooperate with the County in efforts to
include this ADR provision in all other Project contracts.
END OF EXHIBIT
South East Justice Courts and Adult Probation Serial # 200095-DBB
Request for Bids - Design Bid Build Pg. #11
Attachment I - STATUTORY PAYMENT BOND
PURSUANT TO TITLE 34 CHAPTER 2, ARTICLE 2, OF THE ARIZONA REVISED STATUTES
(Penalty of this bond must be 100 percent of the contract amount)
KNOW ALL MEN BY THESE PRESENTS:
That, Johnson Carlier, LLC (hereinafter called the Principal), as Principal, and
Fidelity and Deposit Company of Maryland a corporation organized and existing under the laws of the State of
Ullinois , with its principal office in the City of Chicago
(hereinafter called the Surety), as Surety, are held and firmly bound unto Maricopa County (hereinafter called
the Obligee), in the amount of Twenty Seven Million Four Hundred* _ DOLLARS ($_27,475,000.00-—_—__— ),
for the payment whereof, the said Principal and Surety bind themselves, and their heirs, administrators,
executors, successors and assigns, jointly and severally, firmly by these presents.
*Seventy Five Thousand and 00/100—Dollars)
WHEREAS, the Principal has entered into a certain written contract with the Obligee, dated the _19th_ day
of_August ,20 20 _, for South East Justice Courts and Adult Probation, 200095-
DBB, which contract is hereby referred to and made a part hereof as fully and to the same extent as if copied
at length herein.
NOW, THEREFORE, THE CONDITION OF THIS OBLIGATION IS SUCH, that if the said Principal
promptly pays all monies due to all persons supplying labor or materials to the Principal or the Principal's
subcontractors in the prosecution of the work provided for in the contract, this obligation is void. Otherwise it
remains in full force and effect.
PROVIDED, HOWEVER, that this bond is executed pursuant to the provisions of Title 34, Chapter 2, Article
2, of the Arizona Revised Statutes, and all liabilities on this bond shall be determined in accordance with the
provisions, conditions, and limitations of Title 34, Chapter 2, Article 2, Arizona Revised Statutes, to the same
extent as if it was copied at length in this agreement.
The prevailing party in a suit on this bond shall recover as a part of the judgment reasonable attomey's fees
that may be fixed by the court or a judge thereof.
Witness our hands this _24th__ day of __July , 20.20
Johnson Carlier, LLC
PRINC SEAL
‘
Arthur J. Gallagher & Co. BY: 2 Ay
v
AGENT OF RECORD, STATE OF Az CA
1160 Battery Street, Suite 360, S.F., CA 94111 Fidelity and Deposit Company of Maryland
AGENT ADDRESS S TY SEAL
BOND NUMBER: _ 9351262 BY) Usawway-yolace—
. Virginia }.. Black, Attorney-in-Fact
South East Justice Courts and Adult Probation
Serial # 200095-DBB
Request for Bids - Design Bid Build Pg. #26
ACKNOWLEDGMENT
A notary public or other officer completing this
certificate verifies only the identity of the individual
who signed the document to which this certificate is
attached, and not the truthfulness, accuracy, or
validity of that document.
State of California
County of San Francisco )
oA uA WY vw before me, M. Moody, Notary Public
\
(insert name and title of the officer)
personally appeared Virginia L. Black
who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are
subscribed to the within instrument and acknowledged to me that he/she/they executed the same in
his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the
person(s), or the entity upon behalf of which the person(s) acted, executed the instrument.
| certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing
paragraph is true and correct.
COMM. #2225134 vu
ea) NOTARY PUBLIC-CALIFORNIA
SAN FRANCISCO COUNTY
J Ciieate My Comm. Expires Jan. 8, 2022 {
Signature MA
(Seal)
N
WITNESS my hand and official seal. 8
a
ZURICH AMERICAN INSURANCE COMPANY
COLONIAL AMERICAN CASUALTY AND SURETY COMPANY
FIDELITY AND DEPOSIT COMPANY OF MARYLAND
POWER OF ATTORNEY
KNOW ALL MEN BY THESE PRESENTS: That the ZURICH AMERICAN INSURANCE COMPANY, a corporation of the State of New
York, the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY, a corporation of the State of Illinois, and the FIDELITY
AND DEPOSIT COMPANY OF MARYLAND a corporation of the State of Illinois (herein collectively called the “Companies"), by
Robert D. Murray, Vice President, in pursuance of authority granted by Article V, Section 8, of the By-Laws of said Companies, which are
set forth on the reverse side hereof and are hereby certified to be in full force and effect on the date hereof, do hereby nominate, constitute,
and appoint Maureen O’CONNELL, Robert P. WRIXON, M MOODY, Betty L. TOLENTINO, Janet C. ROJO, Virginia L. BLACK,
Kevin RE, Susan M. EXLINE, Gillian BHASKARAN, T. LE, Brittany KAVAN, Julia ORTEGA, K. ZEROUNIAN, Douglas B.
BOWRING, Susan HECKER and Matthew KALAFATIS, of Lafayette and San Francisco, California, EACH, its true and lawful
agent and Attorney-in-Fact, to make, execute, seal and deliver, for, and on its behalf as surety, and as its act and deed: any and all bonds
and undertakings, and the execution of such bonds or undertakings in pursuance of these presents, shall be as binding upon said Companies,
as fully and amply, to all intents and purposes, as if they had been duly executed and acknowledged by the regularly elected officers of the
ZURICH AMERICAN INSURANCE COMPANY at its office in New York, New York., the regularly elected officers of the COLONIAL
AMERICAN CASUALTY AND SURETY COMPANY at its office in Owings Mills, Maryland., and the regularly elected officers of the
FIDELITY AND DEPOSIT COMPANY OF MARYLAND at its office in Owings Mills, Maryland., in their own proper persons.
The said Vice President does hereby certify that the extract set forth on the reverse side hereof is a true copy of Article V, Section 8, of
the By-Laws of said Companies, and is now in force.
IN WITNESS WHEREOF, the said Vice-President has hereunto subscribed his/her names and affixed the Corporate Seals of the said
ZURICH AMERICAN INSURANCE COMPANY, COLONIAL AMERICAN CASUALTY AND SURETY COMPANY, and
FIDELITY AND DEPOSIT COMPANY OF MARYLAND, this I Ith day of June, A.D. 2019.
ATTEST:
ZURICH AMERICAN INSURANCE COMPANY
COLONIAL AMERICAN CASUALTY AND SURETY COMPANY
FIDELITY AND DEPOSIT COMPANY OF MARYLAND
By: Robert D. Murray
Vice President
coun Srou re
By: Dawn E. Brown
Secretary
State of Maryland
County of Baltimore
On this Ith day of June, A.D. 2019, before the subscriber, a Notary Public of the State of Maryland, duly commissioned and qualified, Robert D.
Murray, Vice President and Dawn E. Brown, Secretary of the Companies, to me personally known to be the individuals and officers described in and who
executed the preceding instrument, and acknowledged the execution of same, and being by me duly sworn, deposeth and saith, that he/she is the said officer of
the Company aforesaid, and that the seals affixed to the preceding instrument are the Corporate Seals of said Companies, and that the said Corporate Seals and
the signature as such officer were duly affixed and subscribed to the said instrument by the authority and direction of the said Corporations.
IN TESTIMONY WHEREOF, I have hereunto set my hand and affixed my Official Seal the day and year first above written.
Conmatance.O.urmey
Constance A. Dunn, Notary Public
My Commission Expires: July 9, 2023
wy
»
111 Be
rw
EXTRACT FROM BY-LAWS OF THE COMPANIES
“Article V, Section 8, Attorneys-in-Fact, The Chief Executive Officer, the President, or any Executive Vice President or Vice President
may, by written instrument under the attested corporate seal, appoint attorneys-in-fact with authority to execute bonds, policies,
tecognizances, stipulations, undertakings, or other like instruments on behalf of the Company, and may authorize any officer or any such
attorney-in-fact to affix the corporate seal thereto; and may with or without cause modify of revoke any such appointment or authority at any
time."
CERTIFICATE
|, the undersigned, Secretary of the ZURICH AMERICAN INSURANCE COMPANY, the COLONIAL AMERICAN CASUALTY
AND SURETY COMPANY, and the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, do hereby certify that the foregoing
Power of Attorney is still in full force and effect on the date of this certificate: and I do further certify that Article V, Section 8, of the By-
Laws of the Companies is still in force.
This Power of Attorney and Certificate may be signed by facsimile under and by authority of the following resolution of the Board of
Directors of the ZURICH AMERICAN INSURANCE COMPANY ata meeting duly called and held on the [5th day of December 1998
RESOLVED: "That the signature of the President or a Vice President and the attesting signature of a Secretary or an Assistant Secretary
and the Seal of the Company may be affixed by facsimile on any Power of Attorney...Any such Power or any certificate thereof bearing such
facsimile signature and seal shall be valid and binding on the Company."
This Power of Attorney and Certificate may be signed by facsimile under and by authority of the following resolution of the Board of
Directors of the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY at a mecting duly called and held on the 5th day of
May, 1994, and the following resolution of the Board of Directors of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND at a
meeting duly called and held on the 10th day of May, 1990.
RESOLVED: "That the facsimile or mechanically reproduced seal of the company and facsimile or mechanically reproduced signature
of any Vice-President, Secretary, or Assistant Secretary of the Company, whether made heretofore or hereafter, wherever appearing upon a
certified copy of any power of attorney issued by the Company, shall be valid and binding upon the Company with the same force and effect
as though manually affixed.
HRramotiy REOF, I have hegeynto subscribed my name and affixed the corporate seals of the said Companies,
this, day o Sway
By: Brian M. Hodges
Vice President
TO REPORT A CLAIM WITH REGARD TO A SURETY BOND, PLEASE SUBMIT A COMPLETE DESCRIPTION
OF THE CLAIM INCLUDING THE PRINCIPAL ON THE BOND, THE BOND NUMBER, AND YOUR CONTACT
INFORMATION TO:
Zurich Surety Claims
1299 Zurich Way
Schaumburg, IL 60196-1056
www. reportsfclaims@zurichna.com
800-626-4577
Attachment J - STATUTORY PERFORMANCE BOND
PURSUANT TO TITLE 34 CHAPTER 2, ARTICLE 2, OF THE ARIZONA REVISED STATUTES (Penalty
of this bond must be 100 percent of the contract amount)
KNOW ALL MEN BY THESE PRESENTS:
That, _Johnson Carlier, LLC (hereinafter called the Principal), as Principal, and
Fidelity and Deposit Company of Maryland a
corporation organized and existing under the laws of the State of _llinois : with its
principal office in the City of Chicago (hereinafter called the Surety), as Surety, are held and
firmly bound unto Maricopa County, (hereinafter called the Obligee) in the amount of Twenty Seven Million Four *
DOLLARS (§ 27,475,000.00—-—-—_-—-—), for the payment whereof, the said Principal and Surety bind
themselves, and their heirs, administrators, executors, successors and assigns, jointly and severally, firmly by
these presents. *Hundred Seventy Five Thousand and 00/100—Dollars)
WHEREAS, the Principal has entered into a certain written contract with Obligee, dated the _ 19th day of
August , 20.20, for South East Justice Courts and Adult Probation, 200095-DBB, which
contract is hereby referred to and made a part hereof as fully and to the same extent as if copied at length
herein.
NOW, THEREFORE, THE CONDITION OF THIS OBLIGATION IS SUCH, that if the said Principal shall
faithfully perform and fulfill all the undertakings, covenants, terms, conditions, and agreements of said contract
during the original term of said contract and any extension thereof, with or without notice to the Surety, and
during the life of any guaranty required under the contract, and shall also perform and fulfill all the
undertakings, covenants, terms, conditions, and agreements of any and all duly authorized modifications of
said contract that may hereafter be made, notice of which modifications to the Surety being hereby waived;
then the above obligation shall be void, otherwise to remain in full force and effect;
PROVIDED, HOWEVER, that this bond is executed pursuant to the provisions of Title 34, Chapter 2, Article
2, of the Arizona Revised Statutes, and all liabilities on this bond shall be determined in accordance with the
provisions of said Title, Chapter, and Article, to the extent as if it was copied at length herein. The prevailing
party in a suit on this bond shall be entitled to such reasonable attorney's fees as may be fixed by a judge of
the court.
Witness our hands this _24th__ day of _July 20_20_.
Johnson Carlier, LLC
PRINCIPAL SEAL
4
Arthur J. Gallagher & Co. BY: all fs oan
AGENT OF RECORD, STATE OF A# CA q
1160 Battery Street, Suite 360, S.F., CA 94111 Fidelity and Deposit Company of Maryland
AGENT ADDRESS SURETY
SEAL
BOND NUMBER: _ 9351262 BY:
South East Justice Courts and Adult Probation
Black, Attorney-in-Fact
Serial # 200095-DBB
Request for Bids - Design Bid Build Pg. #27
ACKNOWLEDGMENT
A notary public or other officer completing this
certificate verifies only the identity of the individual
who signed the document to which this certificate is
attached, and not the truthfulness, accuracy, or
validity of that document.
State of California
County of San Francisco )
on Auld Y4 wr before me, M. Moody, Notary Public
- \
(insert name and title of the officer)
personally appeared Virginia L. Black
who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are
subscribed to the within instrument and acknowledged to me that he/she/they executed the same in
his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the
person(s), or the entity upon behalf of which the person(s) acted, executed the instrument.
1
| certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing
paragraph is true and correct. oe oeeemrrerrrrremmanaas (
as M. MOODY
COMM. #2225134 3
NOTARY PUBLIC-CALIFORNIA @&
SAN FRANCISCO COUNTY
My Comm. Expires Jan. 8, 2022
Ton sot Seno
Bor
Ba
ay,
nN
WITNESS my hand and official seal. 3
Signatur Da Lack (Seal)
ZURICH AMERICAN INSURANCE COMPANY
COLONIAL AMERICAN CASUALTY AND SURETY COMPANY
FIDELITY AND DEPOSIT COMPANY OF MARYLAND
POWER OF ATTORNEY
KNOW ALL MEN BY THESE PRESENTS: That the ZURICH AMERICAN INSURANCE COMPANY, a corporation of the State of New
York, the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY, a corporation of the State of Illinois, and the FIDELITY
AND DEPOSIT COMPANY OF MARYLAND a corporation of the State of Illinois (herein collectively called the "Companies"), by
Robert D. Murray, Vice President, in pursuance of authority granted by Article V, Section 8, of the By-Laws of said Companies, which are
set forth on the reverse side hereof and are hereby certified to be in full force and effect on the date hereof, do hereby nominate, constitute,
and appoint Maureen O’CONNELL, Robert P. WRIXON, M MOODY, Betty L. TOLENTINO, Janet C. ROJO, Virginia L. BLACK,
Kevin RE, Susan M. EXLINE, Gillian BHASKARAN, T. LE, Brittany KAVAN, Julia ORTEGA, K. ZEROUNIAN, Douglas B.
BOWRING, Susan HECKER and Matthew KALAFATIS, of Lafayette and San Francisco, California, EACH, its true and lawful
agent and Attorney-in-Fact, to make, execute, seal and deliver, for, and on its behalf as surety, and as its act and deed: any and all bonds
and undertakings, and the execution of such bonds or undertakings in pursuance of these presents, shall be as binding upon said Companies,
as fully and amply, to all intents and purposes, as if they had been duly executed and acknowledged by the regularly elected officers of the
ZURICH AMERICAN INSURANCE COMPANY at its office in New York, New York., the regularly elected officers of the COLONIAL
AMERICAN CASUALTY AND SURETY COMPANY at its office in Owings Mills, Maryland., and the regularly elected officers of the
FIDELITY AND DEPOSIT COMPANY OF MARYLAND at its office in Owings Mills, Maryland., in their own proper persons.
The said Vice President does hereby certify that the extract set forth on the reverse side hereof is a true copy of Article V, Section 8, of
the By-Laws of said Companies, and is now in force.
IN WITNESS WHEREOF, the said Vice-President has hereunto subscribed his/her names and affixed the Corporate Seals of the said
ZURICH AMERICAN INSURANCE COMPANY, COLONIAL AMERICAN CASUALTY AND SURETY COMPANY, and
FIDELITY AND DEPOSIT COMPANY OF MARYLAND, this I Ith day of June, A.D. 2019.
ATTEST:
ZURICH AMERICAN INSURANCE COMPANY
COLONIAL AMERICAN CASUALTY AND SURETY COMPANY
FIDELITY AND DEPOSIT COMPANY OF MARYLAND
By: Robert D. Murray
Vice President
Denne 6 har
By: Dawn E. Brown
Secretary
State of Maryland
County of Baltimore
On this 11th day of June, A.D. 2019, before the subscniber, a Notary Public of the State of Maryland, duly commissioned and qualified, Robert D.
Murray, Vice President and Dawn E. Brown, Secretary of the Companies, to me personally known to be the individuals and officers described in and who
executed the preceding instrument, and acknowledged the execution of same, and being by me duly swom, deposeth and saith, that he/she is the said officer of
the Company aforesaid, and that the seals affixed to the preceding instrument are the Corporate Seals of said Companies, and that the said Corporate Seals and
the signature as such officer were duly affixed and subscribed to the said instrument by the authority and direction of the said Corporations.
IN TESTIMONY WHEREOF, I have hereunto set my hand and affixed my Official Seal the day and year first above written.
Comat nce... urn, J
Constance A. Dunn, Notary Public
My Commission Expires: July 9, 2023
EXTRACT FROM BY-LAWS OF THE COMPANIES
“Article V, Section 8, Attorneys-in-Fact. The Chief Executive Officer, the President, or any Executive Vice President or Vice President
may, by written instrument under the attested corporate scal, appoint attorneys-in-fact with authority to execute bonds, policies,
recognizances, stipulations, undertakings, or other like instruments on behalf of the Company, and may authorize any officer or any such
attorncy-in-fact to affix the corporate seal thereto: and may with or without cause modify of revoke any such appointment or authority at any
time."
CERTIFICATE
|, the undersigned. Secretary of the ZURICH AMERICAN INSURANCE COMPANY, the COLONIAL AMERICAN CASUALTY
AND SURETY COMPANY, and the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, do hereby certify that the foregoing
Power of Attorney is still in full force and effect on the date of this certificate: and I do further certify that Article V. Section 8, of the By-
Laws of the Companies is still in force.
This Power of Attorney and Certificate may be signed by facsimile under and by authority of the following resolution of the Board of
Directors of the ZURICH AMERICAN INSURANCE COMPANY at a meeting duly called and held on the 15th day of December 1998.
RESOLVED: "That the signature of the President or a Vice President and the attesting signature of a Secretary or an Assistant Secretary
and the Seal of the Company may be affixed by facsimile on any Power of Attorney...Any such Power or any certificate thercof bearing such
facsimile signature and seal shall be valid and binding on the Company."
This Power of Attorney and Certificate may be signed by facsimile under and by authority of the following resolution of the Board of
Directors of the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY at a mecting duly called and held on the Sth day of
May, 1994. and the following resolution of the Board of Directors of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND at a
meeting duly called and held on the 10th day of May, 1990.
RESOLVED: "That the facsimile or mechanically reproduced seal of the company and facsimile or mechanically reproduced signature
of any Vice-President, Secretary. or Assistant Secretary of the Company. whether made heretofore or hereafter, wherever appearing upon a
certified copy of any power of attorney issued by the Company, shall be valid and binding upon the Company with the same force and effect
as though manually affixed.
ys Aine na fREOF, | have hereunto subscribed my name and affixed the corporate seals of the said Companies,
this day of Ww
so NSU, CASI
By: Brian M. Hodges
Vice President
TO REPORT A CLAIM WITH REGARD TO A SURETY BOND, PLEASE SUBMIT A COMPLETE DESCRIPTION
OF THE CLAIM INCLUDING THE PRINCIPAL ON THE BOND, THE BOND NUMBER, AND YOUR CONTACT
INFORMATION TO:
Zurich Surety Claims
1299 Zurich Way
Schaumburg, IL 60196-1056
www. reports felaims@zurichna.com
800-626-4577
7/24/2020
—[
ACORD® CERTIFICATE OF LIABILITY INSURANCE neon
THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS
CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES
BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED
REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER.
IMPORTANT: If the certificate holder Is an ADDITIONAL INSURED, the policy(les) must have ADDITIONAL INSURED provislons or be endorsed.
If SUBROGATION IS WAIVED, subject to the terms and conditions of the pollcy, certaln pollcles may require an endorsement. A statement on
this certificate does not confer rights to the certificate holder in lieu of such endorsement(s).
PRODUCER NAME”. Certificate Department
Arthur J. Gallagher & Co. {wate P FAX
Insurance Brokers of CA, Inc. | LIC #0726293 (AIG. No, Ext); 415-391-1500 (AIG, No): 415-391-1882
1255 Battery Street #450 AppREess: GCSSFCerts@ajg.com
San Francisco CA 94111 INSURER(S) AFFORDING COVERAGE NAIC #
INSURER A: Zurich American Insurance Company 16535
INSURED . BIG-COR-01) insurer B : WCF Mutual Insurance Company 10033.
Johnson Carlier, L.L.C. i oe
738 S. 52nd Street iNsuRER Cc : American Guarantee and Liability Ins Co 26247
Tempe, AZ 85281 INSURER D : Indian Harbor Insurance Company 36940
INSURER E : XL Insurance America, Inc. 24554
insurer F: WCF National Insurance Company 40517
COVERAGES CERTIFICATE NUMBER: 1158499370 REVISION NUMBER:
THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD
INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS
CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
INSR ADDL|SUBR| POLICY EFF | POLICY EXP
LTR TYPE OF INSURANCE INsD | wyp POLICY NUMBER {MM/DD/VYYY) | (MM/DD/YYYY) LIMITS
A | X | COMMERCIAL GENERAL LIABILITY Y | Y | GLogs2903509 4/1/2020 11112021 | EACH OCCURRENCE $ 2,000,000
DAMAGE TO RENTED
CLAIMS-MADE OccuUR PREMISES (Ea occurrence) _| $ 1,000,000
MED EXP (Any one person) $10,000
PERSONAL & ADV INJURY _| $2,000,000
GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $4,000,000
POLICY Feo C] Loc PRODUCTS - COMP/OP AGG | $ 4,000,000
OTHER: s
COMBINED SINGLE LIMIT
A | AUTOMOBILE LIABILITY Y | Y | BAP982903609 4/1/2020 11112021 | FaMecident) $ 2,000,000
X | ANY AUTO BODILY INJURY (Per person) | $
OWNED SCHEDULED ,
ONE Ly [| scieo BODILY INJURY (Per accident)| $
X | HIRED. X | NON-OWNED PROPERTY DAMAGE $
| “ | AUTOS ONLY AUTOS ONLY | (Per accident)
$
c UMBRELLA LIAB X | occur Y | Y | SXS014093203 1/1/2020 11112021 | EACH OCCURRENCE $10,000,000
X | EXCESS LIAB CLAIMS-MADE AGGREGATE $ 10,000,000
DEO | | RETENTION $ $
g |WORKERS COMPENSATION Y | 2293327 [UTAH] anizo20 | vi2021 [x [EER | [ote
F | AND EMPLOYERS’ LIABILITY YIN 2301693 [AOS] 4/1/2020 1/112021
ANYPROPRIETOR/PARTNER/EXECUTIVE E.L. EACH ACCIDENT $ 1,000,000
OFFICER/MEMBEREXCLUDED? NIA
(Mandatory in NH) E.L. DISEASE - EA EMPLOYEE| $ 1,000,000
Ityes, describe under
DESCRIPTION OF OPERATIONS below E.L. DISEASE - POLICY LIMIT | $ 1,000,000
D | Professional/Pollution Liability CEO7420968 4/1/2020 11112021 | Each Claim/Agg $5,000,000
E | 2nd Layer Excess Y | Y | US00097558LI20A 1/1/2020 1/1/2021 | Each OcclAgg $15,000,000
DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space Is required)
Contract/Serial #: 200095-DBB | Johnson Carlier Job #: 20-026 | Contract Amount is $27,475,000.00
RE: The Southeast Justice Courts and Adult Probation - 222 EAST JAVELINE AVENUE MESA, AZ 85210
ADDITIONAL INSURED(S): Maricopa County its agents, representatives, officers, directors, officials, and employees for any claims arising out of Contractors
work or service.
The Producer will endeavor to mail 30 days written notice to the Certificate Holder named on the certificate if any policy listed on the certificate is cancelled prior
to the expiration date. Failure to do so shall impose no obligation or liability of any kind upon the Producer or otherwise alter the policy terms.
CERTIFICATE HOLDER CANCELLATION
SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE
THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN
ACCORDANCE WITH THE POLICY PROVISIONS.
Maricopa County
160 South 4th Avenue AUTHORIZED REPRESENTATIVE
Phoenix AZ 85003 Mag bt Wie Engg”
© 1988-2015 ACORD CORPORATION. All rights reserved.
ACORD 25 (2016/03) The ACORD name and logo are registered marks of ACORD