240017-CONTRACT.PDF

CONSTRUCTION CONTRACT - STIPULATED SUM 
(DESIGN-BID BUILD PROJECT) 
Clerk of the Superior Court SE Remodel
Office of Procurement Services 
Serial # 240017-DBB Contract # 
240017-DBB 
C-73-24-025-X-00
Project # 2855-23-0004 
Facilities Management Department 
MARICOPA COUNTY, ARIZONA

Clerk of the Superior Court SE Remodel
Serial # 240017-DBB
Request for Bids - Design Bid Build
Pg. # 2 
CONTRACT AGREEMENT 
THIS AGREEMENT, is made and entered into this 1st     day of November, 2023, by and between 
MARICOPA COUNTY, hereinafter called the COUNTY, acting by and through its BOARD OF 
SUPERVISORS, and 
TSG Constructors, LLC     hereinafter referred to as CONTRACTOR.  
The CONTRACTOR, for and in the consideration of the sum of 
Two Million, Four Hundred Seventy-Seven Thousand Dollars, and No Cents ($2,477,000.00) 
Unit prices, if any, are as follows: 
N/A_______________________________________________________ 
___________________________________________________________ 
___________________________________________________________ 
___________________________________________________________ 
___________________________________________________________ 
___________________________________________________________ 
to be paid to him by the COUNTY, in the manner and at the times hereinafter provided, and in consideration 
of the other covenants and agreements herein contained, hereby agrees for itself, its heirs, executors, 
administrators, successors, and assigns as follows: 
ARTICLE I - SCOPE OF WORK:  CONTRACTOR shall construct, and complete in a workmanlike 
manner and to the satisfaction of the FMD Director, a project for the Maricopa County FMD, designated 
as Serial # 240017-DBB, Clerk of the Superior Court SE Remodel, and furnish at its own cost and 
expense all necessary machinery, equipment, tools, apparatus, materials, and labor to complete the work in 
the most workmanlike manner according to the Plans and Specifications on file with the Maricopa County 
FMD, and listed herein, together with modifications of the same and other directions that may be made by 
the Maricopa County FMD as provided herein. 
ARTICLE II - CONTRACT DOCUMENTS: The Contract Documents (Invitation to Bid, Plans, 
Construction Special Provisions , Addenda issued prior to the execution of this Agreement, if any, General 
Conditions, General Requirements, Specifications, Maricopa Association of Governments (MAG) Standard 
Specifications and Uniform Standard Details, and the latest revisions thereto, Maricopa County Supplement 
to M.A.G. Uniform Standard Specifications for Public Works Construction, Bid, Affidavits, Performance 
Bond, Payment Bond, Certificates of Insurance, and Change Orders, if any,) are by this reference made a 
part of this Contract and shall have the same effect as though all of the same were fully inserted herein.  
This Contract, including the Contract Documents, represents the entire and integrated agreement between 
the parties and supersedes any prior negotiations, representations, or agreements, either written or oral.   
All amendments to this Contract shall be in writing and approved/signed by both parties. 
ARTICLE III - TIME FOR COMPLETION: CONTRACTOR further covenants and agrees at its own 
cost and expense, to do all work as aforesaid for the construction of said improvements and to completely 
construct the same and install the material therein, as called for by this agreement free and clear of all 
claims, liens, and charges whatsoever, in the manner and under the conditions specified and within the time, 
or times, stated in the Bid pamphlet and this Contract.  The date for the commencement of the work will be 
set by a Notice to Proceed issued by the Owner.  The time for completion will be measured from the date 
of commencement.   
ARTICLE IV - SUBSTANTIAL COMPLETION:  The CONTRACTOR shall achieve Substantial 
Completion of the work not later than 365 days from the date of commencement subject to adjustments to 
the Contract Time as provided for herein.  Final Completion shall be achieved in 30 days after Substantial 
Completion, subject to adjustments to the Contract Time as provided for herein.

Clerk of the Superior Court SE Remodel  
 
 
 
 
Serial # 240017-DBB 
Request for Bids - Design Bid Build 
 
 
 
 
 
Pg. # 3 
 
ARTICLE V - PAYMENTS:  For and in consideration of the satisfactory performance of the work as set 
forth in the Contract Documents, which are a part hereof, and in accordance with the directions of the 
COUNTY, through its Design Professional, the COUNTY agrees to pay the said CONTRACTOR the 
amount earned, (and, if unit prices are applicable the sum due as computed from actual quantities of work 
performed and accepted, or materials furnished at the unit bid price on the Bid made a part hereof) and to 
make such payment in accordance with the requirements of A.R.S. § 34-221, as amended.  
CONTRACTOR agrees to discharge its obligations and to make payments to its subcontractors and 
suppliers in accordance with A.R.S. § 32-1129, the Prompt Pay Act.    
 
ARTICLE VI - LIQUIDATED DAMAGES:   
 
Liquidated damages are provided for in this Contract, as explained in the General Conditions to this 
Contract.   
 
Upon failure of Contractor to substantially complete the Project within the specified period of time, plus 
approved time extensions, Contractor shall pay to OWNER the maximum sum of Eight Hundred Eighty-
Eight  Dollars ($888.00) for each calendar day after the time specified in Article IV above.  The actual 
liquidated damages cost, including back-up will be forwarded to the Contractor.  In any case the actual 
liquidated damages amount shall not exceed the maximum sum indicated above.  After Substantial 
Completion, should Contractor fail to complete the remaining work within the time specified in Article IV 
above, plus approved time extensions thereof, for completion and readiness for Final Completion, 
Contractor shall pay to OWNER the maximum sum of Eight Hundred Eighty-Eight Dollars ($888.00) for 
each calendar day after the time specified in Article IV above.  The actual liquidated damages cost, 
including back-up will be forwarded to the Contractor.  In any case the actual liquidated damages amount 
shall not exceed the maximum sum indicated above.  These amounts are not penalties but are liquidated 
damages to OWNER for its inability to obtain full beneficial occupancy of the Project.   
 
ARTICLE VII - TERMINATION:  The COUNTY hereby gives notice that pursuant to A.R.S. § 38-511 
A, this contract may be canceled without penalty or further obligation within three years after execution if 
any person significantly involved in initiation, negotiation, securing, drafting or creating the contract on 
behalf of the COUNTY is, at any time while the contract or any extension of the contract is in effect, an 
employee or agent of any other party to the contract in any capacity or a Contractor to any other party of 
the contract with respect to the subject matter of the contract.  Cancellation under this section shall be 
effective when written notice from the COUNTY is received by all of the parties to the contract.  In 
addition, the COUNTY may recoup any fee or commission paid or due to any person significantly involved 
in initiation, negotiation, securing, drafting or creating the contract on behalf of the COUNTY from any 
other party to the contract arising as a result of the contract. 
 
ARTICLE VIII - TERMINATION FOR DEFAULT:  If the CONTRACTOR should be adjudged 
bankrupt or should make a general assignment for the benefit of its creditors, or if a receiver should be 
appointed on account of its insolvency, the COUNTY may terminate the Contract.  If the CONTRACTOR 
should repeatedly refuse or should fail, except in cases for which extension of time is provided, to provide 
enough properly skilled workers or proper materials, or repeatedly disregard laws and ordinances, or fail to 
meet deadlines or not proceed with work, or otherwise be guilty of a material breach of any provision of 
this Contract, then the COUNTY may terminate the Contract.  Prior to termination of the Contract, the 
COUNTY shall give the Contractor fourteen (14) calendar day’s written notice.  Upon receipt of such 
termination notice, the Contractor shall be allowed fourteen (14) calendar days to cure such deficiencies.  
In the event of termination under this paragraph, all documents, data, and reports prepared by the 
CONTRACTOR under this Contract shall become the property of and be delivered to the COUNTY upon 
demand.  Sums claimed due by the CONTRACTOR shall not be paid until the Work has been completed 
and such payment shall only be made after deduction damages caused by the default.  In the event a 
termination for default is determined to be without cause, it shall be deemed to be a termination for 
convenience.

Clerk of the Superior Court SE Remodel  
 
 
 
 
Serial # 240017-DBB 
Request for Bids - Design Bid Build 
 
 
 
 
 
Pg. # 4 
ARTICLE IX - TERMINATION FOR CONVENIENCE: The COUNTY reserves the right to terminate 
the Contract, in whole or in part at any time, when in the best interests of the COUNTY without penalty or 
recourse.  Upon receipt of the written notice, the CONTRACTOR shall immediately stop all work, as 
directed in the notice, notify all subcontractors of the effective date of the termination and minimize all 
further costs to the COUNTY.  In the event of termination under this paragraph, all documents, data and 
reports prepared by the CONTRACTOR under the Contract shall become the property of and be delivered 
to the COUNTY upon demand.  The CONTRACTOR shall be entitled to receive just and equitable 
compensation for work in progress, work completed and materials accepted before the effective date of the 
termination.  No lost “future profits” will be paid to the CONTRACTOR. 
 
ARTICLE X - SUSPENSION OF WORK: The Owner may order the CONTRACTOR, in writing, to 
suspend, delay, or interrupt all or any part of the work of this Contract for the period of time that the Owner 
determines appropriate for the convenience of the COUNTY. 
 
If the performance of all or any part of the work is, for an unreasonable period of time, suspended, delayed, 
or interrupted (1) by an act of the Owner in the administration of this Contract, or (2) by the Owner’s failure 
to act within the time specified in this Contract (or within a reasonable time if not specified), an adjustment 
shall be made for any increase in the cost of performance of the Contract (excluding profit) caused by the 
unreasonable suspension, delay, or interruption, and the contract will be modified in writing accordingly.  
However, no adjustment shall be made under this provision for any suspension, delay, or interruption to the 
extent that performance would have been so suspended, delayed, or interrupted by any other cause, 
including the fault of negligence of the Contractor, or for which an equitable adjustment is provided (or 
excluded) under any other term or condition of this Contract. 
 
A claim under this provision shall not be allowed: 
 
For any costs incurred more than 14 days before the CONTRACTOR has notified the Owner in writing of 
the act or failure to act involved (but this requirement shall not apply as to a claim resulting from a 
suspension order); and unless the claim, in an amount stated, is made in writing as soon as practicable after 
the termination of the suspension, delay, or interruption, but not later than the date of final payment under 
the Contract. 
 
ARTICLE XI - NEGOTIATION CLAUSE: Recovery of damages related to expenses incurred by 
CONTRACTOR for a delay for which the COUNTY is responsible, which is unreasonable under the 
circumstances and which was not within the contemplation of the parties to the contract, shall be negotiated 
between CONTRACTOR and the COUNTY.  This provision shall be construed so as to give full effect 
to any provision in the contract which requires notice of delays, provides for neutral evaluation and 
arbitration or other procedure for settlement, or provides for liquidated damages. 
 
ARTICLE XII - COMPLIANCE WITH LAWS:  CONTRACTOR is required to comply with all 
Federal, State and local ordinances and regulations.   CONTRACTOR'S signature on this contract certifies 
compliance with the provisions of the I-9 requirements of the Immigration Reform Control Act of 1986 for 
all personnel that CONTRACTOR and any subcontractors employ to complete this project.  The 
COUNTY will perform in accordance with the provisions of the Maricopa County Procurement Code. 
 
The CONTRACTOR warrants that it is in compliance with A.R.S. §41-4401 (regarding immigration) and 
further acknowledges: 
 
(1) 
The CONTRACTOR and its sub-contractors, if any, warrant their compliance with all 
federal immigration laws and regulations that relate to their employees and their 
compliance with A.R.S. §23-214, subsection A; (on e-verification, etc.).  After December 
31, 2007, every employer, after hiring an employee, shall verify the employment eligibility 
of the employee through the e-verify program and shall keep a record of the verification 
for the duration of the employee’s employment or at least three years, whichever is longer. 
 
(2) 
A breach of a warranty under subsection 1 above, shall be deemed a material breach of the 
contract that is subject to penalties up to and including termination of the Contract;

Clerk of the Superior Court SE Remodel 
Serial # 240017-DBB 
Request for Bids - Design Bid Build 
Pg. # 5 
(3)
The COUNTY retains the legal right to inspect the papers of any CONTRACTOR or sub-
contractor employee who works on the contract to ensure that the CONTRACTOR or sub-
contractor is complying with the warranty provided under subsection 1 above and that the
CONTRACTOR agrees to make all papers and employment records of said employee(s)
available during normal working hours in order to facilitate such an inspection.
(4)
Nothing herein shall make any CONTRACTOR or sub-contractor an agent or employee
of the COUNTY.
ARTICLE XIII - SBE PROGRAM:  It is Maricopa County’s policy to endeavor to ensure in every way 
possible that small business participation firms shall have the opportunity to provide professional services, 
materials, and contractual services to the County in a nondiscriminatory manner.   
ARTICLE XIV – SBE PARTICIPATION PAY FORM:  This form (copy attached) is to be submitted 
with each pay application or invoice.  Any pay application or invoice without this form attached is subject 
to rejection as not being a completed pay application or invoice pursuant to the terms of the contract. 
ARTICLE XV - ANTI-DISCRIMINATION PROVISION:  CONTRACTOR agrees not to 
discriminate against any employee or applicant for employment because of race, age, color, religion, sex, 
disability, or national origin, and further agrees not to engage in any unlawful employment practices. 
CONTRACTOR further agrees to insert the foregoing provision in all subcontracts hereunder.   
CONTRACTOR agrees to comply with all provisions and requirements of Arizona Executive Order 2009-
09 including flow down of all provisions and requirements to any subcontractors. Executive Order 2009-
09 supersedes Executive order 99-4 and amends Executive order 75-5 and may be viewed and downloaded 
at 
the 
Governor 
of 
the 
State 
of 
Arizona’s 
website 
http://www.azgovernor.gov/dms/upload/EO_2009_09.pdf  which is hereby incorporated into this contract 
as if set forth in full herein. During the performance of this contract, CONTRACTOR shall not discriminate 
against any employee, client or any or any other individual in any way because of that person’s age, race, 
creed, color, religion, sex, disability or national origin. 
ARTICLE XVI – INFLUENCE:  As prescribed in MC1-1203 of the Maricopa County Procurement Code, 
any effort to influence an employee or agent to breach the Maricopa County Ethical Code of Conduct, or 
any unethical conduct, may be grounds for Disbarment or Suspension under MC1-902.   
An attempt to influence includes, but is not limited to: 
(1)
A Person offering or providing a gratuity, gift, tip, present, donation, money, entertainment
or educational passes or tickets, or any type valuable contribution or subsidy;
(2)
That is offered or given with the intent to influence a decision, obtain a contract, garner
favorable treatment, or gain favorable consideration of any kind.
If a Person attempts to influence any employee or agent of Maricopa County, the Chief Procurement 
Officer, or his designee, reserves the right to seek any remedy provided by the Maricopa County 
Procurement Code, any remedy in equity or in the law, or any remedy provided by this contract.   
ARTICLE XVII – AMENDMENTS:  All amendments to this Contract shall be in writing and 
approved/signed by both parties.  Maricopa County Office of Procurement Services shall be responsible for 
approving all amendments for Maricopa County.

Clerk of the Superior Court SE Remodel  
 
 
 
 
Serial # 240017-DBB 
Request for Bids - Design Bid Build 
 
 
 
 
 
Pg. # 6 
ARTICLE XVIII – ALTERNATIVE DISPUTE RESOLUTION 
 
See Exhibit A for Alternative Dispute Resolution. 
 
ARTICLE XIX -- UNIFORM ADMINISTRATIVE REQUIREMENTS: 
 
When applicable and by entering into this Contract the Contractor agrees to comply with all applicable 
provisions of Title 2, Subtitle A, Chapter II,  PART 200—UNIFORM ADMINISTRATIVE 
REQUIREMENTS, COST PRINCIPLES, AND AUDIT REQUIREMENTS FOR FEDERAL AWARDS 
contained in Title 2 C.F.R. § 200 et seq. 
 
ARTICLE XX -- FORCED LABOR 
 
By submitting a bid for this solicitation and/or entering into a contract as a result of this solicitation, contractor 
agrees to comply with all applicable portions of Arizona Revised Statutes Section 35-394. Contracting; 
procurement; prohibition; written certification; remedy; termination; exception; definitions. 
 
Contractor certifies that it does not currently, and agrees for the duration of the contract, that it will not use:  
 
The forced labor of ethnic Uyghurs in the People’s Republic of China. 
 
Any goods or services produced by the forced labor of ethnic Uyghurs in the People’s Republic of China.  
 
Any contractors, subcontractors or suppliers that use the forced labor or any good or services produced by the 
forced labor of ethnic Uyghurs in the People’s Republic of China. 
 
If contractor becomes aware during the term of the agreement that contractor is not in compliance with this 
paragraph, the contractor shall notify the County within five business days after becoming aware of the 
noncompliance. If the contractor fails to provide a written certification to the County that the contractor has 
remedied the noncompliance within 180 days after notifying the County of its noncompliance, then the 
agreement terminates, except that if the agreement termination date occurs before the end the 180 day period, 
the agreement terminates on the agreement termination date. 
 
ARTICLE XXI -- WRITTEN CERTIFICATION PURSUANT TO A.R.S. § 35-393.01 
 
If vendor engages in for-profit activity and has 10 or more employees, and if this agreement has a value of 
$100,000 or more, vendor certifies it is not currently engaged in, and agrees for the duration of this 
agreement to not engage in, a boycott of goods or services from Israel. This certification does not apply to 
a boycott prohibited by 50 U.S.C. § 4842 or a regulation issued pursuant to 50 U.S.C. § 4842.

IN WITNESS WHEREOF, the parties hereto have executed this Agreement on the day and date first 
above written, in counterparts, each of which shall, without proof or accounting for the other 
counterparts, be deemed an original contract. 
Clerk of the Superior Court SE Remodel 
240017-DBB 
October 20,2023 
~
m · a (S1 
Date 
Stanley S. Showalter 
90-0275459 
Printed Name 
Federal Tax Identification Number 
Manager 
ROC 204114 
Title 
Arizona Contractor's License Number 
90924 
Vendor Tem1s 
NIGP Commodity Code (Adnntage) 
RECOMMENDED BY: 
COUNTY OF MARICOPA, ARIZONA 
ACCEPTED AND APPROVED: 
Depa1tment Head 
Date 
LEGAL REVIEW 
Approved as to fonn and within the powers and 
authority granted under the laws of the State of 
Arizona to Maricopa County. 
By: 
Deputy County Attorney 
Date: -------------
Clerk of the Superior Court SE Remodel 
Request for Bids- Design Bid Build 
Chainrnm, Board of Supervisors 
Date 
ATTEST: 
Clerk of the Board 
Date 
Serial # 2-10017-DBB 
Pg. # 7 
Net 30

Clerk of the Superior Court SE Remodel  
 
 
 
 
Serial # 240017-DBB 
Request for Bids - Design Bid Build 
 
 
 
 
 
Pg. # 8 
EXHIBIT A - ALTERNATIVE DISPUTE RESOLUTION 
 
1.1 
Scope.  Notwithstanding anything to the contrary provided elsewhere in the Contract, the 
alternative dispute resolution (“ADR”) process provided herein shall be the exclusive means for 
resolution of claims or disputes arising under or related to the Contract, the interpretation thereof 
or the performance or breach by any party thereto, including but not limited to original claims or 
disputes asserted as cross claims, counterclaims, third party claims or claims for indemnity or 
subrogation, in any threatened or ongoing litigation or arbitration with third parties, if such disputes 
involve parties to contracts containing this ADR provision.  No changes can be made to this process 
without the mutual assent of the County and the claimant.  The parties have structured this 
procedure with the goal of providing for the prompt, efficient and final resolution of all disputes 
falling within the purview of this ADR process. 
 
1.2 
Meeting of Principals.  When a claim is made or a dispute (hereafter “dispute”) as described in 
Paragraph 1.2 arises, senior representatives of the County and the claimant will meet personally 
within ten (10) business days to discuss the dispute and attempt to resolve it.  If, after good faith 
efforts, resolution is not achieved, the dispute will proceed to mediation. 
 
1.3 
Qualifications of Mediator and Arbitrators.  Any person selected as mediator or arbitrator, either 
as single arbitrator as a member or Chair of the arbitration panel, shall be a member of the State 
Bar of Arizona and have experience in construction law. 
 
1.4 
Mediation.  If the parties have been unable to resolve the dispute after a meeting of principals, the 
parties may enter into mediation.  The parties shall jointly select a mediator.  The parties may 
mutually agree to waive mediation and proceed directly to arbitration.  If the mediation process is 
requested by either party, the mediation period shall be informal and shall not exceed sixty (60) 
calendar days from the selection of the mediator.  During the mediation process either party may 
terminate mediation on written notice to the other party and the mediator. 
 
1.5 
Binding Arbitration Procedure.  The following binding arbitration procedure shall serve as the 
exclusive method to resolve a dispute if mediation is unsuccessful, if mediation has been waived 
by the parties, or if a party requests arbitration during the mediation process.  Except as provided 
in Section 1.7.5 and 1.7.9, the decision of the arbitrator or arbitrator panel is final and binding on 
the parties and not subject to further judicial review. 
 
1.5.1 
A party requesting binding arbitration shall notify the other party of their demand for 
arbitration in writing within seven (7) calendar days of (1) the failure of mediation; (2) 
waiver of mediation;  or (3) of the party’s demand to terminate mediation. 
 
1.5.2 
If the Contractor requests arbitration it shall post a cash bond with the arbitrator in an 
amount agreed upon by the parties or, in the event of no agreement, the arbitrator shall 
establish the amount of the cash bond to defray the cost of the arbitration and the proceeds 
from the bond shall be allocated in accordance with paragraph 1.7.7.  The bond must be in 
the full amount agreed upon or as established by the Arbitrator to pay the potential cost of 
the full arbitration proceeding.  The bond must be posted with and received by the arbitrator 
within five (5) calendar days after the demand for arbitration. 
 
1.5.3 
Disputes involving less than $200,000 shall be heard by one single arbitrator chosen by 
agreement of the parties.  If the parties cannot agree on the single arbitrator, then the parties

Clerk of the Superior Court SE Remodel  
 
 
 
 
Serial # 240017-DBB 
Request for Bids - Design Bid Build 
 
 
 
 
 
Pg. # 9 
shall each submit two names to a Judge designated by Maricopa County who shall select 
the single arbitrator. 
 
1.5.4 
For disputes in excess of $200,000, the arbitration panel shall consist of three arbitrators:  
the County's appointed arbitrator, the Contractor's appointed arbitrator and a third arbitrator 
who shall be selected by the parties' arbitrators and serve as the Chair of the arbitration 
panel. 
 
1.5.5 
The arbitration is to be convened and administered under the Revised Uniform Arbitration 
Act (“RUAA”) (A.R.S. § 12-3001 et seq.) and the American Arbitration Association 
Construction Rules shall serve as a guideline for proceedings, thus as a supplement to the 
RUAA. 
 
1.6 
Expedited Hearing.  Any party can request the single arbitrator or the Chair of the arbitration panel 
to set an expedited hearing. If the single arbitrator or the Chair of the arbitration panel determines 
that the circumstances justify it, the single arbitrator or the Chair of the arbitration panel will 
arrange for scheduling of the arbitration at the earliest possible date.  In any event, the hearing of 
any dispute not expedited will commence as soon as practical but in no event later than thirty (30) 
calendar days after notification of request for arbitration having been received.  This deadline can 
be extended only with the consent of all the parties to the dispute, or by decision of the single 
arbitrator or the Chair of the arbitration panel upon a showing of good cause.  
 
1.7 
Procedure.  The single arbitrator or the arbitration panel will conduct the hearing in such a manner 
that will resolve disputes in a prompt, cost efficient manner giving regard to the rights of all parties.  
Each party shall supply to the single arbitrator or arbitration panel a written pre-hearing statement 
which shall contain a brief statement of the nature of the claim or defense, a list of witnesses and 
exhibits, a brief description of the subject matter of the testimony of each witness who will be called 
to testify, and an estimate as to the length of time that will be required for the arbitration hearing. 
The single arbitrator or the Chair of the arbitration panel shall determine the nature and scope of 
discovery, if any, and the manner of presentation of relevant evidence consistent with deadlines 
provided herein, and the parties’ objective that disputes be resolved in a prompt and efficient 
manner.  No discovery may be had of any materials or information for which a privilege is 
recognized by Arizona law. The single arbitrator or the Chair upon proper application shall issue 
such orders as may be necessary and permissible under law to protect confidential, proprietary or 
sensitive materials or information from public disclosure or other misuse.  Any party may make 
application to the Maricopa County Superior Court to have a protective order entered as may be 
appropriate to confirm or enforce such orders of the Chair. 
 
1.7.1 
Hearing Days.  In order to effectuate parties’ goals, the hearing once commenced, will 
proceed from working day to working day until concluded, absent a showing of good cause. 
 
1.7.2 
Award.  The single arbitrator shall within ten (10) calendar days of the conclusion of a 
hearing issue an award.  The arbitration panel shall, within ten (10) calendar days from the 
conclusion of any hearing, by majority vote, issue its award.  The award shall include an 
allocation of fees and costs pursuant to 1.7.7 herein.  The award is to be in accordance with 
the Contract and the law of the State of Arizona. 
 
1.7.3 
Scope of Award.  Regardless of the provisions of the RUAA, the arbitration panel shall be 
without authority to award punitive damages, and any such punitive damage award shall 
be void. If an award is made against any party in excess of one hundred thousand dollars 
($100,000), exclusive of interest, arbitration fees, costs and attorneys’ fees, it shall be

Clerk of the Superior Court SE Remodel  
 
 
 
 
Serial # 240017-DBB 
Request for Bids - Design Bid Build 
 
 
 
 
 
Pg. # 10 
supported by written findings of fact, conclusions of law and a statement as to how damages 
were calculated. 
 
1.7.4 
Jurisdiction.  The arbitration panel shall not be bound for jurisdictional purposes by the 
amount asserted in any party’s claim, but shall conduct a preliminary hearing into the 
question of jurisdiction over the claim as regards its amount upon application of any party 
at the earliest convenient time, but not later than the commencement of the arbitration 
hearing.  If the dispute is determined to involve less than $200,000, the arbitration shall 
continue before the Neutral Arbitrator as a single arbitrator, with the party appointed 
arbitrators being excused. 
 
1.7.5 
Entry of Judgment.  As provided in the RUAA, any party can make application to the 
Maricopa County Superior Court for confirmation of an award, and for entry of judgment 
on it. 
 
1.7.6 
Severance and Joinder.  To reduce the possibility of inconsistent adjudications, the 
Mediator or the single arbitrator or arbitration panel, may: (i) at the request of any party, 
join and/or sever parties, and/or claims arising under other contracts containing this ADR 
provision, and (ii) the Mediator, on his own authority, or the single arbitrator or arbitration 
panel may, on its own authority, join or sever parties and/or claims subject to this ADR 
process as deemed necessary for a just resolution of the dispute, consistent with the parties’ 
goal of the prompt and efficient resolution of disputes, provided; however, that the A/E, 
Owner and Project Professionals shall not be joined as a party to any claim made by a 
Contractor.  Nothing herein shall create the right by any party to assert claims against 
another party not arising under or related to the Contract or not recognized under the 
substantive law as applicable to the dispute.  Neither the Mediator nor the single arbitrator 
or arbitration panel is authorized to join to the proceeding parties not in privity with the 
County.  The CONTRACTOR cannot be joined to any pending arbitration proceeding, 
without CONTRACTOR’s express written consent and unless CONTRACTOR is given 
the opportunity to participate in the selection of the single arbitrator or non-County 
appointed arbitrator. 
 
1.7.7 
Fees and Costs.  Each party shall bear its own fees and costs in connection with any 
informal hearing before the mediation.  All fees and costs associated with any arbitration 
before the single panel or arbitration panel, including without limitation the arbitrator fees, 
and the prevailing party’s reasonable attorneys’ fees, expert witness fees and costs, will be 
paid by the non-prevailing party, except as provided for herein.  In the event that 
CONTRACTOR is the non-prevailing party, all fees and costs as noted above shall first be 
paid out of the bond posted with the arbitrator.  In no event shall the CONTRACTOR’s 
obligation to pay fees and costs be limited to the amount of the bond posted herein.  In no 
event shall any arbitrator’s hourly fees be awarded in an amount in excess of $250 per hour 
and (i) costs shall not include any travel expenses in excess of mileage at the rate paid by 
Maricopa County, not to exceed a one way trip of 150 miles, and (ii) all travel expenses, 
including meals, shall be reimbursed pursuant to the travel policy of Maricopa County in 
effect at the time of the hearing.  The determination of prevailing and non-prevailing 
parties, and the appropriate allocation of fees and costs, will be included in the award by 
the single arbitrator or arbitration panel. 
 
1.7.8 
Confidentiality.  Any proceeding initiated under this ADR provision shall be deemed 
confidential to the maximum extent allowed by Arizona law and, except for disclosures to 
a party’s attorneys or accountants, no party shall make any disclosure related to the

Clerk of the Superior Court SE Remodel 
Serial # 240017-DBB 
Request for Bids - Design Bid Build 
Pg. # 11 
disputed matter or to the outcome of any proceeding except to the extent required by law, 
or to seek interim equitable relief, or to enforce an agreement reached by the parties or an 
award made hereunder.  This provision does not affect the County’s right to inform the 
County Supervisors of the dispute. 
1.7.9 
Equitable Litigation.  Notwithstanding any other provision of ADR to the contrary, any 
party can petition the Maricopa County Superior Court for interim equitable relief as may 
become necessary to preserve the status quo and prevent immediate and irreparable harm 
to a party or to the Project pending resolution of a dispute pursuant to ADR provided herein.  
No court may order any permanent injunctive relief except as may be necessary to enforce 
an order entered by the arbitration panel.  The fees and costs incurred in connection with 
any such equitable proceeding shall be determined and assessed in ADR. 
1.7.10 Change Order.  Any award in favor of the CONTRACTOR against the County or in favor 
of the County against the CONTRACTOR shall be reduced to a Change Order and 
executed by the parties in accordance with the award and the provisions of the Contract or 
a settlement agreement as appropriate. 
1.7.11 Merger and Bar.  Any claim asserted pursuant to this ADR process shall be deemed to 
include all claims, demands, and requests for compensation for costs and losses or other 
relief, including the extension of the Contract performance period which reasonably should 
or could have been brought against any party that was or could have been brought into this 
ADR process, with respect to the subject claim.  The arbitration panel shall apply legal 
principles commonly known as merger and bar to deny any claim or claims against any 
party regarding which claim or claims recovery has been sought or should have been sought 
in a previously adjudicated claim for an alleged cost, loss, breach, error, or omission.  
1.8 
Inclusion in Other Contracts.  The CONTRACTOR shall cooperate with the County in efforts to 
include this ADR provision in all other Project contracts. 
END OF EXHIBIT

Maricopa County 
Bid 240017-DBB 
Attachment 1- STATUTORY PAYMENT BOND 
PURSUANT TO TITLE 34 CHAPTER 2, ARTICLE 2, OF THE ARIZONA REVISED STATUTES 
(Penalty of this bond must be 100 percent of the contract amount) 
KNOW ALL MEN BY THESE PRESENTS: 
That, TSG Constructors, LLC 
(h~reinafter called the Principal), as Principal, and 
Travelers Casualty and Surety Company ofb,~ation organized and existing under the laws of the State of 
Connecticut 
with its principal office in the City of ~H=a=rtf=o~r=d ______ _ 
(hereinafter called the Surety), as Su~eitv, are held and firrnly bound unto Maricopa County (hereinafter called 
the Obl·1gee) ,·n the amo nt of Two M1llu:i'n Four Hundred SeventySeven 
DOLLARS ($ 2 477 000 00 
) ~ 
, 
u 
Ib011saod aod DDt1QD** 
, 
, 
. 
., ,or 
the payment whereof, the said Principal and Surety bind themselves, and their heirs, administrators, executors, 
successors and assigns, jointly and severally, firmly by these presents. 
WHEREAS, the Principal has entered into a certain written contract with the Obligee, dated the 1st 
day 
of November 
, 20 23 , for Clerk of the Superior Court SE Remodel, Serial #240017-
DBB, which contract is hereby referred to and made a part hereof as fully and to the same extent as if copied 
at length herein. 
NOW, THEREFORE, THE CONDITION OF THIS OBLIGATION IS SUCH, that if the said Principal promptly 
pays all monies due to all persons supplying labor or materials to the Principal or the Principal's subcontractors 
in the prosecution of the work provided for in the contract, this obligation is void. Otherwise, it remains in full 
force and effect. 
PROVIDED, HOWEVER, that this bond is executed pursuant to the provisions of Title 34, Chapter 2, Article 2, 
of the Arizona Revised Statutes (A.RS.), and all liabilities on this bond shall be determined in accordance with 
the provisions, conditions, and limitations of Title 34, Chapter 2, Article 2, A.RS., to the same extent as if it 
was copied at length in this agreement. 
The prevailing party in a suit on this bond shall recover as a part of the judgment reasonable attorney's fees 
that may be fixed by the court or a judge thereof. 
Witness our hands this 1st 
Constructors Bonding, Inc. 
AGENT OF RECORD, STATE OF AZ 
day of November 
, 20-=2=3 __ _ 
TSG Constructors LLC 
PRINCIPAL 
SEAL 
7220 N. 16th Street, Bldg K, Phoenix, AZ 85020 
AGENT ADDRESS 
Travelers Casualty and Surety-Cpmpany of America 
''-
~ 
'--,_,,,.,·,~- .... 
~ ~--
BOND NUMBER: 107854459 
----------
Clerk of the Superior Court SE Remodel 
Re_quest for Bids - Design Bid Build 
9/6/2023 3:32 P1171 
Serial# 240017-DBB 
Pg. #27 
p.892

Maricopa County 
Bid 240017-DBB 
Attachment J - STATUTORY PERFORMANCE BOND 
PURSUANT TO TITLE 34 CHAPTER 2, ARTICLE 2, OF THE ARIZONA REVISED STATUTES (A.RS.) (Penalty of 
this bond must be 100 percent of the contract amount) 
KNOW ALL MEN BY THESE PRESENTS: 
That, TSG Constructors, LLC 
(hereinafter called the Principal), as Principal, and 
Travelers Casualty and Surety Company of America 
a 
corporation 
organized and existing under the laws of the State of 
Connecticut 
with its principal office in 
the City of Hartford 
(hereinafter called the Suretv) _as Surety, are held and firmly 
bound unto Maricopa County. (hereinafter called the Obligee) in the amount of ~.f1i~W1fn~u6J&88Wd Seventy Seven 
DOLLARS ($2,477,000.00 
). for the payment whereof, the said Principal and Surety bind themselves, 
and their heirs, administrators, executors, successors and assigns, jointly and severally, firmly by these presents. 
WHEREAS, the Principal has entered into a certain written contract with Obligee, dated the 1st 
day of November 
, 20 23 
for Clerk of the Superior Court SE Remodel, Serial #240017-DBB, which contract is hereby 
referred to and made a part hereof as fully and to the same extent as if copied at length herein. 
NOW, THEREFORE, THE CONDITION OF THIS OBLIGATION IS SUCH, that if the said Principal shall faithfully 
perform and fulfill all the undertakings, covenants, terms, conditions, and agreements of said contract during the 
original term of said contract and any extension thereof, with or without notice to the Surety, and during the life of any 
guaranty required under the contract, and shall also perform and fulfill all the undertakings, covenants, terms, 
conditions, and agreements of any and all duly authorized modifications of said contract that may hereafter be made, 
notice of which modifications to the Surety being hereby waived; then the above obligation shall be void, otherwise to 
remain in full force and effect; 
PROVIDED, HOWEVER, that this bond is executed pursuant to the provisions of Title 34, Chapter 2, Article 2, of the 
Arizona Revised Statutes (A.RS.), and all liabilities on this bond shall be determined in accordance with the provisions 
of said Title, Chapter, and Article, to the extent as if it was copied at length herein. The prevailing party in a suit on this 
bond shall be entitled to such reasonable attorney's fees as may be fixed by a judge of the court. 
Witness our hands this ...... 1=st,....__ day of Novemb~20 23 . 
Constructors Bonding, Inc. 
AGENT OF RECORD, STATE OF AZ 
7220 N. 16th Street. Bldg K, Phoenix, AZ 85020 
AGENT ADDRESS 
BONDNUMBER: 107854459 
----------
Clerk of the Superior Court SE Remodel 
Re_q_uest for Bids - Design Bid Build 
9/6/2023 3:32 PIVI 
TSG Constructors, LLC 
PRINCIPAL 
SEAL 
B~~ 
Travelers Casualty and Surety ~~pany-_efAtrlei:!ca 
SURETY 
<c' --"- :----· SEAL \ ~\ 
~- .- ....... _,"' ~ - - : : \ 
\., '°"'-·\..-.... 
~ -- ~ 
Serial# 240017-DBB 
Pg. #28 
p.893

TRAVELERs'f"' 
Travelers Casualty and Surety Company of America 
Travelers Casualty and Surety Company 
St. Paul Fire and Marine Insurance Company 
POWER OF ATTORNEY 
KNOW ALL MEN BY THESE PRESENTS: That Travelers Casualty and Surety Company of America, Travelers Casualty and Surety Company, and 
St. Paul Fire and Marine 
Insurance Company are corporations duly organized under the laws of the State of Connecticut (herein 
collectively called the "Companies"), and that the Companies do hereby make, constitute and appoint Jennifer Castillo 
of 
PHOENIX 
, Arizona 
, their true and 
lawful Attorney(s)-in-Fact to sign, 
execute, 
seal and 
acknowledge any and 
all 
bonds, 
recognizances, conditional undertakings and other writings obligatory in the nature thereof on behalf of 
the Companies in their business of guaranteeing the fidelity of persons, 
guaranteeing 
the performance of contracts and executing or 
guaranteeing bonds and undertakings required or permitted in any actions or proceedings allowed by law. 
IN WITNESS WHEREOF, the Companies have caused this instrument to be signed, and their corporate seals to be hereto affixed, this 21st day of April, 
2021. 
State of Connecticut 
City of Hartford ss. 
On this the 21st day of April, 2021, before me personally appeared Robert L. Raney, who acknowledged himself to be the Senior 
Vice President of each of the Companies, and that he, as such, being authorized so to do, executed the foregoing instrument for the 
purposes therein contained by signing on behalf of said Companies by himself as a duly authorized officer. 
IN WITNESS WHEREOF, I hereunto set my hand and official seal. 
My Commission expires the 30th day of June, 2026 
© 
Anna P. Nowik, Notary Public 
This Power of Attorney is granted under and by the authority of the following resolutions adopted by the Boards of Directors of each of 
the Companies, which resolutions are now in full force and effect, reading as follows: 
RESOLVED, that the Chairman, the President, any Vice Chairman, any Executive Vice President, any Senior Vice President, any Vice 
President, any Second Vice President, the Treasurer, any Assistant Treasurer, the Corporate Secretary or any Assistant Secretary may appoint 
Attorneys-in-Fact and Agents to act for and on behalf of the Company and may give such appointee such authority as his or her certificate of authority 
may prescribe to sign with the Company's name and seal with the Company's seal bonds, recognizances, contracts of indemnity, and other writings 
obligatory in the nature of a bond, recognizance, or conditional undertaking, and any of said officers or the Board of Directors at any lime may 
remove any such appointee and revoke the power given him or her; and it is 
FURTHER RESOLVED, that the Chairman, the President, any Vice Chairman, any Executive Vice President, any Senior Vice President or 
any Vice President may delegate all or any part of the foregoing authority to one or more officers or employees of this Company, provided 
that each such delegation is in writing and a copy thereof is filed in the office of the Secretary; and it is 
FURTHER RESOLVED, that any bond, recognizance, contract of indemnity, or writing obligatory in the nature of a bond, recognizance, 
or conditional undertaking shall be valid and binding upon the Company when (a) signed by the President, any Vice Chairman, any Executive 
Vice President, any· Senior Vice President or any Vice President, any Second Vice President, the Treasurer, any Assistant Treasurer, the 
Corporate Secretary or any Assistant Secretary and duly attested and sealed with the Company's seal by a Secretary or Assistant Secretary; 
or (b) duly executed (under seal, if required) by one or more Attorneys-in-Fact and Agents pursuant to the power prescribed in his or her 
certificate or their certificates of authority or by one or more Company officers pursuant to a written delegation of authority; and it is 
-
. 
FURTHER RESOLVED, that the signature of each of the following officers: President, any Executive Vice President, any Senior Vice President, 
any Vice President, any Assistant Vice President, any Secretary, any Assistant Secretary, and the seal of the Company may be affixed by facsimile to 
any Power of Attorney or to any certificate relating thereto appointing Resident Vice Presidents, Resident Assistant Secretaries or Attorneys-in-
Fact for purposes only of executing and attesting bonds and undertakings and other writings obligatory in the nature thereof, and any such Power of 
Attorney or certificate bearing such facsimile signature or facsimile seal shall be valid and binding upon the Company and any such power so executed 
and certified by such facsimile signature and facsimile seal shall be valid and binding on the Company in the future with respect to any bond or 
understanding to which it is attached. 
I, Kevin E. Hughes, the !:l.C19ft.(Signed, Assistant Secretary of each of the Companies, do hereby certify that the above and foregoing is a 
true and correct copy of tj::ie•y?o_wer qf,6.ttqmey executed by said Companies, which remains in full force and effect. 
--~~~· ~-~ - --~·~·~~~~~~~--~ "'-. .:~~~-~ 
Dated this 1st 
jj~tiL-filovembe'l'-._ · -,- 2023 
Q._®\9 
CH~~~ 
~-~~°'-.._" 
-~-,.",'--'-' _,_,' 
,·-~ 
> 
· 
· To ~erify the authenticity of this Power of Attomey, please call us a~ 1.-BD_0-421.-3880. 
. 
Please refer to the above-named Attomey{s}-in-Fact and the details of the bond to which this Power of Attomey is attached.

SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE
THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN
ACCORDANCE WITH THE POLICY PROVISIONS.
INSURER(S) AFFORDING COVERAGE
INSURER F :
INSURER E :
INSURER D :
INSURER C :
INSURER B :
INSURER A :
NAIC #
NAME:
CONTACT
(A/C, No):
FAX
E-MAIL
ADDRESS:
PRODUCER
(A/C, No, Ext):
PHONE
INSURED
REVISION NUMBER:
CERTIFICATE NUMBER:
COVERAGES
IMPORTANT:  If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed.
If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement.  A statement on
this certificate does not confer rights to the certificate holder in lieu of such endorsement(s).
THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS
CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES
BELOW.  THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED
REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER.
OTHER:
(Per accident)
(Ea accident)
$
$
N / A
SUBR
WVD
ADDL
INSD
THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD
INDICATED.  NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS
CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
$
$
$
$
PROPERTY DAMAGE
BODILY INJURY (Per accident)
BODILY INJURY (Per person)
COMBINED SINGLE LIMIT
AUTOS ONLY
AUTOS
AUTOS ONLY
NON-OWNED
SCHEDULED
OWNED
ANY AUTO
AUTOMOBILE LIABILITY
Y / N
WORKERS COMPENSATION
AND EMPLOYERS' LIABILITY
OFFICER/MEMBER EXCLUDED?
(Mandatory in NH)
DESCRIPTION OF OPERATIONS below
If yes, describe under
ANY PROPRIETOR/PARTNER/EXECUTIVE
$
$
$
E.L. DISEASE - POLICY LIMIT
E.L. DISEASE - EA EMPLOYEE
E.L. EACH ACCIDENT
ER
OTH-
STATUTE
PER
LIMITS
(MM/DD/YYYY)
POLICY EXP
(MM/DD/YYYY)
POLICY EFF
POLICY NUMBER
TYPE OF INSURANCE
LTR
INSR
DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES  (ACORD 101, Additional Remarks Schedule, may be attached if more space is required)
EXCESS LIAB
UMBRELLA LIAB
$
EACH OCCURRENCE
$
AGGREGATE
$
OCCUR
CLAIMS-MADE
DED
RETENTION $
$
PRODUCTS - COMP/OP AGG
$
GENERAL AGGREGATE
$
PERSONAL & ADV INJURY
$
MED EXP (Any one person)
$
EACH OCCURRENCE
DAMAGE TO RENTED
$
PREMISES (Ea occurrence)
COMMERCIAL GENERAL LIABILITY
CLAIMS-MADE
OCCUR
GEN'L AGGREGATE LIMIT APPLIES PER:
POLICY
PRO-
JECT
LOC
CERTIFICATE OF LIABILITY INSURANCE
DATE (MM/DD/YYYY)
CANCELLATION
AUTHORIZED REPRESENTATIVE
ACORD 25 (2016/03)
© 1988-2015 ACORD CORPORATION.  All rights reserved.
CERTIFICATE HOLDER
The ACORD name and logo are registered marks of ACORD
HIRED
AUTOS ONLY
10/11/2023
Crest Insurance Group, LLC
10650 Treena Street Suite 308
San Diego AZ 92131
Dawn Manzano
480-689-5338
480-839-2272
dmanzano@crestins.com
License#: 967026
Selective Way Insurance Company
26301
TSGCONS-01
Selective Insurance Company of SC
19259
TSG Constructors, LLC
2340 W. Parkside Lane
Suite H105
Phoenix AZ 85027
Indian Harbor Insurance Co.
36940
Selective Insurance Co of America
12572
345354631
A
X
1,000,000
X
500,000
15,000
1,000,000
2,000,000
X
X
Y
Y
S 2302705
1/1/2023
1/1/2024
2,000,000
A
1,000,000
X
X
X
Y
Y
S 2302705
1/1/2023
1/1/2024
A
X
X
5,000,000
S 2302705
1/1/2023
1/1/2024
5,000,000
X
0
B
Y
WC 9075224
1/1/2023
1/1/2024
1,000,000
1,000,000
1,000,000
A
C
D
Leased/Rented Equipment
Pollution/Professional Liability
Builders Risk
S 2302705
STO0970059-01
S 2507958
1/1/2023
8/10/2023
12/1/2023
1/1/2024
8/10/2024
12/1/2024
Limit
Per Claim/Aggregate
Hard Costs Limit
150,000
5M/5M
$2,447,000
Certificate holder and others when required in a written contract or agreement are additional Insured (General Liability). Coverage is Primary &
Non-Contributory (General Liability). Waiver of Subrogation (General Liability & Workers Compensation) applies. This form is subject to all policy forms, terms,
endorsements, conditions, definitions, & exclusions.
RE: Maricopa County Clerk of the Superior Court SE Remodel - 222 E. Javelina Ave., Mesa, AZ 85210
Maricopa County is named as additional insured per written contract.
Maricopa County
401 W. Jefferson St.
Phoenix AZ 85003

INSURED'S COPY
CA 78 09 11 17
Copyright, 2017 Selective Insurance Company of America. All rights reserved.
Includes copyrighted material of Insurance Services Office, Inc., with its permission.
S  2302705
00000F
Page 1 of 5
047
ElitePac®
Commercial Automobile Extension
COMMERCIAL AUTO
CA 78 09 11 17
THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY.
This endorsement modifies insurance provided under the following:
BUSINESS AUTO COVERAGE FORM
With respect to coverage provided by this endorsement, the provisions of the Business Auto Coverage Form apply unless
modified by the endorsement.
AMENDMENTS
TO
SECTION
II
-
LIABILITY
COVERAGE
A.
If this policy provides Auto Liability coverage for
Owned
Autos,
the
following
extensions
are
applicable accordingly:
NEWLY
ACQUIRED
OR
FORMED
ORGANIZATIONS
The following is added to SECTION II, A.1. - Who
Is An Insured:
Any organization you newly acquire or form, other
than a partnership, joint venture or limited liability
company over which you maintain ownership or
majority interest, will qualify as a Named Insured if
there is no similar
insurance available
to
that
organization. However:
1.
Coverage under this provision is afforded only
until the 180th day after you acquire or form the
organization or the end of the policy period,
whichever is earlier;
2.
Coverage does not apply to "bodily injury" or
"property damage" resulting from an "accident"
that occurred before you acquired or formed the
organization.
No person or organization is an "insured" with
respect to the conduct of
any current or past
partnership, joint venture or limited liability company
that is not shown as a Named Insured in the
Declarations.
EXPENSES FOR BAIL BONDS AND LOSS OF
EARNINGS
Paragraphs (2) and (4) of SECTION II, A.2.a. -
Supplementary
Payments are
deleted in their
entirety and replaced with the following:
(2) Up to the Limit of Insurance shown on the
ElitePac Schedule for the cost of bail bonds
(including
bonds
for
related
traffic
law
violations) required because of an "accident"
covered under this policy. We do not have to
furnish these bonds.
(4) All
reasonable
expenses
incurred
by
the
"insured" at our request. This includes actual
loss of earnings because of time off from work,
which we will pay up to the Limit of Insurance
shown on the ElitePac Schedule.
EMPLOYE E
INDEMNIFICATION
AND
EMPLOYER'S LIABILITY AMENDMENT
The following is added to SECTION
II, B.4. -
Exclusions:
This
exclusion does not apply to
a "volunteer
worker" who is not entitled to workers compensation,
disability or unemployment compensation benefits.
FELLOW EMPLOYEE COVERAGE
The Fellow Employee Exclusion, SECTION II, B.5.
- is deleted in its entirety.
CARE, CUSTODY OR CONTROL AMENDMENT
The following is added to SECTION
II, B.6. -
Exclusions:
This exclusion does not apply to property owned by
anyone other than an "insured", subject to the
following:
1.
The most we will pay under this exception for
any one "accident" is the Limit of Insurance
stated in the ElitePac Schedule; and
2.
A per "accident" deductible as stated in the
ElitePac Schedule applies to this exception.
B.
If this policy provides Auto Liability coverage for
Owned Autos or Non-Owned Autos, the following
extension is applicable accordingly:
LIMITED LIABILITY COMPANIES
The following is added to SECTION II, A.1. - Who
Is An Insured:
If you are a limited liability company, your members
and managers are "insureds" while using a covered
"auto" you don't own, hire or borrow during the
course of their duties for you.
BLANKET
ADDITIONAL
INSUREDS
-
As
Required By Contract
The following is added to SECTION II, A.1. - Who
Is An Insured:

INSURED'S COPY
CA 78 09 11 17
Copyright, 2017 Selective Insurance Company of America. All rights reserved.
Includes copyrighted material of Insurance Services Office, Inc., with its permission.
Page 2 of 5
Any person or organization whom you have agreed
in a written contract, written agreement or written
permit that such person or organization be added as
an additional "insured" on your policy. Such person
or organization is an additional "insured" only with
respect to liability for "bodily injury" or "property
damage" caused, in whole or in part, by your
ownership, maintenance or use of a covered "auto".
This coverage shall be primary and non-contributory
with
respect
to
the
additional
"insured".
This
provision only applies if:
1.
It is required in the written contract, written
agreement or written permit identified in this
section;
2.
It is permitted by law; and
3.
The written contract or written agreement has
been executed (executed means signed by a
named insured) or written permit issued prior to
the "bodily injury" or "property damage".
C.
If this policy provides Auto Liability coverage for
Non-Owned
Autos,
the
following
extension
is
applicable accordingly:
EMPLOYEES AS INSUREDS
If this policy provides Auto Liability coverage for
Non-Owned
Autos,
the
following
is
added
to 
SECTION II, A.1. - Who Is An Insured:
Any "employee" of yours is an "insured" while using
a covered "auto" you don't own, hire or borrow in
your business or your personal affairs.
An
"employee"
of
yours
is an
"insured"
while
operating an "auto" hired or rented under a contract
or agreement in that "employee's" name with your
permission, while performing duties related to the
conduct of your business.
AMENDMENTS
TO
SECTION
III
-
PHYSICAL
DAMAGE COVERAGE
If this policy provides Comprehensive, Specified Causes
of Loss or Collision coverage, the following extensions
are
applicable
for
those
"autos"
for
which
Comprehensive, Specified Causes of Loss or Collision
coverage is purchased:
TOWING AND LABOR
SECTION III, A.2. - Towing is deleted in its entirety and
replaced with the following:
We will pay all reasonable towing and labor costs up to
the maximum Limit of Insurance shown on the ElitePac
Schedule
per
tow
each
time
a
covered
"Private
Passenger Auto", "Social Service Van or Bus" or "Light
Truck" is disabled and up to the maximum Limit of
Insurance per tow each time a covered "Medium Truck",
"Heavy Truck" or "Extra Heavy Truck" is disabled.
For labor charges to be eligible for reimbursement the
labor must be performed at the place of disablement.
This coverage extension does not apply to Emergency
Services Organizations and Governmental Entities.
GLASS BREAKAGE DEDUCTIBLE
The following is added to SECTION III, A.3. - Glass
Breakage - Hitting A Bird Or Animal - Falling Objects
or Missiles:
If damaged glass is repaired rather than replaced, no
deductible will apply for such repair. This extension does
not apply to Emergency Services Organizations and
Governmental Entities.
ADDITIONAL
TRANSPORTATION
EXPENSES
SECTION III, A.4.a. - Transportation Expenses is
deleted in its entirety and replaced with the following:
We will pay up to the maximum Limit of Insurance shown
on the ElitePac Schedule for temporary transportation
expenses that you incur because of any "loss" to a
covered "auto", but only if the covered "auto" carries the
coverages and meets the requirements described in 1.
or 2. below:
1.
We will pay temporary transportation expenses for
total theft of a covered "auto". We will only pay for
such expenses incurred during the period beginning
24 hours after the theft and ending, regardless of the
policy's
expiration, when
the covered "auto" is
returned to use or we pay for its "loss".
2.
For "loss" other than total theft of a covered "auto"
under Comprehensive or Specified Causes of Loss
Coverage, or for any "loss" under Collision Coverage
to a covered "auto", we will only pay for those
temporary transportation expenses incurred during
the policy period beginning 24 hours after the "loss"
and ending, regardless of the policy's expiration,
with the lesser of the number of days reasonably
required to repair or replace the covered "auto" or 30
days.
Paragraph 2. of this extension does not apply while
there are spare or reserve "autos" available to you
for your operations.
This coverage extension does not apply to Emergency
Services Organizations and Governmental Entities.
HIRED AUTO PHYSICAL DAMAGE COVERAGE
The following is added to SECTION III, A.4. - Coverage
Extensions:
Physical Damage coverage is hereby extended to apply
to Physical Damage "loss" to "autos" leased, hired,
rented or borrowed without a driver. We will provide
coverage equal to the broadest coverage available to
any covered "auto" shown in the Declarations. But, the
most we will pay for "loss" to each "auto" under this
coverage extension is the lesser of:

Copyright, 2017 Selective Insurance Company of America. All rights reserved.
Includes copyrighted material of Insurance Services Office, Inc., with its permission.
CA 78 09 11 17
INSURED'S COPY
S  2302705
00000F
Page 3 of 5
049
1.
The
Limit
of
Insurance stated
in the ElitePac
Schedule; or
2.
The actual cash value of the damaged or stolen
property as of the time of the "loss"; or
3.
The
actual
cost
of
repairing
or
replacing
the
damaged or stolen property with other property of
like kind and quality. A part is of like kind and quality
when it is of equal or better condition than the
pre-accident
part.
We
will
use
the
original
equipment from the manufacturer when:
(a) The operational safety of the vehicle might
otherwise be impaired;
(b) Reasonable and diligent efforts to locate the
appropriate rebuilt, aftermarket or used part
have been unsuccessful; or
(c) A new original equipment part of like kind
and quality is available and will result in the
lowest overall repair cost.
For each leased, hired, rented or borrowed "auto" our
obligation to pay "losses" will be reduced by a deductible
equal to the highest deductible applicable to any owned
"auto" for that coverage. No deductible will be applied to
"losses" caused by fire or lightning.
SECTION
IV,
B.5.
Other
Insurance
Condition,
Paragraph 5.b. is deleted in its entirety and replaced by
the following:
For
Hired
Auto
Physical
Damage
Coverage,
the
following are deemed to be covered "autos'" you own:
1.
Any covered "auto" you lease, hire, rent, or borrow;
and
2.
Any
covered
"auto"
hired
or
rented
by
your
"employee" under a contract or agreement in that
"employee's" name, with your permission,
while
performing duties related to the conduct of your
business.
However, any "auto" that is leased, hired, rented or
borrowed with a driver is not a covered "auto".
This coverage extension does not apply to Emergency
Services Organizations and Governmental Entities.
HIRED AUTO LOSS OF USE COVERAGE
The following is added to SECTION III, A.4. - Coverage
Extensions:
We
will
pay
expenses
for which
you are
legally
responsible to pay up to the Limit of Insurance shown on
the ElitePac Schedule per "accident" for loss of use of a
leased, hired, rented or borrowed "auto" if it results from
an "accident".
This coverage extension does not apply to Emergency
Services
Organizations,
Governmental
Entities,
and
Schools.
AUTO
LOAN/LEASE
GAP
COVERAGE
(Not
Applicable in New York)
The following is added to SECTION III, A.4. - Coverage
Extensions:
In the event of a total "loss" to a covered "auto" we will
pay any unpaid amount due on the lease or loan for a
covered "auto", less:
1.
The
amount
paid
under
the
Physical Damage
Coverage Section of the policy; and
2.
Any:
a.
Overdue lease/loan payments at the time of
"loss";
b.
Financial penalties imposed under a lease for
excessive use, abnormal wear and tear, high
mileage or similar charges;
c.
Security deposits not refunded by the lessor or
financial institution;
d.
Costs for extended warranties, credit life, health,
accident, or disability insurance purchased with
the loan or lease; and
e.
Carry-over balances from previous leases or
loans.
You are responsible for the deductible applicable to the
"loss" for the covered "auto".
PERSONAL EFFECTS
The following is added to SECTION III, A.4. - Coverage
Extensions:
If this policy provides Comprehensive Coverage for a
covered "auto" you own and that covered "auto" is
stolen, we will pay up to the Limit of Insurance shown on
the
ElitePac
Schedule,
without
application
of
a
deductible, for lost personal effects that were in the
covered "auto" at the time of theft. Personal effects do
not include jewelry, tools, money, or securities. This
coverage is excess over any other collectible insurance.
AIRBAG COVERAGE
The
following
is
added to SECTION
III,
B.3.a.
-
Exclusions:
Mechanical breakdown does not include the accidental
discharge of an airbag.
This coverage extension does not apply to Emergency
Services Organizations and Governmental Entities.
EXPANDED
AUDIO,
VISUAL,
AND
DATA
ELECTRONIC EQUIPMENT COVERAGE
SECTION III, B.4. - Exclusions
This exclusion does not apply to the following:
1.
Global positioning systems;
2.
"Telematic devices"; or
3.
Electronic equipment that reproduces, receives or
transmits visual or data signals and accessories
used with such equipment, provided such equipment
is:

Copyright, 2017 Selective Insurance Company of America. All rights reserved.
Includes copyrighted material of Insurance Services Office, Inc., with its permission.
CA 78 09 11 17
INSURED'S COPY
Page 4 of 5
a.
Permanently installed in or upon the covered
"auto" at the time of the "loss";
b.
Removable
from
a
housing
unit
that
is
permanently installed in the covered "auto" at
the time of the "loss";
c.
Designed to be solely operated by use of power
from the "auto's" electrical system; or
d.
Designed to be used solely in or upon the
covered "auto".
For each covered "loss" to such equipment, a deductible
of $50 shall apply, unless the deductible otherwise
applicable to such equipment is less than $50, at which
point the lower deductible, if any, will apply.
COMPREHENSIVE
DEDUCTIBLE
-
LOCATION
TRACKING DEVICE
The following is added to SECTION III, D. - Deductible:
Any Comprehensive Coverage Deductible shown in the
Declarations will be reduced by 50% for any "loss"
caused by theft if the covered "auto" is equipped with a
location tracking device and that device was the sole
method used to recover the "auto".
PHYSICAL DAMAGE LIMIT OF INSURANCE
SECTION III, C. - Limit Of Insurance is deleted in its
entirety and replaced with the following:
The most we will pay for a "loss" in any one "accident" is
the lesser of:
1.
The actual cash value of the damaged or stolen
property as of the time of the "loss"; or
2.
The cost of repairing or replacing the damaged or
stolen property with other property of like kind and
quality.
This coverage extension does not apply to Emergency
Services Organizations and Governmental Entities.
AMENDMENTS TO SECTION IV - BUSINESS AUTO
CONDITIONS
DUTIES IN THE EVENT OF ACCIDENT, CLAIM, SUIT
OR LOSS
The following is added to SECTION IV, A.2.a. - Duties
In The Event Of Accident, Claim, Suit Or Loss:
The notice requirements for reporting "accident" claim,
"suit" or "loss" information to us, including provisions
related
to
the
subsequent
investigation
of
such
"accident", claim, "suit" or "loss" do not apply until the
"accident", claim, "suit" or "loss" is known to:
1.
You, if you are an individual;
2.
A partner, if you are a partnership;
3.
An executive officer or insurance manager, if you
are a corporation;
4.
Your members, managers or insurance manager, if
you are a limited liability company;
5.
Your elected or appointed officials, trustees, board
members or your insurance manager, if you are an
organization other than a partnership, joint venture
or limited liability company.
But, this section does not amend the provisions relating
to notification of police or protection or examination of
the property that was subject to the "loss".
WAIVER OF SUBROGATION
SECTION IV, A.5. - Transfer Of Rights Of Recovery
Against Others To Us is deleted in its entirety and
replaced with the following:
We waive any right of recovery we may have against
any person or organization because of payments we
make for "bodily injury" or "property damage" resulting
from the ownership, maintenance or use of a covered
"auto" but only when you have assumed liability for such
"bodily injury" or "property damage" in an "insured
contract". In all other circumstances, if a person or
organization to or for whom we make payment under
this Coverage Form has rights to recover damages from
another, those rights are transferred to us.
MULTIPLE DEDUCTIBLES
The following is added to SECTION IV, A. - Loss
Conditions:
If a "loss" from one event involves two or more covered
"autos"
and
coverage
under
Comprehensive
or
Specified Causes of Loss applies, only the highest
applicable deductible will be applied.
CONCEALMENT, MISREPRESENTATION OR FRAUD
The
following
is
added
to SECTION
IV,
B.2.
-
Concealment, Misrepresentation Or Fraud:
If you should unintentionally fail to disclose any existing
hazards in your representations to us prior to the
inception date of the policy or during the policy period in
connection with any newly discovered hazards, we will
not deny coverage under this Coverage Form based
upon such failure.
POLICY PERIOD, COVERAGE TERRITORY
SECTION IV, B.7. - Policy Period, Coverage Territory
is deleted in its entirety and replaced with the following:
Under this Coverage Form, we cover "accidents" and
"losses" occurring:
a.
During the policy period shown in the Declarations;
and
b.
Within the "Coverage Territory".

Copyright, 2017 Selective Insurance Company of America. All rights reserved.
Includes copyrighted material of Insurance Services Office, Inc., with its permission.
CA 78 09 11 17
INSURED'S COPY
S  2302705
00000F
Page 5 of 5
051
We also cover "loss" to or "accidents" involving
a
covered "auto" while being transported between any of
these places.
TWO OR MORE COVERAGE FORMS OR POLICIES
ISSUED BY US - DEDUCTIBLES
The following is added to SECTION IV, B.8. - Two Or
More Coverage Forms Or Policies Issued By Us:
If a "loss" covered under this Coverage Form also
involves a "loss" to other property resulting from the
same "accident" that is covered under this policy or
another policy issued by us or any member company of
ours, only the highest applicable deductible will be
applied.
AMENDMENTS TO SECTION V - DEFINITIONS
BODILY
INJURY
INCLUDING
MENTAL
ANGUISH
(Not Applicable in New York)
The definition of bodily injury is deleted in its entirety
and replaced by the following:
"Bodily injury" means bodily injury, sickness, or disease
sustained by a person, including death resulting from
any of these. "Bodily injury" includes mental anguish
resulting
from
bodily
injury,
sickness
or
disease
sustained by a person.
ADDITIONS TO SECTION V - DEFINITIONS
COVERAGE TERRITORY
"Coverage Territory" means:
1.
The
United
States
of
America
(including
its
territories and possessions), Canada and Puerto
Rico; and
2.
Anywhere in the world, except for any country or
jurisdiction that is subject to trade or other economic
sanction or
embargo by
the
United
States of
America, if a covered "auto" is leased, hired, rented,
or borrowed without a driver for a period of 30 days
or less, and the insured's responsibility to
pay
"damages" is determined in a "suit" on the merits in
and under the substantive law of the United States
of
America
(including
its
territories
and
possessions), Puerto
Rico, or Canada, or in a
settlement we agree to.
If we are prevented by law, or otherwise, from defending
the "insured" in a "suit" brought in a location described in
Paragraph 2. above, the insured will conduct a defense
of that "suit". We will reimburse the "insured" for the
reasonable and necessary expenses incurred for the
defense of any such "suit" seeking damages to which
this insurance applies, and that we would have paid had
we been able to exercise our right and duty to defend.
EXTRA HEAVY TRUCK
"Extra Heavy Truck" means a truck with a gross vehicle
weight rating of 45,001 pounds or more.
HEAVY TRUCK
"Heavy Truck" means a truck with a gross vehicle
weight rating of 20,001 pounds to 45,000 pounds.
LIGHT TRUCK
"Light Truck" means a truck with a gross vehicle weight
rating of 10,000 pounds or less.
MEDIUM TRUCK
"Medium Truck" means a truck with a gross vehicle
weight rating of 10,001 pounds to 20,000 pounds.
PRIVATE PASSENGER AUTO
"Private Passenger Auto" means a four-wheel "auto" of
the private passenger or station wagon type. A pickup,
panel truck or van not used for business is included
within the definition of a "private passenger auto".
SOCIAL SERVICE VAN OR BUS
"Social Service Van or Bus" means a van or bus used
by a government
entity, civic,
charitable
or social
service organization to provide transportation to clients
incidental
to
the social
services sponsored by the
organization, including special trips and outings.
TELEMATIC DEVICE
"Telematic Device" includes devices designed for the
collection and dissemination of data for the purpose of
monitoring
vehicle
and/or
driver
performance.
This
includes Global Positioning System technology, wireless
safety communications and automatic driving assistance
systems, all
integrated
with computers
and mobile
communications technology in automotive navigation
systems.
VOLUNTEER WORKER
"Volunteer
worker" means
a person who performs
business duties for
you,
for no
financial
or
other
compensation.

INSURED'S COPY
CG 79 88 06 22
Copyright, 2021 Selective Insurance Company of America. All rights reserved.
Includes copyrighted material of Insurance Services Office, Inc., with its permission.
S  2302705
00000F
Page 1 of 4
984
Contracting, Installation, Service and Repair
General Liability Extended ElitePac® Endorsement
COMMERCIAL GENERAL LIABILITY
CG 79 88 06 22
THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY.
This endorsement modifies insurance provided under the following:
COMMERCIAL GENERAL LIABILITY COVERAGE PART
With respect to coverage provided by this endorsement, the provisions of the Coverage Form apply unless modified by
the endorsement.
A.
BLANKET ADDITIONAL INSUREDS
1.
Ongoing Operations
SECTION
II —
WHO IS AN
INSURED is
amended to include as an additional insured:
a.
Any person or organization for whom you
are performing operations when you and
such person or organization have agreed in
a written contract,
written agreement or
written
permit
that
such
person
or
organization be
added
as an
additional
insured on your commercial general liability
policy; and
b.
Any other person or organization, including
any architects, engineers or surveyors not
engaged by you, whom you are required to
add as an additional insured under your
policy
in
the
contract or
agreement
in
Paragraph 1. above;
Such person or organization is an additional
insured only with respect to liability arising out of
your ongoing operations performed under that
contract,
agreement,
or
permit
when
that
contract,
agreement, or
permit
requires the
additional insured be added with respect to
liability arising out of your ongoing operations.
If the written contract, written agreement, or
written
permit
does
not
require
that
the
additional insured be added with respect to
liability arising out of your ongoing operations,
then such person or organization is an additional
insured only with respect to "bodily injury",
"property damage" or "personal and advertising
injury" caused in whole or in part by your
ongoing
operations
performed
under
that
contract, agreement, or permit.
2.
Completed Operations
SECTION II — WHO IS AN INSURED is amended
to include as an additional insured:
a.
Any person or organization for whom you are
performing or have performed operations when
you and such person or organization
have
agreed in a written contract, written agreement
or
written
permit
that
such
person
or
organization be added as an additional insured
on your commercial general liability policy; and
b.
Any other person or organization, including any
architects, engineers or surveyors not engaged
by you, whom you are required to add as an
additional
insured under
your policy
in the
contract or agreement in Paragraph 1. above;
Such person or organization is an additional insured
only with respect to their liability arising out of "your
work" performed under that contract, agreement, or
permit
and
included
in the
"productscompleted
operations hazard" when that contract, agreement,
or permit requires the additional insured be added
with respect to liability arising out of "your work"
performed under that contract, agreement, or permit
and included in the "productscompleted operations
hazard".
If the written contract, written agreement, or written
permit does not require that the additional insured
be added with respect to liability arising out of "your
work" performed under that contract, agreement, or
permit
and
included
in the
"productscompleted
operations
hazard",
then
such
person
or
organization
is an
additional
insured
only with
respect to
liability
for
"bodily injury",
"property
damage"
or
"personal
and
advertising
injury"
caused,
in
whole
or
in
part,
by
"your
work"
performed under that contract, agreement, or permit
and included in the "productscompleted operations
hazard".

INSURED'S COPY
CG 79 88 06 22
Copyright, 2021 Selective Insurance Company of America. All rights reserved.
Includes copyrighted material of Insurance Services Office, Inc., with its permission.
Page 2 of 4
3.
The insurance afforded to the additional insureds in
Paragraphs 1. and 2. above:
a.
Does not apply unless the written contract or
written
agreement has been signed
by the
Named Insured or written permit issued prior to
the
"bodily
injury",
"property
damage"
or
"personal and advertising injury";
b.
Only applies to the extent permitted by law; and
c.
Will not be broader than that which you are
required
by
the
written
contract,
written
agreement, or written permit to provide to such
additional insured.
4.
Exclusions
a.
With
respect
to
the
insurance
afforded
to
additional
insureds
under
a.
Ongoing
Operations the
following
is
added
to 2.
Exclusions under SECTION I — COVERAGE
A
—
BODILY
INJURY
AND
PROPERTY
DAMAGE LIABILITY:
This insurance does not apply to "bodily injury",
"property damage", or "personal and advertising
injury" occurring after:
(1) All
work,
including
materials,
parts
or
equipment furnished in connection with such
work, on the project (other than service,
maintenance or repairs) to be performed by
or on behalf of the additional insured(s) at
the site of the covered operations has been
completed; or
(2) That portion of "your work" out of which the
injury or damage arises has been put to its
intended use by any person or organization
other
than
another
contractor
or
subcontractor
engaged
in
performing
operations for a principal as a part of the
same project.
b.
With respect to the insurance afforded to these
additional
insureds
under 
a.
Ongoing
Operations and b. Completed Operations, the
following is added
to 2.
Exclusions under
SECTION
I — COVERAGE
A —
BODILY
INJURY
AND
PROPERTY
DAMAGE
LIABILITY:
This insurance does not apply to:
"Bodily injury", "property damage", or "personal
and
advertising
injury"
arising
out
of
the
rendering    of,   or   the   failure  to  render,  any
professional
architectural,
engineering
or
surveying services, including:
(1) The
preparing,
approving,
or
failing
to
prepare or approve, maps, shop drawings,
opinions,
reports,
surveys,
field
orders,
change
orders
or
drawings
and
specifications; or
(2) Supervisory,
inspection,
architectural
or
engineering activities.
5.
Conditions
With respect to the insurance afforded to these
additional insureds under a. Ongoing Operations 
and b. Completed Operations the following is
added to Paragraph 4. Other Insurance, a. Primary
Insurance under SECTION IV — COMMERCIAL
GENERAL LIABILITY CONDITIONS:
This insurance is primary to and will not seek
contribution from any other insurance available to an
additional insured under this policy provided that:
a.
The additional insured is a Named Insured
under such other insurance; and
b.
You have agreed in a written contract, written
agreement or written permit that this insurance
would
be
primary
and
would
not
seek
contribution from any other insurance available
to the additional insured.
6.
With respect to the insurance afforded to these
additional
insureds,
the
following
is
added
to
Section III — Limits Of Insurance:
The most we will pay on behalf of the additional
insured is the amount of insurance:
a.
Required
by
the
written
contract,
written
agreement or written permit you have entered
into with the additional insured; or
b.
Available
under
the
applicable
limits
of
insurance;
whichever is less.
The insurance provided by this provision shall not
increase the applicable limits of insurance.

Copyright, 2021 Selective Insurance Company of America. All rights reserved.
Includes copyrighted material of Insurance Services Office, Inc., with its permission.
CG 79 88 06 22
INSURED'S COPY
S  2302705
00000F
Page 3 of 4
986
B.
PROPERTY
DAMAGE
CARE,
CUSTODY
OR
CONTROL
1.
The following is added to Exclusion j. under 
SECTION I — COVERAGE A BODILY INJURY
AND PROPERTY DAMAGE LIABILITY:
Paragraphs (4) and (5) of this exclusion do not
apply for the limited purpose of providing the
coverage and sublimits of liability as set forth
below.
We
will
pay
those sums
that
the insured
becomes legally obligated to pay as damages
because of "property damage" to:
(a) Personal property, including keys, in the
care, custody or control of an insured; and
(b) That particular part of real property on which
you or any contractors or subcontractors
working directly or indirectly on your behalf
are performing operations, if the "property
damage" arises out of those operations.
The most we will pay under a. and b. above in
any one "occurrence" or for all damages during
any one policy period is a sub-limit of $100,000.
These limits are included in and not in addition
to
the
Limits
of
Insurance
shown
in
the
Declarations
of
the
Commercial
General
Liability Policy.
Our right and duty to defend the insured against
any "suit" for damages under a. and b. above
ends when we have used up the applicable
sub-limit of liability in the payment of judgments
or settlements under it.
2.
With respect this provision only, the following is
added to
Definition
17. under SECTION
V
—
DEFINITIONS:
"Property
damage"
also includes adjustment
of
locks to fit new keys or the cost of new locks,
including
their installation,
when replacing
keys
covered in Paragraph 1.(a) above provided that
such "property damage" is not a result of
any
dishonest act on the part of any insured, or the
insured's employees or agents, whether acting alone
or in collusion.
C.
OTHER
INSURANCE
AMENDMENT
—
SUPPLEMENTAL COVERAGE FOR INSURED'S
INVOLVEMENT IN A CONTROLLED (WRAPUP)
INSURANCE PROGRAM
1.
The following is added to SECTION IV —
COMMERCIAL
GENERAL
LIABILITY
CONDITIONS, Paragraph 4. Other Insurance
b. Excess Insurance (1)(a):
(V) That is covered by a "controlled (wrap-up)
insurance
program"
in
which
you
are
enrolled for your
ongoing operations
or
operations
included
within
the
"products-completed
operations
hazard",
unless such "controlled (wrap-up) insurance
program"
is
specifically
excluded
from
coverage on this policy.
2.
The
following is added
to SECTION
V
—
DEFINITIONS:
"Controlled
(wrap-up)
insurance
program"
means a centralized insurance program under
which one party has secured either insurance or
self-insurance
covering
some
or
all
of
the
contractors or subcontractors performing work
on one or more specific project(s).
D.
FELLOW EMPLOYEE EXTENSION
Under SECTION
II — WHO IS AN INSURED 
Paragraphs 2.a. and 2.a. (1) are replaced by the
following:
a.
Your "volunteer workers" only while performing
duties related to the conduct of your business, or
your
"employees",
other
than
either
your
"executive officers" (if you are an organization
other than a partnership, joint venture, or limited
liability company) or your managers (if you are a
limited liability company), but only for acts within
the scope of their employment by you or while
performing duties related to the conduct of your
business. However, none of these "employees"
or "volunteer workers" are insureds for "bodily
injury"
or
"personal
and
advertising
injury"
arising out of his or her providing or failing to
provide professional health care services.
With
respect
to
this
provision
only,
Subparagraph (1) of Exclusion 2. e. Employer's
Liability under SECTION I — COVERAGES,
COVERAGE
A
BODILY
INJURY
AND
PROPERTY DAMAGE
LIABILITY does
not
apply.

Copyright, 2021 Selective Insurance Company of America. All rights reserved.
Includes copyrighted material of Insurance Services Office, Inc., with its permission.
CG 79 88 06 22
INSURED'S COPY
Page 4 of 4
E.
CONTRACTUAL LIABILITY (RAILROADS)
Definition 9. under SECTION V — DEFINITIONS
is amended as follows:
1.
Paragraph c. is deleted in its
entirety and
replaced by the following:
c.
Any easement or license agreement;
2.
Paragraph f.(1) is deleted in its entirety.
F.
CONTRACTUAL
LIABILITY
AMENDMENT
—
(PERSONAL AND ADVERTISING INJURY)
If
it
is
required
in a
written
contract,
written
agreement or written permit with the insured that
any contractual liability exclusion for personal injury
be removed from the policy, then Exclusion e.
Contractual
Liability
under 
COVERAGE
B
PERSONAL
AND
ADVERTISING
INJURY,
2. 
Exclusions is deleted in its entirety and replaced by
the following:
e.
Contractual Liability
"Personal and advertising Injury" for which the
insured has assumed liability in a contract or
agreement arising out of an "advertisement".
This exclusion does not apply to liability for
damages that the insured would have in the
absence of the contract or agreement".
G. WAIVER OF GOVERNMENTAL IMMUNITY
We will waive, both in the adjustment of claims and
in the defense of "suits" against the insured, any
governmental immunity of the insured, unless the
insured requests in writing that we not do so.
Waiver of immunity as a defense will not subject us
to liability for any portion of a claim or judgment in
excess of the applicable limit of insurance.
H.
DAMAGE TO PREMISES RENTED TO YOU
The Limit of Insurance for Damage To Premises
Rented To You is increased to $1,000,000.

INSURED'S COPY
CG 73 00 06 22
Copyright, 2021 Selective Insurance Company of America. All rights reserved.
Includes copyrighted material of Insurance Services Office, Inc., with its permission.
S  2302705
00000F
Page 1 of 10
970
ElitePac
®
General Liability Extension Endorsement
COMMERCIAL GENERAL LIABILITY
CG 73 00 06 22
SUMMARY OF COVERAGES (including index)
This is a summary of the various additional coverages and coverage modifications provided by this endorsement. No
coverage is provided by this summary. Refer to the actual endorsement (Pages 3-through-9) for changes affecting your
insurance protection.
DESCRIPTION
Additional Insureds — Primary and Non-Contributory Provision
Blanket Additional Insureds — As Required By Contract
·
Owners, Lessees or Contractors (includes Architects, Engineers or Surveyors)
·
Lessors of Leased Equipment
·
Managers or Lessors of Premises
·
Mortgagees, Assignees and Receivers
·
Any Other person or organization other than a joint venture
·
Grantors of Permits
PAGE FOUND
Page 8
Page 5
Broad Form Vendors Coverage
Damage To Premises Rented To You (Including Fire, Lightning or Explosion)
Electronic Data Liability ($100,000)
Employee Definition Amended
Employees As Insureds Modified
Employer's Liability Exclusion Amended (Not applicable in New York)
Incidental Malpractice Exclusion modified
Knowledge of Occurrence, Claim, Suit or Loss
Liberalization Clause
Mental Anguish Amendment (Not applicable to New York)
Newly Formed or Acquired Organizations
Non-Owned Aircraft
Non-Owned Watercraft (under 60 feet)
Not-for-profit Members — as additional insureds
Personal And Advertising Injury — Discrimination Amendment (Not applicable in New York)
Products Amendment (Medical Payments)
Supplementary Payments Amended — Bail Bonds ($5,000) and Loss of Earnings ($1,000)
Two or More Coverage Parts or Policies Issued By Us
Unintentional Failure to Disclose Hazards
Waiver of Transfer of Rights of Recovery (subrogation)
When Two or More Coverage Parts of this Policy Apply to a Loss
Page 7
Page 3
Page 4
Page 9
Page 5
Page 3
Page 8
Page 8
Page 8
Page 10
Page 5
Page 3
Page 3
Page 5
Page 9
Page 4
Page 4
Page 9
Page 8
Page 8
Page 3

INSURED'S COPY
CG 73 00 06 22
Copyright, 2021 Selective Insurance Company of America. All rights reserved.
Includes copyrighted material of Insurance Services Office, Inc., with its permission.
Page 2 of 10
THIS PAGE IS INTENTIONALLY LEFT BLANK.

Copyright, 2021 Selective Insurance Company of America. All rights reserved.
Includes copyrighted material of Insurance Services Office, Inc., with its permission.
CG 73 00 06 22
INSURED'S COPY
S  2302705
00000F
Page 3 of 10
972
ElitePac
®
General Liability Extension Endorsement
COMMERCIAL GENERAL LIABILITY
CG 73 00 06 22
THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY.
This endorsement modifies the insurance provided under the following:
COMMERCIAL GENERAL LIABILITY COVERAGE PART
The SECTIONS of the Commercial General Liability Coverage Form identified in this endorsement will be amended as
shown below. However, if (a) two or more Coverage Parts of this policy, or (b) two or more forms or endorsements
within the same Coverage Part apply to a loss, coverage provision(s) with the broadest language will apply, unless
specifically stated otherwise within the particular amendment covering that loss.
With respect to coverage provided by this endorsement, the provisions of the Coverage Form apply unless modified by
the endorsement.
COVERAGES — Amendments
SECTION I — COVERAGE A BODILY INJURY AND
PROPERTY DAMAGE LIABILITY
EXCLUSIONS
Employer's Liability Amendment
(This provision is not applicable in the State of New
York).
The following is added to Exclusion e. Employer's
Liability under COVERAGE A BODILY INJURY AND
PROPERTY DAMAGE LIABILITY, 2. Exclusions:
This exclusion also does not apply to any "temporary
worker".
Non-Owned Aircraft, Auto or Watercraft
A.
Paragraph (2) of Exclusion g. Aircraft, Auto Or
Watercraft under COVERAGE A BODILY INJURY
AND
PROPERTY
DAMAGE
LIABILITY,
2.
Exclusions is deleted in its entirety and replaced
with the following:
(2) A watercraft you do not own that is:
(a) Less than 26 feet long and not being used to
carry persons or property for a charge; or
(b) At least 26 feet, but less than 60 feet long,
and not being used to carry persons or
property for a charge. Any person is an
insured who uses or is responsible for the
use of such watercraft with your expressed
or implied consent. However, if the insured
has any other valid and collectible insurance
for "bodily injury" or "property damage" that
would be covered under this provision, or on
any other
basis, this
coverage
is then
excess, and subject to Condition 4. Other
Insurance,
b. Excess Insurance
under 
SECTION IV — COMMERCIAL GENERAL
LIABILITY CONDITIONS.
B.
The following is added to Exclusion g. Aircraft,
Auto Or Watercraft under COVERAGE A BODILY
INJURY AND PROPERTY DAMAGE LIABILITY, 2.
Exclusions:
This exclusion does not apply to:
(6) Any aircraft, not owned or operated by any
insured, which is hired, chartered or loaned with
a paid crew. However, if the insured has any
other valid and collectible insurance for "bodily
injury" or "property damage" that
would be
covered under this provision, or on any other
basis, this coverage is then excess, and subject
to Condition 4. Other Insurance, b. Excess
Insurance
under 
SECTION
IV
—
COMMERCIAL
GENERAL
LIABILITY
CONDITIONS.
Damage To Premises Rented to You
A.
The last paragraph of Paragraph 2. Exclusions 
under COVERAGE
A
BODILY
INJURY
AND
PROPERTY DAMAGE is deleted in its entirety and
replaced with the following:
Exclusions c. through n. do not apply to damage by
fire, lightning or explosion to premises rented to you
or temporarily occupied by you with the permission
of the owner. A separate limit of insurance applies
to this coverage as described in SECTION III -
LIMITS OF INSURANCE.

Copyright, 2021 Selective Insurance Company of America. All rights reserved.
Includes copyrighted material of Insurance Services Office, Inc., with its permission.
CG 73 00 06 22
INSURED'S COPY
Page 4 of 10
B.
Paragraph 6. under SECTION III — LIMITS OF
INSURANCE is deleted in its entirety and replaced
with the following:
6.
Subject to Paragraph 5. above, the most we will
pay under COVERAGE A for damages because
of "property damage" to any one premises,
while rented to you, or in the case of damage
caused by fire,
lightning or explosion, while
rented to you or temporarily occupied by you
with permission of
the owner, for all
such
damage caused by fire, lightning or explosion
proximately caused by the same event, whether
such damage results from
fire,
lightning or
explosion or any combination of the three, is the
amount
shown in
the
Declarations
for
the
Damage To Premises Rented To You Limit.
C.
Paragraph a. of
Definition 9. "Insured contract"
under SECTION V — DEFINITIONS is deleted in its
entirety and replaced with the following:
a.
A contract for a lease of premises. However,
that portion
of the contract for a lease of
premises
that
indemnifies
any
person
or
organization for damage by fire, lightning or
explosion to premises while rented to you or
temporarily occupied by you with the permission
of the owner is not an "insured contract";
Electronic Data Liability
A.
Exclusion
p.
Access
or
Disclosure
Of
Confidential
Or
Personal
Information
And
Data-related
Liability 
under
COVERAGE
A
BODILY
INJURY
AND
PROPERTY
DAMAGE
LIABILITY, 2. Exclusions is deleted in its entirety
and replaced by the following:
p.
Access or
Disclosure
Of Confidential
Or
Personal
Information
And
Data-related
Liability
Damages arising out of:
(1) Any access to or disclosure of any person's
or organization's confidential
or personal
information, including patents, trade secrets,
processing
methods,
customer
lists,
financial information, credit card information
or any other type of nonpublic information;
or
(2) The loss of, loss of use of, damage to,
corruption of, inability to access, or inability
to manipulate "electronic data" that does not
result
from
physical
injury
to
tangible
property.
This exclusion applies even if damages are
claimed for notification costs, credit monitoring
expenses, forensic expenses, public relations
expenses or any other loss, cost or expense
incurred by you or others arising out of that
which is described in Paragraph (1) or (2)
above.
B.
The following paragraph is added to SECTION III —
LIMITS OF INSURANCE:
Subject to 5. above, the most we will pay under 
COVERAGE A for "property damage" because of all
loss of "electronic data" arising out of any one
"occurrence" is a sub-limit of $100,000.
SECTION I — COVERAGE C MEDICAL PAYMENTS
EXCLUSIONS
Any Insured Amendment
Exclusion a.
Any
Insured
under COVERAGE
C
MEDICAL PAYMENTS, 2. Exclusions is deleted in its
entirety and replaced with the following:
a.
Any Insured
To any insured.
This exclusion does not apply to:
(1) "Not-for-profit members";
(2) "Golfing facility" members who are not paid a
fee, salary, or other compensation; or
(3) "Volunteer workers".
This exclusion exception does not apply if COVERAGE
C
MEDICAL
PAYMENTS
is
excluded
by
another
endorsement to this Coverage Part.
Product Amendment
Exclusion f. Products-Completed Operations Hazard 
under
COVERAGE
C
MEDICAL
PAYMENTS,
2.
Exclusions is deleted in its entirety and replaced with
the following:
f.
Products-Completed Operations Hazard
Included within the "products-completed operations
hazard".
This exclusion does not apply to "your products"
sold for use or consumption on your premises, while
such products are still on your premises.
This exclusion exception, does not apply if COVERAGE
C
MEDICAL
PAYMENTS
is
excluded
by
another
endorsement to this Coverage Part.
SECTION
I —
SUPPLEMENTARY
PAYMENTS
—
COVERAGES A AND B
Expenses For Bail Bonds And Loss Of Earnings
A.
Subparagraph 
1.b.
under 
SUPPLEMENTARY
PAYMENTS — COVERAGES A AND B is deleted
in its entirety and replaced with the following:
b.
Up to $5,000 for cost of bail bonds required
because of accidents or traffic law violations
arising out of the use of any vehicle to which
Bodily Injury Liability Coverage applies. We do
not have to furnish these bonds.

Copyright, 2021 Selective Insurance Company of America. All rights reserved.
Includes copyrighted material of Insurance Services Office, Inc., with its permission.
CG 73 00 06 22
INSURED'S COPY
S  2302705
00000F
Page 5 of 10
974
B.
Subparagraph 
1.d.
under 
SUPPLEMENTARY
PAYMENTS — COVERAGES A AND B is deleted
in its entirety and replaced with the following:
d.
All reasonable expenses incurred by the insured
at our request to assist us in the investigation or
defense of the claim or "suit", including actual
loss of earnings up to $1,000 a day because of
time off from work.
SECTION II — WHO IS AN INSURED — Amendments
Not-for-Profit Organization Members
The following paragraph is added to SECTION II —
WHO IS AN INSURED:
If you are an organization other than a partnership, joint
venture, or a limited liability company, and you are a
not-for-profit organization, the following are included as
additional insureds:
1.
Your officials;
2.
Your trustees;
3.
Your members;
4.
Your board members;
5.
Your commission members;
6.
Your agency members;
7.
Your insurance managers;
8.
Your elective or appointed officers; and
9.
Your "not-for-profit members".
However only with respect to their liability for your
activities or activities they perform on your behalf.
Employees As Insureds Modified
A.
Subparagraph 2.a.(1)(a) under SECTION II — WHO
IS AN INSURED does not apply to "bodily injury" to
a "temporary worker" caused by a co-"employee"
who is not a "temporary worker".
B.
Subparagraph 2.a.(2) under SECTION II — WHO IS
AN INSURED does not apply to "property damage"
to the property of a "temporary worker" or "volunteer
worker" caused by a co-"employee" who is not a
"temporary worker" or "volunteer worker".
C.
Subparagraph 2.a.(1)(d) under SECTION II — WHO
IS AN INSURED does not apply to "bodily injury"
caused by cardio-pulmonary resuscitation or first aid
services administered by a co-"employee".
With respect to this provision only, Subparagraph (1) of
Exclusion 2. e. Employer's Liability under SECTION I
— COVERAGES, COVERAGE A BODILY INJURY
AND PROPERTY DAMAGE LIABILITY does not apply.
Newly Formed Or Acquired Organizations
A.
Subparagraph 3.a. under SECTION II — WHO IS
AN INSURED is deleted in its entirety and replaced
with the following:
a.
Coverage under this provision is afforded only
until the 180th day after you acquire or form the
organization or the end of the policy period,
whichever is earlier. However, COVERAGE A
does not apply to "bodily injury" or "property
damage" that occurred before you acquired or
formed the organization.
B.
The following paragraph is added to SECTION
II — WHO IS AN INSURED, Paragraph 3:
If
you
are
engaged
in
the
business
of
construction of dwellings three stories or less in
height, or other buildings three stories or less in
height and less than 25,000 square feet in area,
you will also be an insured with respect to "your
work" only, for the period of time described
above,
for your
liability
arising
out of
the
conduct of any partnership or joint venture of
which you are or were a member, even if that
partnership or joint venture is not shown as a
Named Insured. However, this provision only
applies if you maintain or maintained an interest
of at least fifty percent in that partnership or
joint venture for the period of that partnership or
joint venture.
This provision does not apply to any partnership or joint
venture that has been dissolved or otherwise ceased to
function for more than thirty-six months.
With respect to the insurance provided by this provision, 
Newly
Formed
or
Acquired
Organizations,
the
following is added to SECTION IV — COMMERCIAL
GENERAL LIABILITY, Paragraph 4. Other Insurance,
Subparagraph b. Excess Insurance:
The
insurance
provided
by
this
provision,
Newly
Formed or Acquired Organizations, is excess over
any other insurance available to the insured, whether
primary, excess, contingent or on any other basis.
(All other provisions of this section remain unchanged)
Blanket
Additional Insureds
— As Required By
Contract
A.
Subject to the Primary and
Non-Contributory
provision set forth in this endorsement, SECTION II
— WHO IS AN INSURED is amended to include as
an additional insured:
1.
Owners, Lessees or Contractors/Architects,
Engineers and Surveyors
a.
Any person or organization for whom you
are performing operations when you and
such person or organization have agreed in
a written contract,
written agreement or
written
permit
that
such
person
or
organization
be added as
an additional
insured on your commercial general liability
policy; and

Copyright, 2021 Selective Insurance Company of America. All rights reserved.
Includes copyrighted material of Insurance Services Office, Inc., with its permission.
CG 73 00 06 22
INSURED'S COPY
Page 6 of 10
b.
Any other person or organization, including
any architects, engineers or surveyors not
engaged by you, whom you are required to
add as an additional insured under your
policy
in the
contract
or
agreement in
Paragraph a. above:
Such person or organization is an additional
insured only with respect to liability for "bodily
injury",
"property damage" or "personal and
advertising injury" caused, in whole or in part,
by:
(1) Your acts or omissions; or
(2) The acts of omissions of those acting on
your behalf;
in the performance of your ongoing operations
performed
for
the
additional
insured
in
Paragraph a., above.
However, this insurance does not apply to:
"Bodily injury", "property damage" or "personal
and
advertising
injury"
arising
out
of
the
rendering
of,
or the failure
to
render,
any
professional
architectural,
engineering
or
surveying services by or for you, including:
(1) The
preparing,
approving,
or
failing
to
prepare or approve, maps, shop drawings,
opinions,
reports,
surveys,
field
orders,
change
orders
or
drawings
and
specifications; and
(2) Supervisory,
inspection,
architectural
or
engineering activities.
Professional services do not include services
within
construction
means,
methods,
techniques,
sequences
and
procedures
employed
by
you
in
connection
with
your
operations in your capacity as a construction
contractor.
A
person
or
organization's
status
as
an
additional insured under this endorsement ends
when
your
operations
for
the
person
or
organization described in Paragraph a. above
are completed.
2.
Other Additional Insureds
Any of the following persons or organizations
with
whom
you
have
agreed in
a
written
contract, written agreement or written permit
that such persons or organizations be added as
an
additional
insured
on
your
commercial
general liability policy:
a.
Lessors of Leased Equipment
Any person or organization from whom you
lease equipment, but only with respect to
liability
for
"bodily
injury",
"property
damage"
or
"personal
and
advertising
injury" caused, in whole or in part, by your
maintenance, operation or use of equipment
leased
to
you
by
such
person
or
organization.
With respect to the insurance afforded to
these additional
insureds, this insurance
does not apply to any "occurrence" which
takes
place
after
the
equipment
lease
expires.
b.
Managers or Lessors of Premises
Any person or organization from whom you
lease premises, but only with respect to
liability
for
"bodily
injury",
"property
damage"
or
"personal
and
advertising
injury" caused, in whole or in part, by you or
those acting on your behalf in connection
with the ownership, maintenance or use of
that part of the premises leased to you.
This
insurance
does
not
apply
to
any
"occurrence" which takes place after you
cease to be a tenant of that premises.
c.
Mortgagees, Assignees or Receivers
Any person or organization with respect to
their liability
as mortgagee, assignee or
receiver and arising out of the ownership,
maintenance or use of your premises.
This
insurance
does
not
apply
to
any
"occurrence" which takes place after the
mortgage is satisfied, or the assignment or
receivership ends.
d.
Any Person or Organization Other Than
A Joint Venture
Any person or organization (other than a
joint venture of which you are a member),
but only with respect to liability for "bodily
injury", "property damage" or "personal and
advertising injury" caused, in whole or in
part, by your acts or omissions or the acts of
omissions of those acting on your behalf in
the performance of your ongoing operations
or in connection with property owned by
you.
e.
State
or
Governmental
Agency
or
Political
Subdivision
—
Permits
or
Authorizations
Any
state
or
governmental
agency
or
subdivision or political subdivision, but only
with respect to:
(1) Operations performed by you or on your
behalf
for
which
the
state
or
governmental agency or subdivision or
political subdivision has issued a permit
or authorization; or

Copyright, 2021 Selective Insurance Company of America. All rights reserved.
Includes copyrighted material of Insurance Services Office, Inc., with its permission.
CG 73 00 06 22
INSURED'S COPY
S  2302705
00000F
Page 7 of 10
976
(2) The following hazards for which the
state
or
governmental
agency
or
subdivision or political subdivision has
issued
a permit
or
authorization
in
connection with premises you own, rent
or control and to which this insurance
applies:
(a) The existence, maintenance, repair,
construction, erection or removal of
advertising
signs,
awnings,
canopies,
cellar
entrances,
coal
holes,
driveways,
manholes,
marquees,
hoist
away
openings,
sidewalk vaults, street banners or
decorations and similar exposures;
(b) The
construction,
erection
or
removal of elevators; or
(c) The ownership, maintenance or use
of any elevators covered by this
insurance.
This insurance does not apply to:
i.
"Bodily
injury"
or
"property
damage"
arising
out
of
operations
performed
for
the
federal
government,
state
or
municipality; or
ii.
"Bodily
injury"
or
"property
damage"
included
within
the
"products-completed operations
hazard".
With respect to Paragraphs 2.b. through 
2.d.,
this
insurance
does
not
apply
to
structural alterations, new construction or
demolition operations performed by or on
behalf of such person or organization.
B.
The insurance coverge afforded to the additional
insureds in this coverage extension:
1.
Does not apply unless the written contract or
written
agreement has been signed by the
Named Insured or written permit issued prior to
the "bodily injury"
or "property damage" or
"personal and advertising injury";
2.
Only applies to the extent permitted by law; and
3.
Will not be broader than that which you are
required
by
the
written
contract,
written
agreement, or written permit to provide to such
additional insured.
C.
With respect to the insurance afforded to these
additional
insureds,
the
following
is
added
to 
Section III — Limits Of Insurance:
The most we will pay on behalf of the additional
insured is the amount of insurance:
1.
Required
by
the
written
contract,
written
agreement or written permit you have entered
into with the additional insured; or
2.
Available
under
the
applicable
limits
of
insurance;
whichever is less.
The insurance provided by this extension shall not
increase the applicable limits of insurance.
Broad Form Vendors Coverage
Subject
to
the 
Primary
and
Non-Contributory
provision set forth in this endorsement, SECTION II —
WHO IS AN INSURED is amended to include as an
additional insured any person or organization (referred
to below as vendor) for whom you have agreed in a
written
contract
or
written
agreement
to
provide
coverage as an additional insured under your policy.
Such person or organization is an additional insured
only with respect to "bodily injury" or "property damage"
arising out of "your products" which are distributed or
sold in the regular course of the vendor’s business.
However, the insurance afforded the vendor does not
apply to:
a.
"Bodily injury" or "property damage" for which
the vendor is obligated to pay damages by
reason of the assumption of liability in a contract
or agreement; however this exclusion does not
apply to liability for damages that the vendor
would have in the absence of the contract or
agreement;
b.
Any express warranty unauthorized by you;
c.
Any physical or chemical change in the product
made intentionally by the vendor;
d.
Repackaging, unless unpacked solely for the
purpose of inspection, demonstration, testing, or
the substitution of parts under instructions from
the manufacturer, and then repackaged in the
original container;
e.
Any
failure
to
make
such
inspections,
adjustments, tests or servicing as the vendor
has agreed to make or normally undertakes to
make
in
the
usual
course
of
business in
connection with the sale of the product; or
f.
Products which, after distribution or sale by you,
have been labeled or re-labeled or used as a
container, part of ingredient of any other thing or
substance by or for the vendor; however this
insurance does not apply to any insured person
or organization, from who you have acquired
such
products,
or
any
ingredient,
part
or
container,
entering
into,
accompanying
or
containing such products.
The provisions of this coverage extension do not apply
unless the written contract or written agreement has
been signed by the Named Insured prior to the "bodily
injury" or "property damage".

Copyright, 2021 Selective Insurance Company of America. All rights reserved.
Includes copyrighted material of Insurance Services Office, Inc., with its permission.
CG 73 00 06 22
INSURED'S COPY
Page 8 of 10
Incidental Malpractice
Subparagraph 2.a.(1)(d) under SECTION II — WHO IS
AN INSURED is deleted in its entirety and replaced with
the following:
(d) Arising out of his or her providing or failing to
provide professional health care services.
This does not apply to nurses, emergency medical
technicians or paramedics if you are not in the
business or
occupation
of
providing
any such
professional services.
This also does not apply to "bodily injury" caused by
cardio-pulmonary resuscitation or first aid services
administered by a co-"employee".
This provision does not apply if you are a Social Service
or Senior Living risk.
SECTION IV — COMMERCIAL GENERAL LIABILITY
CONDITIONS — Amendments
Knowledge Of Occurrence, Claim, Suit Or Loss
The following is added to Paragraph 2. Duties in the
Event of Occurrence, Offense, Claim or Suit under 
SECTION IV — COMMERCIAL GENERAL LIABILITY
CONDITIONS:
The requirements under this paragraph do not apply
until after the "occurrence" or offense is known to:
1.
You, if you are an individual;
2.
A partner, if you are a partnership;
3.
An "executive officer" or insurance manager, if you
are a corporation;
4.
Your members, managers or insurance manager, if
you are a limited liability company; or
5.
Your
elected
or
appointed
officials,
officers,
members, trustees, board members, commission
members, agency members, or your administrator
or
your
insurance
manager
if
you
are
an
organization other than a partnership, joint venture,
or limited liability company.
Primary and Non-Contributory Provision
The
following
is
added
to
Paragraph
4.
Other
Insurance, b. Excess Insurance under SECTION IV —
COMMERCIAL GENERAL LIABILITY CONDITIONS:
This insurance is primary to and we will not seek
contribution from any other insurance available to an
additional insured under this policy provided that:
(1) The additional insured is a Named Insured under
such other insurance; and
(2) You have agreed in a written contract,
written
agreement or written permit
that this insurance
would be primary and would not seek contribution
from any other insurance available to the additional
insured.
Unintentional Failure To Disclose Hazards
The
following
is
added
to
Paragraph 
6.
Representations
under 
SECTION
IV
—
COMMERCIAL GENERAL LIABILITY CONDITIONS:
However, if you should unintentionally fail to disclose
any existing hazards in your representations to us at the
inception date of the policy, or during the policy period
in connection with any additional hazards, we shall not
deny coverage under this Coverage Part based upon
such failure to disclose hazards.
Waiver Of Transfer Of Rights Of Recovery
The following is added to Paragraph 8. Transfer of
Rights Of Recovery Against Others To Us under 
SECTION IV — COMMERCIAL GENERAL LIABILITY
CONDITIONS:
We will waive any right of recovery against a person or
organization because of payments we make under this
Commercial
General
Liability
Coverage
Part.
This
waiver applies only if the insured has agreed in a written
contract or written agreement to:
1.
Waive any right of recovery against that person or
organization; or
2.
Assume the liability of that person or organization
pursuant to a written contract or written agreement
that qualifies as an "insured contract"; and
3.
Include such person or organization as an additional
insured on your policy.
Such waiver by us applies only to that person or
organization identified above, and only to the extent that
the insured has waived its right of recovery against such
person or organization prior to loss.
Liberalization
The following condition is added to SECTION IV —
COMMERCIAL GENERAL LIABILITY CONDITIONS:
If
we revise
this Coverage
Part to
provide
more
coverage without additional premium charge, subject to
our filed company rules, your policy will automatically
provide the additional coverage as of
the day the
revision is effective in your state.

Copyright, 2021 Selective Insurance Company of America. All rights reserved.
Includes copyrighted material of Insurance Services Office, Inc., with its permission.
CG 73 00 06 22
INSURED'S COPY
S  2302705
00000F
Page 9 of 10
978
Two or More Coverage Parts or Policies Issued By
Us
(This provision is not Applicable in the state of New York
or Wisconsin).
The following condition is added to SECTION IV —
COMMERCIAL GENERAL LIABILITY CONDITIONS:
It is our intention that the various coverage parts or
policies issued to you by us, or any company affiliated
with us, do not provide any duplication or overlap of
coverage. We have exercised diligence to draft our
coverage parts and policies to reflect this intention.
However,
if
the facts
and
circumstances
that
will
respond to any claim or "suit" give rise to actual or
claimed duplication or overlap of coverage between the
various coverage parts or policies issued to you by us or
any company affiliated with us, the limit of insurance
under all such coverage parts or policies combined shall
not exceed
the highest
applicable
limit
under this
coverage, or any one of the other coverage forms or
policies.
This condition does not apply to any Excess or Umbrella
policy issued by us specifically to apply as excess
insurance over this coverage part or policy to which this
coverage part is attached.
SECTION V — DEFINITIONS
Discrimination
(This provision does not apply in New York).
A.
The following is added to Definition 14. "Personal
and advertising injury":
"Personal
and
advertising
injury"
also
means
"discrimination" that results in injury to the feelings
or reputation of a natural person, however only if
such "discrimination" or humiliation is:
1.
Not done by or at the direction of:
a.
The insured; orb. Anyone considered an
insured under SECTION II — WHO IS AN
INSURED;
2.
Not done intentionally to cause harm to another
person.
3.
Not
directly
or
indirectly
related
to
the
employment,
prospective
employment
or
termination of employment of any person or
persons by any insured.
4.
Not arising out of any "advertisement" by the
insured.
B.
The following definition is added to SECTION V —
DEFINITIONS:
"Discrimination" means:
a.
Any act or conduct that would be considered
discrimination
under
any applicable
federal,
state, or local statute, ordinance or law;
b.
Any act or conduct that results in disparate
treatment of, or has disparate impact on, a
person, because of that person's race, religion,
gender, sexual orientation, age, disability or
physical impairment; or
c.
Any act or conduct characterized or interpreted
as discrimination by a person based on that
person's
race,
religion,
gender,
sexual
orientation,
age,
disability
or
physical
impairment.
It does not include acts or conduct characterized or
interpreted
as
sexual
intimidation
or
sexual
harassment, or intimidation or harassment based on
a person's gender.
Electronic Data
The following definition is added to SECTION V —
DEFINITIONS:
"Electronic data" means information, facts or programs
stored as or on, created or used on, or transmitted to or
from
computer
software,
including
systems
and
applications software, hard or floppy disks, CD-ROMS,
tapes, drives, cell, data processing devices or any other
media which are used with electronically
controlled
equipment. For the purpose of the Electronic Data
Liability
coverage
provided
by
this
endorsement,
Definition 17. "Property damage" is deleted in its entirety
and replaced by the following:
17. "Property damage" means:
a.
Physical injury to tangible property, including all
resulting loss of use of that property. All such
loss of use shall be deemed to occur at the time
of the physical injury that caused it; or
b.
Loss of, loss of use of, damage to, corruption of,
inability
to
access,
or
inability
to
properly
manipulate
"electronic
data",
resulting
from
physical injury to tangible property. All such loss
of "electronic data" shall be deemed to occur at
the time of the "occurrence" that caused it.
For the purpose of the Electronic Data Liability coverage
provided by this endorsement, "electronic data" is not
tangible property.
Employee Amendment
Definition 
5. "Employee"
under SECTION
V
—
DEFINITIONS is deleted in its entirety and replaced by
the following:
5.
"Employee"
includes
a
"leased
worker",
or
a
"temporary worker". If you are a School, "Employee"
also includes a student teacher.
Golfing Facility
The following definition is added to SECTION V —
DEFINITIONS:
"Golfing facility" means a golf course, golf club, driving
range, or miniature golf course.

Copyright, 2021 Selective Insurance Company of America. All rights reserved.
Includes copyrighted material of Insurance Services Office, Inc., with its permission.
CG 73 00 06 22
INSURED'S COPY
Page 10 of 10
Mental Anguish Amendment
(This provision does not apply in New York).
Definition 3.
"Bodily
injury" under SECTION
V
—
DEFINITIONS is deleted in its entirety and replaced with
the following:
3.
"Bodily
injury" means bodily
injury, sickness or
disease sustained by a person, including death
resulting from any of
these at any time.
This
includes mental anguish resulting from any bodily
injury, sickness or disease sustained by a person.
(In New York, mental anguish has been determined
to be "bodily injury").
Not-for-profit Member
The following definition is added to SECTION V —
DEFINITIONS:
"Not-for-profit
member"
means a person who is a
member of a not-for-profit organization, including clubs
and
churches, who receives
no financial
or
other
compensation.

Included with your offer, your firm/company is required to ackn~wledge this addendum, 
and every addendum, relating to this solicitation by completing ~he following information: 
Addendum No. 2 Acknowledgement: 
' 
TSG Constructors, LLC 
Firm Name 
~ 
Manager 
Title 
Stanley S. Showalter 
Signatory Printed Name 
09.28.23 
Date 
Addendum No 2 To Clerk of the Superior Court SE Remodel - 240017-D~B 
Page 2 of 2

Included with your offer, your firm/company is required to ackn wledge this addendum, 
and every addendum, relating to this solicitation by completing ~he following information: 
Addendum No. 1 Acknowledgement: 
TSG Constructors, LLC 
Firm Name 
~ 
Manager 
Title 
Stanley S. Showalter 
Signatory Printed Name 
09.28.23 
Date 
) 
Addendum No 1 To Clerk of the Superior Court SE Remodel - 240017-DBe 
I 
Page 2 of2

Clerk of the Superior Court SE Remodel 
Serial # 240017-DBB 
Request for Bids - Design Bid Build 
Pg. # 17 
Attachment A - BID FORM 
TO THE BOARD OF SUPERVISORS 
MARICOPA COUNTY 
PHOENIX, ARIZONA 
Gentlemen: 
The following bid is made for constructing Serial #240017-DBB, Clerk of the Superior Court SE Remodel, in 
the County of Maricopa, State of Arizona. 
The following bid is made on behalf of 
 , 
and no others, in the amount of $      
 . 
The maximum allowable overhead rate & profit rate applicable to any future project change orders or revisions 
shall be:  
Overhead Rate: 10 percent 
Profit Rate:  
5 percent 
Evidence of authority to submit the bid is herewith furnished. The bid is, in all respects, fair and is made without 
collusion on the part of any person, firm, or corporation mentioned above, and no member or employee of the 
Board of Supervisors (BOS) is personally or financially interested, directly or indirectly, in the bid, or in any 
purchase or sale of any materials or supplies for the work to which it relates, or in any portion of the profits 
thereof. 
The undersigned certifies that the approved plans, Construction Special Provisions, forms of contract, bonds, 
and sureties authorized by the BOS and constituting essential parts of this bid have been carefully examined 
and also that the site of the work has been personally inspected. 
The undersigned declares that the amount and nature of the work to be done is understood and that at no time 
will misunderstanding of the plans, Construction Special Provisions, bid/contract documents or conditions to be 
overcome, be pled. On the basis of the plans, Construction Special Provisions, bid/contract documents, the 
forms of contract, bonds, and sureties proposed for use, the undersigned shall furnish all the necessary 
machinery, equipment, tools, apparatus, and other means of construction, to do all the work, and to furnish all 
the materials in the manner specified, and to finish the entire project within the time promised, and to accept, 
as full compensation therefore, the sum of various products obtained by multiplying each unit price, herein bid 
for the work or materials, by the quantity thereof actually incorporated in the complete project, as determined 
by the engineer. 
The undersigned understands that the quantities mentioned herein are approximate only and are subject to 
increase or decrease and hereby promises to perform all quantities of work, as either increased or decreased, 
in accordance with the provisions of the construction documents. 
The undersigned shall perform all extra work that may be required on the basis provided in the construction 
documents and to give such work personal attention and to secure economic performance. 
The undersigned shall further execute the Contract Agreement and furnish satisfactory bonds and sureties 
within 10 days of receipt of Notice of Bid acceptance, TIME BEING OF THE ESSENCE. The undersigned 
further proposes to begin work as specified in the contract attached hereto, and to complete the work within 
365 CALENDAR DAYS from the effective date specified in the Notice to Proceed and maintain at all times a 
payment bond and a performance bond, approved by the BOS, each in an amount equal to one hundred percent 
of the contract amount. These bonds shall serve not only to guarantee the completion of the work on the part 
of the undersigned, but also to guarantee the excellence of both workmanship and material and the payment 
of all obligations incurred, said bonds and sureties to be in full force and effect until the work is finally accepted 
and the provisions of the plans, construction specifications, and Construction Special Provisions fulfilled. 
A bid bond in the amount and character named in the Invitation to Bid is enclosed amounting to not less than 
10 percent of the total bid. The bid bond is submitted as a guaranty of the good faith of the bidder and the 
bidder will enter into written contract, as provided, to do the work, if successful in securing the award thereof; 
Bid 240017-DBB
Maricopa County
9/6/2023 3:32 PM
p. 882
TSG Constructors, LLC
2,477,000.00

Maricopa County 
Bid 240017-DBB 
and it is hereby agreed that if, at any time other than as provided in the bid requirements and conditions, the 
undersigned should withdraw its bid, if the bid is accepted and there shopld be failure on the part of the 
undersigned to execute the contract and furnish satisfactory bonds and sureties as herein provided, the County 
of Maricopa in either of such events, shall be entitled and is hereby given th~ right to retain the said bid bond 
as liquidated damages. 
I 
The undersigned has enclosed the required bid security to this bid. 
IF BY AN INDIVIDUAL: NIA 
By: _________________ 
_ 
(Printed Name) 
(Title) 
(Telep~one Number) 
I 
I 
(Signature) 
(Date) 
(Fax Number) 
i 
(Address) 
(Email 1Address) 
I 
IF BY A FIRM, PARTNERSHIP ORLL.C. (LIMITED LIABILITY CORPOR4TION): 
By: TSG Constructors, LLC 
(Firm Name) 
~ 
Member 
(Title) 
09.28.23 
(Date) 
2340 W. Parkside Lane, Suite H105, Phoenix, AZ 85027 
(Firm Address) 
s23L742-01s1 
(Telephone Number) 
I 
N/A 
I 
(Fax ~umber) 
I 
s.sh01,yalter@tsgconstructors.com 
(Emai
11 Address) 
**N amean dAdd 
f 
h 
ress o eac 
b 
mem er, or eac h mana aero .. . oer Ioeratina Aareement 
fl LC 
0 
Stanley S. Showalter 
I 
5237 E. Baker Dr. 
I 
Cave Creek, AZ 85331 
I 
Kerry S. Showalter 
I 
5237 E. Baker Dr. 
I 
Cave Creek, AZ 85331 
I 
I 
I 
I 
I 
I 
I 
** 
,1. 
The name and post office address of each member of the firm or partnership must be shown, or of each 
manager of an L.L.C., also address of the registered office of the L.IL.C. 
Clerk of the Superior Court SE Remodel 
Request for Bids - Design Bid Build 
9/6/2023 3:32 PM 
I 
Serial# 240017-DBB 
Pg. #18 
p.883

Clerk of the Superior Court SE Remodel 
Serial # 240017-DBB 
Request for Bids - Design Bid Build 
Pg. # 19 
IF BY A CORPORATION: 
(Corporate Name)* 
(Corporation Address) 
(Printed Name) 
(Title) 
(Telephone Number) 
(Fax Number) 
(Signature) 
(Date) 
(Email Address) 
*Incorporated under the Laws of the State of __________ and Names and Addresses of Officers:
(President) 
(Address) 
(Secretary) 
(Address) 
(Treasurer) 
(Address) 
*The name of the State under which the Laws of the Corporation was chartered, and the name,
title, and business address of the president, secretary, and treasurer must be shown.
Bid 240017-DBB
Maricopa County
9/6/2023 3:32 PM
p. 884
N/A

Clerk of the Superior Court SE Remodel 
Serial # 240017-DBB 
Request for Bids - Design Bid Build 
Pg. # 20 
Attachment B - SUBCONTRACTOR LISTING 
SUBMIT THIS ATTACHMENT B WITH EITHER: 
1) your bid package; or
2) within 24 hours after this solicitation’s due date.
The following is a listing of material suppliers and/or subcontractors which will be used by contractor in the 
event the undersigned enters into a contract with the County. No changes of the subcontractors and 
material suppliers named herein shall be made without the prior written approval of the County. If 
submitting with 24 hours of the bid due date/time, email the completed Attachment B to the 
corresponding procurement officer and note that in the fields below. 
(Signature) 
(Title) 
(Date) 
Bid 240017-DBB
Maricopa County
9/6/2023 3:32 PM
p. 885
Stanley S. Showalter
Manager
09.29.23
Demolition: M & P Venture Partners Demolition, LLC
Casework & Solid Surface: Red Mountain Woodworking & Design, LLC
Thermal & Acoustical Insulation: Builder Services Group, Inc.
Doors, Frames & Hardware Supplier:  Eighty-Nine A
Glass & Glazing: Carlson Glass Inc.
Drywall & Light Guage Framing: Universal Construction, LLC

Clerk of the Superior Court SE Remodel 
Serial # 240017-DBB 
Request for Bids - Design Bid Build 
Pg. # 20 
Attachment B - SUBCONTRACTOR LISTING 
SUBMIT THIS ATTACHMENT B WITH EITHER: 
1) your bid package; or
2) within 24 hours after this solicitation’s due date.
The following is a listing of material suppliers and/or subcontractors which will be used by contractor in the 
event the undersigned enters into a contract with the County. No changes of the subcontractors and 
material suppliers named herein shall be made without the prior written approval of the County. If 
submitting with 24 hours of the bid due date/time, email the completed Attachment B to the 
corresponding procurement officer and note that in the fields below. 
(Signature) 
(Title) 
(Date) 
Bid 240017-DBB
Maricopa County
9/6/2023 3:32 PM
p. 885
Stanley S. Showalter
Manager
09.29.23
Acoustical Ceilngs Acoustical Panels:  R N R Ceilngs & Walls, LLC
Flooring & Ceramic Tile: Clayton Floor Covering and Design
Painting: Gutierrez Painting, LLC
Roller Shades: Interiortek  Inc.
Fire Sprinklers: Advanced Fire Protection, Inc.
Plumbing: TS  Plumbing Company, Inc. DBA Tek Star Plumbing and Mechanical

Clerk of the Superior Court SE Remodel 
Serial # 240017-DBB 
Request for Bids - Design Bid Build 
Pg. # 20 
Attachment B - SUBCONTRACTOR LISTING 
SUBMIT THIS ATTACHMENT B WITH EITHER: 
1) your bid package; or
2) within 24 hours after this solicitation’s due date.
The following is a listing of material suppliers and/or subcontractors which will be used by contractor in the 
event the undersigned enters into a contract with the County. No changes of the subcontractors and 
material suppliers named herein shall be made without the prior written approval of the County. If 
submitting with 24 hours of the bid due date/time, email the completed Attachment B to the 
corresponding procurement officer and note that in the fields below. 
(Signature) 
(Title) 
(Date) 
Bid 240017-DBB
Maricopa County
9/6/2023 3:32 PM
p. 885
Stanley S. Showalter
Manager
09.29.23
HVAC: DAL Air Conditioning and Heating Partners, LLC
Electrical: Apache Power and Water, Inc.
Video Surveilance & Access Control: Enterprise Security, Inc.
Cabling: Kearney Electric, inc.
Fire Alarm: Climatec, LLC DBA Climatec Building Technologies Group

Maricopa County 
Bid 240017-DBB 
Attachment C - LEGAL WORKER CERTIFICATION 
09.28.23 
(Date) 
Maricopa County 
Office of Procurement Services - Article 5 
301 W. Jefferson Street, Suite 700 
Phoenix, Arizona 85003 
As required by Arizona Revised Statutes (A.RS.)§ 41-4401, Maricopa C ,unty (County) is prohibited, after 
September 30, 2008, from awarding a contract to any contractor who fails[, or whose subcontractors fail, to 
comply with A.RS. § 23-214-A. The undersigned entity warrants that it complies fully with all Federal 
immigration laws and regulations that relate to its employees, that it shall [verify, through E-Verify as jointly 
administered by the U.S. Department of Homeland Security and the Social /Security Administration, or any of 
its successor programs, the employment eligibility of each employee hired after December 31, 2007, and that 
it shall require its subcontractors and sub-subcontractors to provide the sanlie warranties to the below entity. 
The undersigned acknowledges that a breach of this warranty by the beloJ entity or by any subcontractor or 
sub-subcontractor under any contract resulting from this solicitation shall bE!l deemed a material breach of the 
contract, and is grounds for penalties, including termination of the contract, p. y the County. The County retains 
the right to inspect the records of the below entity, subcontractor, and sub-subcontractor employee who 
performs work under the contract, and to conduct random verification of th~ employment records of the below 
entity and any subcontractor and sub-subcontractor who works on the contract, to ensure that the below entity 
and each subcontractor and sub-subcontractor is complying with the warrahties set forth above. 
TSG Constructors, LLC 
Firm 
Stanley S. Showalter 
Print Name 
Manager 
Print Title 
s.showalter@tsgconstructors.com 
Clerk of the Superior Court SE Remodel 
Request for Bids - Design Bid Build 
9/6/2023 3:32 PM 
09.28.23 
Date 
2340 W. Parksid~ Lane, Suite H105 
Address Line 1 
Phoenix, AZ 85027 
Address Line~ 
623-742-0161 
Phone 
N/A 
Fax 
90-0275459 
Federal Taxpayer ID Number 
Serial# 240017-DBB 
Pg. #21 
p. 886

Maricopa County 
Bid 240017-DBB 
' Attachment D - SURETY BOND 
KNOW ALL MEN BY THESE PRESENTS: 
That we, TSG Constructors, LLC 
, as Principal, (here)inafter called the Principal), and the 
Travelers Casualty and Surety Company of America a corporation duly organized under the laws of the State of 
Connecticut 
, as Surety, (hereinaft~r called the Surety), are held and firmly 
bound unto Maricopa County (hereinafter called the Obligee), in the sum bf 10 percent of the total amount of the 
bid of Principal, submitted by him to the Obligee, for the work described b,low, for the payment of which sum, well 
and truly to be made, the said Principal and the said Surety, bind themselvfs, their heirs, executors, administrators, 
successors and assigns, jointly and severally, firmly by these presents1 and in conformance with the Arizona 
Revised Statutes (A.RS.). 
1 
WHEREAS, the said Principal is herewith submitting its Bid for Serial #24J017-DBB, Clerk of the Superior Court 
SE Remodel. 
NOW, THEREFORE, if the Obligee shall accept the bid of the Principal ane the Principal shall enter into a contract 
with the Obligee in accordance with the terms of. the bid and give the ponds and Certificates of· Insurance as -
specified in the Standard Specifications with good and sufficient Surety for the faithful performance of the contract 
and for the prompt payment of labor and material furnished in the prosecu~ion of the contract, or in the event of the 
failure of the Principal to enter into the contract and give such bonds and Certificates of Insurance, if the Principal 
pays to the Obligee the difference not to exceed the penalty of the bond retween the amount specified in the bid 
and such larger amount for which the Obligee may in good faith contrac with another party to perform the work 
covered by the bid then this obligation is void. Otherwise, it remains in ful~ force and effect, provided however, that 
this bond is executed pursuant to the provisions of Section 34-201, A.R.$., and all liabilities on this bond shall be 
determined in accordance with the provisions of the section to the extent j5 if it were copied at length herein. 
Signed and sealed this 26th 
day of September 
20 23 
. 
Constructors Bonding, Inc. 
TSG Corlstructors, LLC 
Agent of Record, State of Arizona 
7220 N. 16th Street, Bldg K, Phoenix, AZ 85020 
Agent Address 
Bond Number Bid Bond 
------------
Jennifer Castillo, Attorney-in-fact 
Power of Attorney 
Clerk of the Superior Court SE Remodel 
Request for Bids - Design Bid Build 
9/6/2023 3:32 PM 
Principal 
I 
Seal 
B~-1~='------
By: 
Seal 
\ 
Serial# 240017-DBB 
Pg. #22 
p.887

TRAVELERs'J"' 
I 
Travelers Casual~ and Surety. Company of America 
Travelers Casua1
1
~ 
and Surety Company 
St. Paul Fire and1 Marine Insurance Company 
POWER OF ATTORNEY 
1 
KNOW ALL MEN BY THESE PRESENTS: That Travelers Casualty and Surety Company of Ame~ca, Travelers Casualty and Surety Company, and 
St. Paul Fire and Marine 
Insurance Company are corporations duly organized under the laws of the State of Connecticut (herein 
collectively called the "Companies"), and that the Companies do hereby make, constitute and appoint I Jennifer Castillo 
of 
PHOENIX 
, Arizona 
, their true 
and 
lawful · Attorney(s)-in-Fact to 
sign, 
execute, 
seal and 
acknowledge 
any 
and 
all 
bonds, 
recognizances, conditional undertakings and other writings obligatory in the nature thereof on behalf of 
the Companies in their business of guaranteeing the fidelity of persons, 
guaranteeing 
thI:' pelformance of contracts and executing or 
guaranteeing bonds and undertakings required or permitted in any actions or proceedings al owed by law. 
IN WITNESS WHEREOF, the Companies have caused this instrument to be signed, and their corpor ,le seals to be hereto affixed, this 21st day of April, 
2021. 
. 
State of Connecticut 
City of Hartford ss. 
On this the 21st day of April, 2021, before me personally appeared Robert L. Raney,! who acknowledged himself to be the Senior 
Vice President of each of the Companies, and that he, as such, being authorized so to ~o. executed the foregoing instrument for the 
purposes therein contained by signing on behalf of said Companies by himself as a duly authorized officer. 
IN WITNESS WHEREOF, I hereunto set my hand and official seal. 
My Commission expires the 30th day of June, 2026 
© 
I 
I 
Anna P. Nowik, Notary Public 
This Power of Attorney is granted under and by the authority of the following resolutions 
1adopted by the Boards of Directors of each of 
the Companies, which resolutions are now in full force and effect, reading as follows: 
RESOLVED, that the Chairman, the President, any Vice Chairman, any Executive Vice !President, any Senior Vice President, any Vice 
President, any Second Vice President, the Treasurer, any Assistant Treasurer, the Corporate Secretary or any Assistant Secretary may appoint 
Attorneys-in-Fact and Agents to act for and on behalf of the Company and may give such appoint~e such authority as his or her certificate of authority 
may prescribe to sign with the Company's name and seal with the Company's seal bonds, recognizances, contracts of indemnity, and other writings 
obligatory in the nature of a bond, recognizance, or conditional undertaking, and any of said qfficers or the Board of Directors at any time may 
remove any such appointee and revoke the power given him or her; and it is 
FURTHER RESOLVED, that the Chairman, the President, any Vice Chairman, any Execut~e Vice President, any Senior Vice President or 
any Vice President may delegate all or any part of the foregoing authority to one or more 1officers or employees of this Company, provided 
that each such delegation is in writing and a copy thereof is filed in the office of the Secretary; and it is 
FURTHER RESOLVED, that any bond, recognizance, contract of indemnity, or writing ol)ligatory in the nature of a bond, recognizance, 
or conditional undertaking shall be valid and binding upon the Company when (a) signed byd the President, any Vice Chairman, any Executive 
Vice President, any Senior Vice President or any Vice President, any Second Vice Presi ent, the Treasurer, any Assistant Treasurer, the 
Corporate Secretary or any Assistant Secretary and duly attested and sealed with the Comi:;iany's seal by a Secretary or Assistant Secretary; 
or (b) duly executed (under seal, if required) by one or more Attorneys-in-Fact and Agents pursuant to the power prescribed in his or her 
certificate or their certificates of authority or by one or more Company officers pursuant to a written/ delegation of authority; and it is 
FURTHER RESOLVED, that the signature of each of the following officers: President, any Executive Vice President, any Senior Vice President, 
any Vice President, any Assistant Vice President, any Secretary, any Assistant Secretary, and th~ seal of the Company may be affixed by facsimile to 
any Power of Attorney or to any certificate relating thereto appointing Resident Vice Presider;its, Resident Assistant Secretaries or Attorneys-in-
Fact for purposes only of executing and attesting bonds and undertakings and other writings obligatory in the nature thereof, and any such Power of 
Attorney or certificate bearing such facsimile signature or facsimile seal shall be valid and binding upon the Company and any such power so executed 
and certified by such facsimile signature and facsimile seal shall be valid and binding on the fompany in the future with respect to any bond or 
understanding to which it is attached. 
I, Kevin E. Hughes, the uci§lersil:fi'l)m;-·,Ai,sistant Secretary of each of the Companies, do !hereby certify that the above and foregoing is a 
true and correct copy of the }"owey,.sf AMr-OJ/Y~~cuted by said Companies, which remains in full fofce and effect. 
<··. _.' · 
__ ------:::---," ---.. _ 
Dated this 26th 
day .Qt A~eptember~-::-: , 2Q2~ \ 
11~01'-r.~-~--~.\ 
~ ~t-
._,. . 
• ~ 
."" 
~'-,, 'it...., 
~··"--
-· <' 
~ -
~ 
-
-
.,.' • • 
'>' 
To verlff l:b~-autiienticity of this Power of Attorney, please call qs at 1-800-421-3880. 
Please refer to the above-named Attorney{s)-in-Fact and the details of the bond to which this Power of Attorney is attached. 
I

Maricopa County 
Bid 240017-DBB 
Attachment E - NON-COLLUSION AFFIDAVIT 
STATE OF ARIZONA 
) 
) ss. 
COUNTY OF MARICOPA 
) 
Stanley S. Showalter 
being firat duly sworn, deposes +d says: 
That he is 
Manager 
of TSG Constructors, LLC 
(Title) 
(Name of Business) 
t 
bidding on Serial #240017-DBB for the construction of Clerk of the Supe ior Court SE Remodel in the 
County of Maricopa, State of Arizona. 
That, in connection with the above-mentioned project, neither he, nor anyone associated with the aforesaid 
business, has, directly or indirectly, participated in any collusion, entered ir· to any contract, combination, 
conspiracy, or other act in restraint of trade or commerce in violation of the provisions of A.RS. § 34-251, 
Article 4, as amended. 
~ 
~Affiant) 
Subscribed and sworn to before me this 28th 
~-
//~ 
Notary Pub I~ ;,/ 
My Commission Expires: __ 
10_·_1_8_·2_5 _____ _ 
Clerk of the Superior Court SE Remodel 
Request for Bids - Design Bid Build 
.✓ 
9/6/2023 3:32 PM 
day of September, 10-=2=3 __ 
f. 
ERRY S DAVIDOFF-SHOWALTER 
Notary Public - Maricopa county 
Commission No. 617013 
My Commission Expires 
-..--,..._,,,.,, 
October 18, 2025 
Serial# 240017~DBB 
Pg. #23 
p.888

Maricopa County 
Bid 240017-DBB 
Attachment F - VERIFICATION OF LICENSE 
Pursuant to A.RS.§ 32-1169, I hereby state that I hold a current contractor' license, duly issued by the office 
of the Registrar of Contractors for the State of Arizonai,.. said license has nbt been revoked, that the license 
number, classification, and expiration date is: 204114 Kc-01, 02/25, 29106 A,3/21 that my privilege license 
number (as required by A.RS.§ 42-1305) is: 21050784 
; ,nd that, if any exemption to the 
above licensing requirements is claimed; 
. 
i 
. 
. 
Tangible personal property to be incorporated into a taxable 
contra~ting project, or a maihtenance, repair, replacement or 
(1) the basis for the claimed exemption is: alteration 
I 
; and 
proJect. 
I 
(2) the names(s) and license number(s) of any general, mechanical, eltctrical, or plumbing contractor(s) 
to be employed on the work are: 
Mechanical -
Electrical -
Plumbing -
IT IS UNDERSTOOD THAT THE FILING OF AN APPLICATION CONTAINING FALSE OR INCORRECT 
INFORMATION CONCERNING AN APPLICANT'S CONTRACTOR'S LICl::NSE OR PRIVILEGE LICENSE 
WITH THE INTENT TO VOID SUCH LICENSING REQUIREMENTS IS UNSWORN FALSIFICATION 
PUNISHABLE ACCORDING TO A.R.S. § 13-2704. 
~EE 
TSG Constructors, LLC 
COMPANY 
Clerk of the Superior Court SE Remodel 
Request for Bids - Design Bid Build 
9/6/2023 3:32 PM 
Ol28.23 
DA 
Serial# 240017-DBB 
Pg. #24 
p. 889 
TCK Service Group, LLC ROC 184388
Apache Power and Water, Inc. ROC 315944
Tek Star Plumbing & Mechanical ROC 091087

--- IMPORTANT NOTICE ---
YOU MUST: 
1.) REPORT DISASSOCIATION OF QUALIFYING PARTY IN WRITING WITHIN 15 DAYS. [SEE A.R.S. 
§ 32-1154(A)(18)] 
2.) REPORT A CHANGE OF ADDRESS IN WRITING WITHIN 30 DAYS. [SEE A.R.S. § 32-1122(8)(1)] 
3.) REPORT ANY TRANSFER OF OWNERSHIP OF 50% OR MORE IMMEDIATELY [SEE A.R.S. 
§ 32-1151.01] 
4.) REPORT ANY CHANGE IN LEGAL ENTITY, SUCH AS ANY CHANGE OF THE OWNERSHIP IN A SOLE 
PROPRIETORSHIP OR CHANGE OF A PARTNER IN A PARTNERSHIP OR THE CREATION OF A NEW 
CORPORATE ENTITY. [SEE A.R.S. § 32-1124(8)(F) § RULE R-4-9-110] 
TSG Constructors LLC 
2340 W Parkside Ln H-105 
Phoenix, AZ 85027 
--- IMPORTANT NOTICE ---
YOU MUST: 
1.) REPORT DISASSOCIATION OF QUALIFYING PARTY IN WRITING WITHIN 15 DAYS. [SEE A.R.S. 
§ 32-1154(A)(18)] 
2.) REPORT A CHANGE OF ADDRESS IN WRITING WITHIN 30 DAYS. [SEE A.R.S. § 32-1122(8)(1)] 
3.) REPORT ANY TRANSFER OF OWNERSHIP OF 50% OR MORE IMMEDIATELY [SEE A.R.S. 
§ 32-1151.01] 
4.) REPORT ANY CHANGE IN LEGAL ENTITY, SUCH AS ANY CHANGE OF THE OWNERSHIP IN A SOLE 
PROPRIETORSHIP OR CHANGE.OF A PARTNER IN A PARTNERSHIP OR THE CREATION OF A NEW 
CORPORATE ENTITY. [SEE A.R.S. § 32-1124(8)(F) § RULE R-4-9-11 OJ 
TSG Constructors LLC 
2340 W Parkside Ln H-105 
Phoenix, AZ 85027 
l 
I 
I 
I 
THIS IS YOUR IDENTIFICATION CARD 
DO NOT DESTROY 
• 
LICENSE EFFECTIVE THROUGH: 
STATE OF ARIZONA 
February 28, 2025 
Registrar of Contractors 
CERTIFIES THAT 
TSG Constructors LLC 
CONTRACTORS LICENSE NO. 
General Dual 
Dual Building Contractor 
THIS CARD MUST BE 
PRESENTED UPON DEMAND 
CLASS 
ROC 204114 
KB-1 
THIS IS YOUR IDENTIFICATION CARD 
DO NOT DESTROY 
• 
1- -
-
-
-
-
-
-
I 
I 
i 
LICENSE EFFECTIVE THROUGH: 
STATE OF ARIZONA 
February 28, 2025 
Registrar of Contractors 
CERTIFIES THAT 
TSG Constructors LLC 
CONTRACTORS LICENSE NO. 
ROC 2041 14 
CLASS KB-1 
General Dual 
Dual Building Contractor 
1 
THIS CARD MUST BE 
: 
PRESENTED UPON DEMAND 
I 
I 
-- - -
-
-
-
-- -- -
-
-
-
-
-
-
-
-
-- •- -
-
-
-
-
-
-
I - -- -
-
- -·---
-~ ------ -
-- -
-- -· -
-- -
---- -
-
-
-- -
-- -
--- -
-
-
-
-
-
--- IMPORTANT NOTICE ---
YOU MUST: 
1.) REPORT DISASSOCIATION OF QUALIFYING PARTY IN WRITING WITHIN 15 DAYS. [SEE A.R.S. 
§ 32-1154(A)(18)] 
2.) REPORT A CHANGE OF ADDRESS IN WRITING WITHIN 30 DAYS. [SEE A.R.S. § 32-1122(8)(1)] 
3.) REPORT ANY TRANSFER OF OWNERSHIP OF 50% OR MORE IMMEDIATELY [SEE A.R.S. 
§ 32-1151.01] 
4.) REPORT ANY CHANGE IN LEGAL ENTITY, SUCH AS ANY CHANGE OF THE OWNERSHIP IN A SOLE 
PROPRIETORSHIP OR CHANGE OF A PARTNER IN A PARTNERSHIP OR THE CREATION OF A NEW 
CORPORATE ENTITY. [SEE A.R.S. § 32-1124(8)(F) § RULE R-4-9-11 OJ 
TSG Constructors LLC 
2340 W Parkside Ln H-105 
Phoenix, AZ 85027 
I 
j 
I 
I 
THIS IS YOUR IDENTIFICATION CARD 
DO NOT DESTROY 
• 
LICENSE EFFECTIVE THROUGH: 
STATE OF ARIZONA 
February 28, 2025 
Registrar of Contractors 
CERTIFIES THAT 
TSG Constructors LLC 
CONTRACTORS LICENSE NO. 
ROC 204114 
CLASS KB-1 
General Dual 
Dual Building Contractor 
THIS CARD MUST BE 
PRESENTED UPON DEMAND

--- IMPORTANT NOTICE ---
YOU MUST: 
1.) REPORT DISASSOCIATION OF QUALIFYING PARTY IN WRITING WITHIN 15 DAYS. [SEE A.R.S. 
§ 32-1154(A)(18)] 
2.) REPORT A CHANGE OF ADDRESS IN WRITING WITHIN 30 DAYS. [SEEA.R.S. § 32-1122(8)(1)] 
3.) REPORT ANY TRANSFER OF OWNERSHIP OF 50% OR MORE IMMEDIATELY [SEE A.R.S. 
§ 32-1151.01] 
4.) REPORT ANY CHANGE IN LEGAL ENTITY, SUCH AS ANY CHANGE OF THE OWNERSHIP IN A SOLE 
PROPRIETORSHIP OR CHANGE OF A PARTNER IN A PARTNERSHIP OR THE CREATION OF A NEW 
CORPORATE ~NTITY. [SEE A.R.S. § 32-1124(8)(F) § RULE R-4-9-110] 
TSG Constructors LLC 
2340 W Parkside Ln H-105 
Phoenix, AZ 85027 
THIS IS YOUR IDENTIFICATION CARD 
DO NOT DESTROY 
• 
LICENSE EFFECTIVE THROUGH: 
STATE OF ARIZONA 
March 31, 2024 
Registrar of Contractors 
CERTIFIES THAT 
TSG -Constructors LLC 
CONTRACTORS LICENSE NO. 
General Commercial 
General Engineering 
THIS CARD MUST BE 
PRESENTED UPON DEMAND 
CLASS 
ROC 291064 
A 
~ETHAM, DIRECTOR 
------------------~----...,..,_ ____ . --·- -- -
-
-
- --- - ---·-·-·- ·---•s. -· ... ·- -
I 
--- IMPORTANT NOTICE ---
YOU MUST: 
1.) REPORT DISASSOCIATION OF QUALIFYING PARTY IN WRITING WITHIN 15 DAYS. [SEE A.R.S. 
§ 32-1154(A)(18)] 
2.) REPORT A CHANGE OF ADDRESS IN WRITINGWITHIN 30 DAYS. [SEE A.R.S. § 32-1122(8)(1)] 
3.) REPORT ANY TRANSFER OF OWNERSHIP OF 50% OR MORE IMMEDIATELY [SEE A.R.S. 
§ 32-1151.01] 
4.) REPORT ANY CHANGE IN LEGAL EN.TITY. SUCH AS ANY CHANGE OF THE OWNERSHIP IN A SOLE 
PROPRIETORSHIP OR CHANGE OFA PARTNER IN A PARTNERSHIP OR THE CREATION OF A NEW 
CORPORATE ENTITY. [SEE A.R.S. § 32-1124(8)(F) § RULE R-4-9-110] 
TSG Constructors LLC 
2340 W Parkside Ln H-105 
Phoenix, AZ 85027 
I 
I 
I 
I 
I 
: THIS IS YOUR IDENTIFICATION CARD 
I 
I 
I 
I 
I 
I 
I 
I 
I 
I 
DO NOT DESTROY 
• 
1--------------------------------------
1 
I 
I 
LICENSE EFFECTIVE THROUGH: 
I STATEOF ARIZONA 
M~rch 31, 2024 
I 
: Registrar of Contractors 
CERTIFIES THAT 
I 
: 
TSG Constructors LLC 
I 
I 
I 
CONTRACTORS LICENSE NO. 
I 
I 
I 
I 
I 
I 
I 
General Commercial 
General Engineering 
1 THIS CARD MUST BE 
: 
PRESENTED UPON DEMAND 
I 
I 
ROC 291064 
CLASS 
A 
-
- --
---·. 
" -
-· 
-- -
-
- -
-
-
-
-
-
-
-
- - -· -
-
-
-
.. -
- -
-
-
-
-
-
-
-
- -
-
-
-
- -
- -
-
- -i- --- - -
- --- -- -- -
- -
- -
- -
-
-
- -
-
-
-
-
-
-
-
-
- -
-
-
-
-
-
--- IMPORTANT NOTICE ---
YOU MUST: 
1.) REPORT DISASSOCIATION OF QUALIFYING PARTY IN WRITING WITHIN 15 DAYS. [SEE A.R.S. 
§ 32-1154(A)(18)] 
• 
. 
2.) REPORT A CHANGE OF ADDRESS IN WRITING WITHIN 30 DAYS. [SEEA.R.S. § 32-1122(8)(1)] 
3.) REPORT ANY TRANSFER O_F OWNERSHIP OF 50% OR MORE IMMEDIATELY [SEE A.R.S. 
§ 32-1151.01] 
. 
4.) REPORT ANY CHANGE IN LEGAL ENTITY, SUCH AS ANY CHANGE OF THE OWNERSHIP IN A SOLE 
PROPRIETORSHIP OR CHANGE OF A PARTNER IN A PARTNERSHIP OR THE CREATION OF A NEW 
CORPORATE ENTITY. [SEE A.R.S. § 32-1124(8)(F) § RULE R-4-9-110] 
TSG Constructors LLC 
2340 W Parkside Ln H-105 
Phoenix, AZ 85027 
I 
I 
I 
I 
I 
I 
I 
I 
I 
I 
I 
I 
I 
I 
I 
I 
I 
THI.S IS YOUR IDENTIFICATION CARD 
DO NOT DESTROY 
• 
1--------------------------------------
1 
. 
I 
LICENSE EFFECTIVE THROUGH: 
STATE OF ARIZONA 
March 31, 2024 
Registrar of Contractors 
CERTIFIES THAT 
TSG Constructors LLC 
CONTRACTORS LICENSE NO. 
General Commercial 
General Engineering 
THIS CARD MUST BE 
PRESENTED UPON DEMAND 
ROC 291064 
CLASS 
A 
()ffe-_. -
#JEFFFLEETHAM, DIRECTOR

ARIZONADEPARTMENT OF REVENUE 
ATTN: Customer Care and Outreach 
PO BOX29032 
Phoenix, AZ 85038-9032 
ARIZONA DEPARTMENT OF REVENUE 
TRANSACTION PRIVILEGE TAX LICENSE 
NOT TRANSFERABLE 
The licensee listed below is licensed to conduct business upon the condition that taxes are paid to 
Arizona Department of Revenue as required under provisions of A.R.S. Title 42, Chapter 5, Article 1. 
ISSUED TO.: TSG • CONSTRUCTORSLLC 
2340 WPARKSIDELNH~105 
PHOENIX AZ 85027-12 
LOCATION: 
017/RETAIL 
029••"·•USETAX 
015••·-•CONTRACTING• ... ·••PRIME 
01·5.·_·.coNSTRUCTION·CONTRACTING 
- SPECULATIVE BUILDERS 
029 - USE TAX 
015 -CONTRACTING - PRIME 
015 - CONTRACTING - PRIME 
2023 
ALL•communications.•and ~~•• ... •·.·• LICENSE; 21050784 
ST REFERto 
START DATE( 01/01/2015 
SENO. 
GE -GLEI\JDAL.E 
GE - GLENDALE 
GL-GLOBE 
Gl..J - GUADALUPE 
ISSUED:••·01/0312023 
EXPIRES: 12/31/2023 
CITY 
CITY 
CITY 
CITY 
CITY 
This License is issued to the business named above for the address shown. Lic':lnses, by law, cannot be transferred from one person to another, nor can they be 
transferred from one location to another. Arizona law requires licensees to notify the Department of Revenue if there is a change in business name, trade name, 
location, mailing address, or ownership. In addition, when the business ceases to operate or the business location changes and a new license is issued, this license 
must be returned to the Arizona Department of Revenue. According lo R 15-5-2201 /license must be displayed in a conspicuous place.

BUSINESS CODE 
015 - CONTRACTING - PRIME 
015 - CONTRACTING - PRIME 
015- CONTRACTING- PRIME 
015 - CONTRACTING - PRIME 
015 - CONTRACTING- PRIME 
015 - CONTRACTING - PRIME 
015 -CONTRACTING- PRIME 
REGION 
ME- MESA 
PM-PIMA 
PX-PHOENIX 
SC - SCOTTSDALE 
SL-SHOW LOW 
TC - THATCHER 
TE-TEMPE 
LICENSE: 21050784 
JURISDICTION 
CITY 
CITY 
CITY 
CITY 
CITY 
CITY 
CITY 
Page 2 of2 
"' 
0 
0 g I 
a, 
"' 
0.. g 
0 
l2 g 
0 "' , 
0 g